Loading...
HomeMy WebLinkAboutCC RESO 15,715RESOLUTION NO. 15,715 RESOLUTION OF THE CITY COUNCIL OF THE CITY OF NATIONAL CITY AUTHORIZING THE MAYOR TO EXECUTE AN IMPROVEMENT AGREEMENT BETWEEN PHILHOMES PLAZA I AND THE CITY OF NATIONAL CITY FOR GRADING AND PUBLIC IMPROVEMENTS BE IT RESOLVED by the City Council of the City of National City that the Mayor is hereby authorized to execute an Improvement Agreement between Philhomes Plaza I and the City of National City for grading and public improvements of subdivision east of Harbison Avenue and north of 5th Street in National City, a copy of which is attached hereto as Exhibit "A". PASSED and ADOPTED this 23rd day of August, 1988. & / /J7e,s- EORG H. WATERS, MAYOR ATTEST: IOI`E CAMPBELL, CITY CLERK 'or APPROVED AS TO FORM: 'gat' ?X- GEORGE H. EISER, III CITY ATTORNEY IMPROVEMENT AGREEMENT FOR FAITHFUL PERFORMANCE OF WORK AND FOR LABOR & MATERIAL THIS AGREEMENT, made and entered into this 23ro! day of �U9t/S/ , 19 628 , by and between the CITY OF NATIONAL CITY, a municipal corporation,tihereinafter called "City", and Naza r I o tliv;/14.2 're , hereinafter call "Developer", WITNESSETH: Sv61441440 WHEREAS, Developer is about to record or has acquired a Tareel Map to be recorded pursuant to the provisions of ordinances of the City of National City relating to the filing, approval and recordation of Parcel Maps; and WHEREAS, That before said map is finally approved by the City, Developer must either have installed and completed all of the public improvements and/or land development work required by the Code to be installed in subdivisions before final maps of subdivision are approved for purposes of recording in the office of the County Recorder of San Diego County, or as an alternative thereof, that Developer shall enter into an agreement with City, secured by an approved improvement security to insure the performance of said work pursuant to the requirements of ordinances of the City of National City, agreeing at its own expense to install and complete, free of liens, all of the public improvements and/or land development work required in said subdivision within a definite period of time prescribed by said City; and WHEREAS, Developer is willing to enter into this agreement wherein it is provided that Developer will install and complete at its own expense, all the public improvement work required by City in connection with the said Subdivision and will deliver to City an improvement security as approved by the City Attorney; and WHEREAS, Complete Plans and Specifications for the construction, installation and completion of said public improvement work have been prepared, -1- and approved by the City Engineer, as shown on Drawings No. 64B4-D, ‘4295l361g6-/7, 6409-Pc, 4498-DD, 4o189DE, 61B7-I 64B9-.0, (o-¢BB�,q,i64BB-DB, and have been filed of record in the , 19 s , office of the City Clerk on Ducun1N qa - i1,2, Document No. �,f8i�.i/ % c hr 4id2 a copy of which plans and Specifications is also on file in the office of the City Engineer; and WHEREAS, an estimate of the cost of constructing said public improvements and/or land development according to said Plans and Specifications has been made by the City Engineer and has been approved by City, to which estimate of costs, 10% thereof has been added as required by ordinances of the City of National City for public improvements and/or an amount computed pursuant to the requirements of said ordinances has been added for land development work, which estimate is attached hereto, marked "Exhibit B" and made a part hereof; NOW, THEREFORE, IT IS MUTUALLY UNDERSTOOD AND AGREED AS FOLLOWS: That in consideration of the approval and recordation by the City Council of the Parcel Map of said subdivision, and/or other valuable consideration, Developer expressly herein undertakes and agrees as follows: To comply with all of the requirements of the tentative map resolutions; to do and perform or cause to be done and performed at its own expense, without cost to City, in a good and workmanlike manner, under the direction and to the satisfaction and approval of the City Engineer of City all of the public improvement and/or land development work required to be done in and adjoining said Map and will furnish the necessary materials therefor, all in strict conformity and in accordance with the Plans and Specifications, which document has been heretofore filed in the office of the City Clerk and by reference thereto is incorporated herein and made a part hereof. It is expressly understood and agreed that Developer will cause all necessary materials to be furnished and all improvements required under the provisions of this contract to be done on or before A69645/13/ /, 99 -2- It is also understood and herein expressly agreed to by Developer that in the performance of said work, Developer will conform to and abide by all of the provisions of the ordinances of the City of National City and the laws of the State of California applicable to said work. That if any of the public improvements and/or land development work contemplated by this agreement is to be constructed or installed on land not owned by Developer, no construction or installation shall be commenced thereon prior to the dedication and acceptance by City of appropriate easements or right of way therefor. Developer further agrees that simultaneously with the execution of this agreement, it will furnish and deliver to the City an approved S56/, 757 for Per/orrnance improvement security in the sum of St2go,By3 4riaborI11617which security shall guarantee the faithful performance of this contract by Developer and is attached hereto marked "Exhibit C" and made a part hereof. It is further agreed that if the public improvements are not completed within the time agreed herein, the sums provided by said improvement security may be used by City for the completion of the public improvements within said subdivision in accordance with specifications contained herein. Upon certification of completion by said City Engineer and acceptance of said work by City and after certification of the City Clerk and City Treasurer that all costs thereof are fully paid, the whole amount, or any balance of said sum not required for payment thereof, may be released to Developer, or its successors in interest pursuant to the terms of the improvement security. It is also agreed and understood by the parties to this agreement that in no case will the City of National City or any Department, Board or Officer thereof be liable for any portion of the costs and expenses of the work aforesaid nor shall any officer, or his sureties or bondsmen be liable for the payment of any sum or sums for the above -mentioned work of any materials furnished therefor. -3- Provided, however, that this shall not preclude City from entering into agreements with Developer for the apportionment of costs of water and sewer mains pursuant to the provisions of the ordinances of National City providing therefor, nor shall anything herein stated commit City to any such apportionment. It is further understood and agreed by Developer that any engineering costs (including plan checking, inspection, materials furnished and other incidental expenses) incurred by City in connection with the preparation of the improvement plans and the installation of the public improvements hereinabove provided for, shall be paid by Developer and Developer shall deposit with City a sum of money equal to 3% of the costs of the improvements, approved by the City Engineer. In ascertaining the amount of such costs incurred by City, the cost report of the City Clerk and City Treasurer shall be prima facie evidence of the true cost of the engineering services so performed by City. It is understood and agreed that until such time as all improvements are fully completed and accepted by City, Developer will be responsible for the care, maintenance of and any damage to the streets, alleys, easements, water and sewer lines within the proposed subdivision. That upon acceptance of the work on behalf of City, Developer shall grant to City by appropriate conveyance, the improvements constructed pursuant to this agreement. The acceptance of the work on behalf of City shall be made by City Manager upon the authorization of the City Council. Such acceptance shall not constitute a waiver of defects by City. It is understood and agreed that City shall not, or any officer or employee thereof, be liable for any injury to person or property occasioned by reason of the acts or omissions of Developer, his agents or employees in the performance of this agreement. Developer further agrees to protect and -4- hold harmless City, its officers and employees from any and all claims, demands, causes of action, liability or loss of any sort, because of or arising out of the acts or omissions of Developer, his agents, or employees in the approved improvement security shall not be required to cover the provisions of this paragraph. In the event that suit is brought upon this contract by City to enforce the terms hereof, City shall be entitled to a reasonable sum as attorney's fees. IN WITNESS WHEREOF, City has caused this agreement to be executed by having affixed thereto the signature of an authorized City Representative and Developer has caused this agreement to be executed, as duly authorized, the day and year first hereinabove written. -5- STATE OF CALIFORNIA, 1 SS. L COUNTY OF • 4- On 2-e z" / 5- / jr 8 S' before me, the under signed, a Notary Public in and for said County t ersonaily appeared �da-t I known to me to be the -4---J-0'.-' and — ,-- , known to me to be o e�c i a ion that executed the within Instrument, known to me to be the persons who executed the within Instrument on behalf of the corporation therein named, and acknowledged to me that such corporation executed the within instru- ment pursuant to its by-laws or resolution of its board (rectors. BY Develc(per Ph1 14,rnes PLAzet 2 n ?DrN�-coo-vac_ 'ExjC..h. SerVice$,TinL.. $'6 Collnl SE. toPre s.of. ,Jr jL to--rikrg L. n Ise, St" inn.' Die ei c / C`� 9a j ?) q Developer's Address BEFORE IR SAID 0 ME •0 THE THEY iD AND THIS 'IRES: D FOR TE ESTIMATED COMPLETION DATE: THE CITY OF NATIONAL CITY GEORGE H. WATERS MAYOR BY Developer's Telephone No. IMPROVEMENT SECURITY FOR Subdivision Improvements: 1. Faithful Performance of Improvement Agreement. Cash: Form of: Boric/ Trust & Agency $ Amount: Jr56/, 78740' Receipt No. 2. Labor and Material for Improvement Agreement. Form of: L76or /i1 /erio/ Cash: Trust & Agency $ Amount: :280 893,, :1 Receipt No. ACKNOWLEDGEMENT FOR CORPORATION JOINT VENTURER STATE OF C IFORN* (SS COUNTY OF Fltit/ .1>rE:(yJ On this /C cday of Ate-. , 19 eq before me, the unj�] ersigned, a Notary Public in nd for said county and state, personally appeared i o,Ci,✓ _5 E //) acrd , known to me to be the President a SccFe4.1.y, _especti.vely of C, /1+. ..5e-i/zees //ye • , the corporation that executed the within instrument, said persons being I`cnown to.me to be the persons who executed the within instrument on behalf of said corporatio , said c poration being known to me to. g be one of the joint venturers of i5// K- •/i»&`5 �,C1x4 ;_ , the joint venture that executed the within instrument and acknowledged tome that such corporation u executed the same both individually and as joint venturer. of said joint venture and that such joint venture also executed the same. WITNESS my hand and official seal. (SEAL) 4414 y`. OFFICIAL SEAL, BERTIE M. GOLD NOTARY PUBLIC • CALIFORNIA SAN DIEGO COUNTY My Corm. Expires Morels 10,1992 S'____. Notary ublic in and for said County a State BOND NUMBER SUR 07 48 06 BOND PREMIUM (INCLUDED) SURETY TO SECURE LABOR AND MATERIAL FOR IMPROVEMENT AGREEMENT Whereas, the City Council of the City of National City, State of California, and PRILHOMES PLAZA I, A JOINT VENTUR$hereinafter designated as "principal") have en- tered into an agreement whereby principal agrees to install and complete certain designated public improvements, which said agreement dated , 19_, and identified as project PEACHBLOSSOM & SHELL AVENUE JOB #4191 is hereby referred to and made a part hereof; and Whereas, Under the terms of said agreement, principal is required before entering upon the performance of the work, to file a good and sufficient payment bond with the City of National City to secure the claims to which reference is made in Title 15 (commencing with Section 3082) of. Part 4 of Division 3 of the Civil Code of the State of California. Now, therefore, said principal and the undersigned as corporate surety, are held firmly bound unto the City of National City, and all contractors, subcontractors, laborers, material -men and other persons employed in the performance of the afore- said agreement and referred to in the aforesaid Code of Civil Procedure in the sum of TWO HUNDRED EIGHTY THOUSAND, EIGHT HUNDRED NINETY THREE .. %3lars ($. 280,893.00 ), for materials furnished or labor thereon of any kind, or',ur amounts due under the Unemployment Insurance Act with respect to such work or labor, that said surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees, including reasonable at- torney's fees, incurred by county (or city) in successfully enforcing such obliga- tion, to be awarded and fixed by the court, and to be taxed as costs and to be in- cluded in the judgment therein rendered. It is hereby expressly stipulated and agreed that this bond shall inure to the be- nefit of any and all persons, companies and corporations entitled to file claims under Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the Civil Code, so as to give a right of action to them or their assigns in any suit brought upon this bond. Should the condition of this bond be fully performed, then this obligation shall become null and void, otherwise it shall be an remain in full force and effect. The surety hereby stipulates and agrees that no change, extension of time, altera- tion or addition to the terms of said agreement or the specifications accompanying LEDGEMENT FOR CORPORATION JOINT VENTURER OF CI LIFORNIA Y OF Ai✓ i 6-6 a (SS this /6 day of A'G-. , 19 eP, before me, the unjjrsigned, a Notary Public in for said county and state, personally appeared ('_O.C/f✓ . 4 /.c( and , known to me to be the President a Secrets , Iectively of 62_, /,V, �E`e 4 C r .5 /n/ he corporation that executed the iin instrument, said persons being known to me to be the persons who executed the gin instrument on behalf of said cor oratipn, said corporation being known to me to pno of the joint venturers of f <.4. ) - i S 1,Lq,zy.E' , the joint venture t executed the within instrument and acknowledged tome that such corporation :cuted the same both individually and as joint venturer of said joint venture and it such joint venture also executed the same. WITNESS my hand and official seal. TEAL) OFFICIAL SEAL BERTIE M. GOLD NOTARY PUBLIC • CALIFORNIA SAN DIEGO COUNTY My Comm. Expirce March I Q 1992 Notary Public in and for said County anState NOTARY PUBLIC-CALIFORNIA a ` PRINCIPAL OFFICE IN SAN DIEGO COUNTY My Comm. Exp. Oct. 2,1990 �N ts." ' EXH/B/T "C " GOLDEN EAGLE INSURANCE COMPANY EXECUTIVE OFFICES San Diego, California BOND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS. That the Golden Eagle Insurance Company, a Corporation duly organized and existing under the laws of the State of California, having its principal office in the City of San Diego, California does hereby nominate, constitute and appoint Terry Gage of San Diego, California its true and lawful agent and attorney -in -fact, to make, execute, seal and deliver for and on its behalf as surety, and its act and deed, any and all bonds, contracts, agreements of indemnity and other undertakings in suretyship provided, however, that the penal sum of any one such instrument executed hereunder shall not exceed the sum of any and all bonds and undertakings, provided the amount of no one bond or undertaking exceeds FOUR MILLION DOLLARS ($4,000,000.00) This power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of the Golden Eagle Insurance Company at a meeting duly called and held on April 10, 1984 which said Resolution has not been amended or rescinded and of which the following is a true, full and complete copy. "RESOLVED: That the President or Secretary may from time to time appoint Attorneys -in -Fact to represent and act for and on behalf of the Company, and either the President or Secretary, the Board of Directors or Executive Committee may at any time remove such Attorneys -in - Fact and revoke the Power of Attorney given him or her; and be it further "RESOLVED: That the Attorneys -in -Fact may be given full power to execute for and in the name of and on behalf of the Company any and all bonds and undertakings as the business of the Company may require, and any such bonds or undertakings executed by any such Attorney - in -Fact shall be as binding upon the Company as if signed by the President and sealed and attested by the Secretary." IN WITNESS WHEREOF, the said Golden Eagle Insurance Company has caused these presents to be executed by its officer, with its corporate seal affixed STATE OF CALIFORNIA COUNTY OF SAN DIEGO SS: this March 10, 1986 GOLDEN EAGLE INSURANCE COMPANY By Micha'I E.J a President On this 10th day of March, 1986, before the subscriber, a Notary Public of the State of California, in and for the County of San Diego, duly commissioned and qualified, came Michael E. James, President, of GOLDEN EAGLE INSURANCE COMPANY, to me personally known to be the individual and officer described in and who executed the preceding instrument and he acknowledged the execution of the same, and being by me duly sworn, deposeth and saith, that he is the said officer of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of the said Company, and that the said Corporate Seal and his signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my Official Seal, at the City of San Diego, the day and year first above written. OFFICIAL SEAL MARY E. LEIGH Notary Public•California Principal Office In San Diego County My Comm. Exp. Jan. 2. 1988 STATE OF CALIFORNIA COUNTY OF SAN DIEGO SS: ✓ Notary Public I, the undersigned, Larry G. Mabee, Secretary of the Golden Eagle Insurance Company, do hereby certify that the original POWER OF ATTORNEY, of which the foregoing is a full, true and correct copy, is in full force and effect, and has not been revoked. IN WITNESS WHEREOF, I have hereunto subscribed my name as Secretary, and affixed the Corporate Seal of the Corporation this 15TH day of AUGUST 19 88 . LARRY G. MABEE Secretary Any correspondence regarding this Power of Attorney, address to: 7175 Navajo Road San Diego, California 92119-1642 BOND NUMBER SUR 07 48 06 BOND PREMIUM $14,045.00 SURETY TO SECURE FAITHFUL PERFORMANCE OF IMPROVEMENT AGREEMENT Whereas, the City Council of the City of National City, State of California, and PHILHOMES PLAZA I, A JOINT VENTINE reinafter designated as "principal") have en tered into an agreement whereby principal agrees to install and complete certain designated public improvements, which said agreement, dated , 19 , and identified as project PEACHBLOSSOM AND SHELL AVENUE, JOB #4191 is hereby referred to and made a part hereof; and Whereas, Said principal is required under the terms of said agreement to furnish a surety for the faithful performance of said agreement. Now, therefore, we, the principal and the undersigned as surety, are held and firmly bound unto the City of National City hereinafter called "City", in the pe- nal Sum of FIVE HUNDRED SIXTY ONE THOUSAND,SEVEN HUNDRED EIGHTY N tars (S 561,787.00 ), lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, successors, executors and administrators, jointly and severally, firmly by these presents. The condition of this obligation is such that if the above bounded principal, his or its heirs, executors, administrators, successors, or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and provisions in the said agreement and any alteration thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City, its officers, agents and employees, as therein stipulated, then this obligation shall become null and void; otherwise it shall be an remain in full force and effect. As part of the obligation secured hereby and in addition to the face amount spe- cified therefor, there shall be included costs and reasonable expenses and fees including reasonable attorney's fees, incurred by City in successfully enforcing such obligation, all to be taxed as costs and included in any judgement rendered. The surety hereby stipulates and agrees that no change, extension of time, alte- ration or addition to the terms of the agreement or to the work to be performed thereunder or the specifications accompanying the same shall in anywise affect its obligations on this bond, and it does herehv ...+; r ___. ___. ACKNOWLEDGEMENT FOR CORPORATION JOINT VENTURER STATE OF CALIFORNJrA COUNTY OF ,SA,✓ Ar 4-c, (SS 0On this iv day of vU. , 19 414, before me, the and�'signed, a Notary Public in and for said county and state, personally appeared C!o/I'V —C -.o a , known to me to be the President am41- Spy, respectively of ?. /J/• 5-E= �✓<!e 5 Apo . , the corporation that executed the within instrument, said persons being -known to.me to be the persons who executed the within instrument on behalf of saidffg�rporat'on, said rporation being known to me to' `rt%� 7 be one of the joint venturers of '�Q inC5 /'Z, /I . ' _, the joint venture that executed the within instrument and acknowledged tome that such corporation executed the same both individually and as joint venturer%of said joint venture and .that such joint venture also executed the same. WITNESS my hand and official seal. (SEAL) o-, `, - OFFICIAL SEAL I ,� NOTA�RRYYRPTuouC M.CALlFOI SANDEt`aO COUNT' ��. My Comm Expires March 10, 1992 1 Notary and State CERTIFICATE FIRST ABOVE WRITTEN. GIGIOMMARIE DI EAENZA NOTARY PUBLIC-CALIFORNI PRINCIPAL OFFICE IN SAW DIEGO COUNTY My Comm. Exp. Oct. 2.1990 Public yn and for said Coun u It/AK rr4 IRIS MY COFimISSION EXPIRES: OCTOBER 2, 1990 UBLIIN UNTY AND STATE EXH/B/T "G " GOLDEN EAGLE INSURANCE COMPANY EXECUTIVE OFFICES San Diego, California BOND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS. That the Golden Eagle Insurance Company, a Corporation duly organized and existing under the laws of the State of California, having its principal office in the City of San Diego, California does hereby nominate, constitute and appoint Terry Gage • of San Diego, California its true and lawful agent and attorney -in -fact, to make, execute, seal and deliver for and on its behalf as surety, and its act and deed, any and all bonds, contracts, agreements of indemnity and other undertakings in suretyship provided, however, that the penal sum of any one such instrument executed hereunder shall not exceed the sum of any and all bonds and undertakings, provided the amount of no one bond or undertaking exceeds FOUR MILLION DOLLARS ($4,000,000.00) This power of Attorney is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of the Golden Eagle Insurance Company at a meeting duly called and held on April 10, 1984 which said Resolution has not been amended or rescinded and of which the following is a true, full and complete copy. "RESOLVED: That the President or Secretary may from time to time appoint Attorneys -in -Fact to represent and act for and on behalf of the Company, and either the President or Secretary, the Board of Directors or Executive Committee may at any time remove such Attorneys -in - Fact and revoke the Power of Attorney given him or her; and be it further "RESOLVED: That the Attorneys -in -Fact may be given full power to execute for and in the name of and on behalf of the Company any and all bonds and undertakings as the business of the Company may require, and any such bonds or undertakings executed by any such Attorney - in -Fact shall be as binding upon the Company as if signed by the President and sealed and attested by the Secretary." IN WITNESS WHEREOF, the said Golden Eagle Insurance Company has caused these presents to be executed by its officer, with its corporate seal affixed STATE OF CALIFORNIA COUNTY OF SAN DIEGO SS: this March 10, 1986 GOLDEN EAGLE INSURANCE COMPANY By Micha=IE.J a , President On this 10th day of March, 1986, before the subscriber, a Notary Public of the State of California, in and for the County of San Diego, duly commissioned and qualified, came Michael E. James, President, of GOLDEN EAGLE INSURANCE COMPANY, to me personally known to be the individual and officer described in and who executed the preceding instrument and he acknowledged the execution of the same, and being by me duly sworn, deposeth and saith, that he is the said officer of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of the said Company, and that the said Corporate Seal and his signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN WITNESS WHEREOF, I have hereunto set my hand and affixed my Official Seal, at the City of San Diego, the day and year first above written. _a"' 4 - ------I OFFICIAL SEAL MARY E. LEIGH Notary Public•Cahfornia Principal Office In San Diego County My Comm. Exp. Jan. 2. 1988 STATE OF CALIFORNIA COUNTY OF SAN DIEGO SS: Notary Public I, the undersigned, Larry G. Mabee, Secretary of the Golden Eagle Insurance Company, do hereby certify that the original POWER OF ATTORNEY, of which the foregoing is a full, true and correct copy, is in full force and effect, and has not been revoked. IN WITNESS Witting, I have hereunto sutLspribed my name as Secretary, and affixed the Corporate Seal of the Corporation, this 15TH day of 19 LS2S LARRY G. MABEE Secretary Any correspondence regarding this Power of Attorney, address to: 7175 Navajo Road San Diego, California 92119-1642 VICINITY M4P NOT TO SCALE PLAT C:,KD. 'ay CATE....... -6Um MAt�� SUBJECT_- 20PD 771 ti T6 . _._ FOF SHEET NOI OF PH-1-.1toiEs `PLAZA J�8 NO- 41`Il LLni QF lUAT►OORG'TY) sz Scw_c-YZ Iir s1ORN gA!I t - fa/SL1 L S7 OOM OKA IN- PKINIATE to -ND S c�}� ic*- c'ex-4-- $ 93, 666_70 4,509.00 4 d53_ pp 4 305:7 959_DD 3.31 34o.00 TOTQ L - $ 5/O 714.70 r0 �o C wr/its, = 5 /> 7 /. 47 7-,e/fivo ��t 4 - _ $ 6 l/ 7 ' . / 7 goA10 /-1-H uAi = $56 2,, paa EXH/B/ T B For /%764c r'ES/9/AZq T44 Job No. Ea/V(7 ESTIMATE By: .S4' Fr Z o = 3 Rigert Engineering, Inc. 428 Broadway Chula Vista, California 92010 (619) 420-7090 • Checked By: J/-/A Dote: 3/23 NO. ITEM QUANTITY UNIT WIT PRICE ITEM PRICE • Z PeleG/c S-/?�C-'7—/.✓ni?g,/may` . S / -c- /2/7 / // 4/777's'�-'C'cam,'.8£'6c 7 /',4,r �/2M /a7 A- . r P P < < S/Dccv.4-6.is / � 9/ s.--. Z - 7©I 9--. „ ..- .8 s--.. s' C�7?6-::c7.'"- 4/4 "T / eo% - ©o• - / • • x? c c'r,Q ei" S-' v=?' .�,-,/v.;, , . 2_ e.,. ? / �� 7 , 422/c-mac i ey- i 3 3 2 S S/c,r=w tk• , &f--a✓,. / 2b—lo s-- / 00 - o:_ 1 11//2&3 £`G e 4? 2%.yviAz_ 6 QL /-f_ 7 , -..v /0 A_ . c, t/A1Z A_ A-401,4LL / Z20 S•--'„ c // /, C c. /�/�1/c r-/v--7-6 ') 98 2 s=- e -, , 70 /Z- 1Ar.D /` - ion 4 t . - f /3 5" V .. P• G7Q /. , z ,. �� / • /Z'//./ . Z8¢ / / (Lrr�le_A=9 'S / C4" / ,,- 7 ,c €4; cC o /.4. G-'x : JroGd / .8,e,7K S6//3-ervi aC S STOZt1 DEA-IV Pcs 30 C_ / (' f UuTLL=T" - Z e1.. / a a , DO GS) / LAID &-P . '/9v'w.4aa D/ZA-/,I/(2-3"PVL I ea. 1 / . / 00 / su rA-,Tcf7-+L - I 0 Do 1♦���ii������� CIVIL ENGINEERS • PLANNING CONSULTANTS • SURVEYORS ESTIMATE ��ii For: ��%/i/.7ii�S 7/ 17c % �Y' Job No. l"/ Ry: �� 2 Atgert Engineering, Inc. 428 Broadway Chum Vista, California 92010 (619) 420-7090 Checked By: 14 Doer. 6/3/ I ITEM PRICE NO. ITEM S7-afe442,,e,4/r2i-Pit/+//�- za u ZZ Z3 u •� ZG 27 Z43 'P-''Cl c<t" Le.IS/A/ / 2' "n / i n2,04/,V /2"X/Z,rc.47.-c ' SA/4/ ,'% Xee11 I//�/oH ,4/ s ,,4,z v.F- r A//r///i/ . 7 7oT,G �— QUANTITY 2 i 4". �Da 72oO 821sa UNIT S.- sA WIT - PRICE 2..7 - oo� e<o0o:J 1�7V 0 /Y'a%-400 ly 0 oc ;3 pc) / ', /g7ok000 -obi a3ky44oin /97/ _G S. CIVIL ENGINEERS • PLANNING CONSULTANTS • SURVEYORS