Loading...
HomeMy WebLinkAboutCC RESO 15,410RESOLUTION NO. 15,410 RESOLUTION AUTHORIZING 'mt. CITY MANAGER TO EXECUTE AN IMPROVEMENT AGREEMENT BETWEEN E.J. & F.P. SPRAGUE, DEVELOPERS OF CITY'S PARCEL MAP NO. 1987-1-NC (SOUTHWEST CORNER OF "K" AVENUE AND 22ND STREET) AND THE CITY OF NATIONAL CITY BE IT RESOLVED by the City Council of the City of National City, California, that the City Manager is hereby authorized to execute on behalf of the City, an Improvement Agreement between E.J. & F.P. Sprague, Developers of City's Parcel Map No. 1987-1-NC (southwest corner of "K" Avenue and 22nd Street).. PASSED and ADOPTED this 1st of September, 1987. ATTEST: Ion Campbell, City lerk APPROVED AS TO FORM: li,g Geor a H. iser, III -City Attorney � �i George lig Waters, Mayor BOND NO. 02 93 44 SURETY TO SECURE FAITHFUL PERFORMANCE OF IMPROVEMENT AGREEMENT Whereas, the City Council of the City of National City, State of California, and E.J. SPRAGUE, JR. AND FRIEDA PALLAS-SRPAGUE (hereinafter designated as "principal") have en tered into an agreement whereby principal agrees to install a d complete certain designated public improvements, which said agreement, dated ,,,L,„ z , 191Z, and identified as project SPRAGUE EXTENSION is hereby referred to and made a part hereof; and Whereas, Said principal is required under the terms of said agreement to furnish a surety for the faithful performance of said agreement. Now, therefore, we, the principal and the undersigned as surety, are held and firmly bound unto the City of National City hereinafter called "City", in the pe- nal sum of TWENTY NINE THOUSAND NINE HUNDRED EIGHTY SIX & NO/100dollars ($ 29,986.00 ), lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, successors, executors and administrators, jointly and severally, firmly by these presents. The condition of this obligation is such that if the above bounded principal, his or its heirs, executors, administrators, successors, or assigns, shall in all things stand to and abide by; and well and truly keep and perform the covenants, conditions and provisions in the said agreement and any alteration thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City, its officers, agents and employees, as therein stipulated, then this obligation shall become null and void; otherwise it shall be an remain in full force and effect. As part of the obligation secured hereby and in addition to the face amount spe- cified therefor, there shall be included costs and reasonable expenses and fees including reasonable attorney's fees, incurred by City in successfully enforcing such obligation, all to be taxed as costs and included in any judgement rendered. The surety hereby stipulates and agrees that no change, extension of time, alte- ration or addition to the terms of the agreement or to the work to be performed thereunder or the specifications accompanying the same shall in anywise affect its obligations on this bond, and it does hereby waive notice of any such change; extension of tiem alteration or addition to the terms of the agreement or to the work or to the specifications. In witness whereof, this instrument has been duly executed by the principal and sure abo, naon AUGUST 24 , 19 87 . In By: Princi al ESPR E, JR. By: »urety By: Principal FRIEDA PA STATE OF CALIFORNIA) COUNTY OF SAN DIEGO) ss AS- RAGUE EXPLORER INSURANCE COMPANY Angie V. Li auricio, Atte'rney-4123Facik ;A;0 "STATE OF i CALIFORNIA ) ss.: CITY AND MUM OF SAN DIEGO ) On this 24th day. August 19 87 , before rm , the undersigned Notary Public, in and for the State, personally appeared Angle V. Mauricio a person known to me (or proved to me on the basis of satisfactory evidence), to be the person who executed the written instrument as Attorney -in -Fact on behalf of the corporation therein named and acknowledged to FTC that the corporation executed it. Given under rry hand and Notarial Seal this 24th day of My Commission Expire OFFICIAL SEAL ANDREA M. CALABRESE; CL NOIA Y PU_'L;C CALIFORNIA PRINCIPAL OFFICE IN SAN DIEGO COUNTY My Commision Expires March 17, 1989 August Notary Public. A.D. 19 R7 BOND NO. 02 93 44 SURETY TO SECURE FAITHFUL PERFORMANCE OF IMPROVEMENT AGREEMENT Whereas, the City Council of the City of National City, State of California, and E.J. SPRAGUE, JR. AND FRIEDA PALLAS-SRPACUE (hereinafter designated as "principal") have en tered into an agreement whereby principal agrees to install and complete certain designated public improvements, which said agreement, dated „„, ,0 z , 1987, and identified as project SPRAGUE EXTENSION is hereby referred to and made a part hereof; and Whereas, Said principal is required under the terms of said agreement to furnish a surety for the faithful performance of said agreement. Now, therefore, we, the principal and the undersigned as surety, are held and firmly bound unto the City of National City hereinafter called "City", in the pe- nal sum of TWENTY NINE THOUSAND NINE HUNDRED EIGHTY SIX & NO/100 dollars (S 29, 986.00 ) , lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, successors, executors and administrators, jointly and severally, firmly by these presents. The condition of this obligation is such that if the above bounded principal, his or its heirs, executors, administrators, successors, or assigns, shall in all things stand to and abide by; and well and truly keep and perform the covenants, conditions and provisions in the said agreement and any alteration thereof made as therein provided, on his or their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City, its officers, agents and employees, as therein stipulated, then this obligation shall become null and void; otherwise it shall be an remain in full force and effect. As part of the obligation secured hereby and in addition to the face amount spe- cified therefor, there shall be included costs and reasonable expenses and fees including reasonable attorney's fees, incurred by City in successfully enforcing such obligation, all to be taxed as costs and included in any judgement rendered. The surety hereby stipulates and agrees that no change, extension of time, alte- ration or addition to the terms of the agreement or to the work to be performed thereunder or the specifications accompanying the same shall in anywise affect its obligations on this bond, and it does hereby waive notice of any such change; extension of tiem alteration or addition to the terms of the agreement or to the work or to the specifications. In witness whereof, this instrument has been duly executed by the principal and sure abo narrpe� on AUGUST 24 , 19 87 . By: Princi E.J'. SPR c, mac( By: Principal FRIEDA FA AS-3 JRAGUE STATE OF CALIFORNIA) COUNTY OF SAN DIEGO) ss al EXPLORER INSURANCE COMPANY JR By: surety Angie V.,Mauricio, Attornej-ir7Fact�:, ON THIS DAY OF , 19 BEFORE ME, THE UNDERSIGNED, A NOTARY PUBLIC IN AND FOR SAID COUNTY AND STATE, PERSONALLY APPEARED AND KNOWN TO ME TO BE THE PERSONS WHOSE NAMES ARE SUBSCRIBED TO THE WITHIN INSTRUMENT, AND ACKNOWLEDGED TO ME THAT THEY EXECUTED THE SAME. IN WITNESS WHEREOF, I HAVE HEREUNTO SET MY HAND AND AFFIXED MY NOTARIAL SEAL, THE DAY AND YEAR IN THIS CERTIFICATE FIRST ABOVE WRITTEN. MY COMMISSION EXPIRES: NOTARY PUBLIC IN AND FOR SAID COUNTY AND STATE EX///B/T NC CONTRACT BOND - CITY OF'NATIONAL CITY BOND NO. 02 93 44 PAYMENT BOND - PUBLIC WORKS KNOW ALL MEN BY THESE PRESENTS: That we E. J. SPRAGUE, JR. & FRIEDA Of PALLAS-SPRAGUE as Principal, and EXPLORER INSURANCE COMPANY , a Surety authorized to transact surety business in the State of California, as Surety, are held and firmly bound unto the City of National City, as Obligee, in the sum of FOURTEEN THOUSAND NINE HUNDRED NINETY THREE AND NO/100 Dollars ($ $ 14,993.00 ), for the payment whereof, well and truly to be made, said Principal and Surety bind themselves, their heirs, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the condition of the foregoing obligation is such that the above bounden Principal has entered into a contract, dated-.-3-,.,/ ,e, 19 ,�' 7, with the Obligee to do and perform the following work, to'wi / GRADING, SIDEWALK, RETAINING WALLS, ETC. FOR SPRAGUE EXTENSION NOW, THEREFORE, if the above -bounden Principal or his subcontractors fail to' pay any of the persons named in Section 3181 of the Civil Code of the State of California, or amounts due under the Unemployment Insurance Code with respect to work or labor performed under the contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the contractor and his subcontractors pursuant to Section 13020 of the Unemployment Insurance Code of the State of California, with respect to such work and labor, the Surety will pay for the same, in an amount not exceeding the sum specified in this bond, and also, in case suit is brought upon this bond, a reasonable attorney's fee, to be fixed by the Court. This bond shall inure to the benefit of any and all persons, companies or corporations entitled to file claims under Section 3181 of the Civil Code of the State of California, so as to give a right of action to them or their assigns in any suit brought upon this bond. SIGNED, SEALED and DA1 this 24TH day of STATE OF CALIFORNIA ) ) ss.: CITY AND QC+NIY OF SAN DI EGO ) AUGUST , 19 87 E.J. SPRAGUE; JR'i & FRIEDA PALLAS-SPRAGUE (Name / f P in ipal) rt.am On this 24th day August 19 87 , before personally appeared Angie V. Mauricio satisfactory evidence), to be the person who executed the coii,uration therein named and acknowledged to me that the Given under my hand and Notarial Seal this `ty Commission Expires me, the undersigned Notary Public, in and for the State, a person known to me (or proved to me on the basis of written lnstrvmnt as Attorney —in -Fact on behalf of the corporation executed it. 24th day. of OFFICIAL S:AL ANDREA M. CALABRESE NOTARY FU_::C CALIFORN!A PRINCIPAL OFFICE IN SAN D!£GO COUNTY MY Commision Expires March 17, 1989 August A.D. 19 87 tabobt O m. 2aL.b - Notary Public. tO CONTRACT BOND - CITY OF'NATIONAL CITY PAYMENT BOND - PUBLIC WORKS KNOW ALL MEN BY THESE PRESENTS: That we E. J. SPRAGUE, JR. & FRIEDA Of PALLAS-SPRAGUE as Principal, and EXPLORER INSURANCE COMPANY , a Surety authorized to transact surety business in the State of California, as Surety, are held and firmly bound unto the City of National City, as Obligee, in the sum of FOURTEEN THOUSAND NINE HUNDRED NINETY THREE AND NO/100 Dollars ($ $ 14,993.00 ), for the payment whereof, well and truly to be made, said Principal and Surety bind themselves, their heirs, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the condition of the foregoing obligation is such that the above bounden Principal has entered into a contract, dated 19 27, with the Obligee to do and perform the following work, to-wi 1 GRADING, SIDEWALK, RETAINING WALLS, ETC. FOR SPRAGUE EXTENSION NOW, THEREFORE, if the above -bounden Principal or his subcontractors fail to. pay any of the persons named in Section 3181 of the Civil Code of the State of California, or amounts due under the Unemployment Insurance Code with respect to work or labor performed under the contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the contractor and his subcontractors pursuant to Section 13020 of the Unemployment Insurance Code of the State of California, with respect to such work and labor, the Surety will pay for the same, in an amount not exceeding the sum specified in this bond, and also, in case suit is brought upon this bond, a reasonable attorney's fee, to be fixed by the Court. This bond shall inure to the benefit of any and all persons, companies or corporations entitled to file claims under Section 3181 of the Civil Code of the State of California, so as to give a right of action to them or their assigns in any suit brought upon this bond. BOND NO. 02 93 44 SIGNED, SEALED and DA'ri D this 24TH day of AUGUST , 19 87 E..J. SPRAGU-, & FR;IEDA PALLAS-SPRAGUE (Name/Of �G� f�in�3pal) APPROVED AS TO PY G ROWEL EISER, III City Attorney r- EXPLORER INSURANCE COMPANY Surety PY (Atitorney-in-Fadt Angie V. Mauricio '•;`�;' (Attach Notary Acknowledgment'fo Attorney -in -Fact) Address to which notices to Surety should be sent: P.O. Box 85563 San Diego, CA 92138-5563 EX///B/T "Cr/ Explorer Insurance Company HOME OFFICE: SAN DIEGO, CALIFORNIA Certified Copy of POWER OF ATTORNEY - KNOW ALL MEN BY THESE PRESENTS: That the EXPLORER INSURANCE COMPANY, a Corporation duly authorized and existing under the laws of the State of AR IZONA and having its principal office in the City of San Diego, California, does hereby nominate, constitute and appoint: ANGIE V. MAURICIO BETTIE L. GARCIA • its true and lawful Attomeys(sl-in-Fact, with full power and authority hereby conferred in its name, place and steed, to execute, seal, acknowledge and deliver any and all bonds, undertakings, recognizances or other written obligations in the nature thereof. This Power of Attorney is granted and is signed and sealed by facsimile under and by the authority_oi.TheloUowingAesolution.adopted by-the --BdarH oTDire fors of the -EXPLORER INSURANCE COMPANY at a meeting duty called and held on the 22nd day of JULY, 1985, which said Resolution has not been amended or rescinded and of which the following is a true, full, and complete copy: "RESOLVED: That the President or Secretary may from time to time appoint Attorneys -in -Fact to represent and act for and on behalf of the Company, and either the President or Secretary, the Board of Directors or Executive Committee may at any time remove such Attorneys -in - Fact and revoke the Power of Attorney given him or her; and be it further "RESOLVED: That the Attorney -in -fact may be given full power to execute for and in the name of and on behalf of the Company any and bondsjnd stadertakings3s rh• busine..-0f-the-Company-tray require, -and -any -such -bonds orvndertziings execufedby any such --Attorney-in- Fact shall be as binding upon the Company as if signed by the President and sealed and attested by the Secretary." IN WITNESS WHEREOF, EXPLORER INSURANCE COMPANY has caused its official seal to be hereunto affixed and these presents to be signed by its duly authorized officers this 18th day of June, 1986. EXPLORER INSURANCE COMPANY Z1- President STATE OF CALIFORNIA SS, COUNTY OF SAN DIEGO On this June 18, 1986 - before the subscriber, a Notary Public of the State of California, in and for the County of San Diego, duly commissioned and qualified, came D.E.of EXPLORER INSURANCE CQ MPANY to me personally known to be the individual and officer Jr. ficer described in and who executed the preceding instrument, and he acknowledged the execution of the same, and being by me duly sworn, deposeth and saith, that he is the said officer of the Corporation aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of the said Corporation, and that the said Corporate Seal and his signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN WITNESS WHEREOF h and and affixed my Official Seal, at the City of San Diego, the day and year first above written.' OFFICULL SEAL -f NANCY A. FAIRCHILD � "Iv NO:AAY Palle• WLIFORSIA i( /"� !/� /7 //�� ��� %/ /r / tC1;.� .'y PR:NCtPAI OFFICE tsa 1, /' �l / / l / "{ ,� / ( . �cit/�7 f J �� /L / } � F SAN ClESO Cr, JNtY ", jj My Lommissas 6P )cne 2t. SSW / WYlhWea•W WINW: nisi rW W STATE OF CALIFORNIA SS: COUNTY OF SAN DIEGO Notary Public I, the undersigned, James W. Austin III, Secretary of the EXPLORER INSURANCE COMPANY, do hereby certify that the original POWER OF ATTORNEY, of which the foregoing is a full, true and correct copy, is in full force and effect, and has not been revoked. IN WITNESS WHEREOF, I have hereunto subscribed my name as Secretary, and affixed the Corporate Seal of the Corporation, this 24th day of August 19 87 EXPLORER INSURANCE COMPANY (nj Secretary `30' 62.74it G2.04 N '......111141111104/ SCARF. 20 46'-- 3"PVC / p� w I. % 4 O. (dO' h EX/STING ORA NAGE INLET 1 0 TS J 1- 0 444/N /N Al4X. 2. / SLOPE II/1/4/LE S OTI-I RWISE STATED MI SO/ REPORT ALLEY /03 F. 72.00 PROPOSED b SID\\ o \\ tE� FSO GEC Ats ��," EX/ST. 8"SEWE.2� RCPEX/ST K \\ v3 AVENUE 3.3014 r..r t.5 i i F —)x--EJNS i EX/S r 6 "WATEi QW .O e_FY/4T PAIN PLAT day of IMPROVEMENT AGREEMENT FOR FAITHFUL PERFORMANCE OF WORK AND FOR LABOR & MATERIAL THIS AGREEMENT, made and entered into this , 19 57 , by and between the CITY OF NATIONAL CITY, a municipal corporation, hereinafter called "City", and .E.%Siavyae fr f P , D/zgae , hereinafter call "Developer", WITNESSETH: WHEREAS, Developer is about to record or has acquired a Parcel Map to be recorded pursuant to the provisions of ordinances of the City of National City relating to the filing, approval and recordation of Parcel Maps; and WHEREAS, That before said map is finally approved by the City, Developer must either have installed and completed all of the public improvements and/or land development work required by the Code to be installed in subdivisions before final maps of subdivision are approved for purposes of recording in the office of the County Recorder of San Diego County, or as an alternative thereof, that Developer shall enter into an agreement with City, secured by an approved improvement security to insure the performance of said work pursuant to the requirements of ordinances of the City of National City, agreeing at its own expense to install and complete, free of liens, all of the public improvements and/or land development work required in said subdivision within a definite period of time prescribed by said City; and WHEREAS, Developer is willing to enter into this agreement wherein it is provided that Developer will install and complete at its own expense, all the public improvement work required by City in connection with the said Subdivision and will deliver to City an improvement security as approved by the City Attorney; and WHEREAS, Complete Plans and Specifications for the construction, installation and completion of said public improvement work have been prepared, and approved by the City Engineer, as shown on Drawings No. 4338 D office of the City Clerk on �7 Document No. c b and have been filed of record in the J 3 , 19 $7 , a copy of which plans and Specifications is also on file in the office of the City Engineer; and WHEREAS, an estimate of the cost of constructing said public improvements and/or land development according to said Plans and Specifications has been made by the City Engineer and has been approved by City, to which estimate of costs, 10% thereof has been added as required by ordinances of the City of National City for public improvements and/or an amount computed pursuant to the requirements of said ordinances has been added for land development work, which estimate is attached hereto, marked "Exhibit B" and made a part hereof; NOW, THEREFORE, IT IS MUTUALLY UNDERSTOOD AND AGREED AS FOLLOWS: That in consideration of the approval and recordation by the City Council of the Parcel Map of said subdivision, and/or other valuable consideration, Developer expressly herein undertakes and agrees as follows: To comply with all of the requirements of the tentative map resolutions; to do and perform or cause to be done and performed at its own expense, without cost to City, in a good and workmanlike manner, under the direction and to the satisfaction and approval of the City Engineer of City all of the public improvement and/or land development work required to be done in and adjoining said Map and will furnish the necessary materials therefor, all in strict conformity and in accordance with the Plans and Specifications, which document has been heretofore filed in the office of the City Clerk and by reference thereto is incorporated herein and made a part hereof. It is expressly understood and agreed that Developer will cause all necessary materials to be furnished and all improvements required under the provisions of this contract to be done on or before 4.5.9o, 3a, /789 -2- It is also understood and herein expressly agreed to by Developer that in the performance of said work, Developer will conform to and abide by all of the provisions of the ordinances of the City of National City and the laws of the State of California applicable to said work. That if any of the public improvements and/or land development work contemplated by this agreement is to be constructed or installed on land not owned by Developer, no construction or installation shall be commenced thereon prior to the dedication and acceptance by City of appropriate easements or right of way therefor. Developer further agrees that simultaneously with the execution of this agreement, it will furnish and deliver to the City an approved ,0'2 9, 966 (/m wo verve z/s) improvement security in the sum of s/.� 9993 (hi6arI4 /2.) which security shall guarantee the faithful performance of this contract by Developer and is attached hereto marked "Exhibit C" and made a part hereof. It is further agreed that if the public improvements are not completed within the time agreed herein, the sums provided by said improvement security may be used by City for the completion of the public improvements within said subdivision in accordance with specifications contained herein. Upon certification of completion by said City Engineer and acceptance of said work by City and after certification of the City Clerk and City Treasurer that all costs thereof are fully paid, the whole amount, or any balance of said sum not required for payment thereof, may be released to Developer, or its successors in interest pursuant to the terms of the improvement security. It is also agreed and understood by the parties to this agreement that in no case will the City of National City or any Department, Board or Officer thereof be liable for any portion of the costs and expenses of the work aforesaid nor shall any officer, or his sureties or bondsmen be liable for the payment of any sum or sums for the above -mentioned work of any materials furnished therefor. -3- Provided, however, that this shall not preclude City from entering into agreements with Developer for the apportionment of costs of water and sewer mains pursuant to the provisions of the ordinances of National City providing therefor, nor shall anything herein stated commit City to any such apportionment. It is further understood and agreed by Developer that any engineering costs (including plan checking, inspection, materials furnished and other incidental expenses) incurred by City in connection with the preparation of the improvement plans and the installation of the public improvements hereinabove provided for, shall be paid by Developer and Developer shall deposit with City a sum of money equal to 3% of the costs of the improvements, approved by the City Engineer. In ascertaining the amount of such costs incurred by City, the cost report of the City Clerk and City Treasurer shall be prima facie evidence of the true cost of the engineering services so performed by City. It is understood and agreed that until such time as all improvements are fully completed and accepted by City, Developer will be responsible for the care, maintenance of and any damage to the streets, alleys, easements, water and sewer lines within the proposed subdivision. That upon acceptance of the work on behalf of City, Developer shall grant to City by appropriate conveyance, the improvements constructed pursuant to this agreement. The acceptance of the work on behalf of City shall be made by City Manager upon the authorization of the City Council. Such acceptance shall not constitute a waiver of defects by City. It is understood and agreed that City shall not, or any officer or employee thereof, be liable for any injury to person or property occasioned by reason of the acts or omissions of Developer, his agents or employees in the performance of this agreement. Developer further agrees to protect and -4- hold harmless City, its officers and employees from any and all claims, demands, causes of action, liability or loss of any sort, because of or arising out of the acts or omissions of Developer, his agents, or employees in the approved improvement security shall not be required to cover the provisions of this paragraph. In the event that suit is brought upon this contract by City to enforce the terms hereof, City shall be entitled to a reasonable sum as attorney's fees. IN WITNESS WHEREOF, City has caused this agreement to be executed by having affixed thereto the signature of an authorized City Representative and Developer has caused this agreement to be executed, as duly authorized, the day and year first hereinabove written. -5- STATE OF CALIFORNIA) AUNTY OF SAN DIEGO) ss COUNT THIS DAY OF , 19 BE " E HE UNDERSIGNED, A NOTARY PUBLIC IN ANDDD F SAID D STATE, PERSONALLY APPEARED AND TO BE THE P -SNS WHOSE NAMES ARE SU:. RIBED TO THE WITHIN INSTRUM AND ACKNOWLEDG = TO ME THAT THEY EXECUTED THE SAME. ill WITNESS WHEREOF, I H. HEREUNTO SET MY HAND AND AFFIXED MY NOTARIAL S DAY AND YEAR IN THIS CERTIFICATE FIRST ''i E WRITT BY JN TO ME MY CO • SION EXPIRES: NOTARY PUBLIC IN AND FO SAID 'r,NTY AND STATE /243 A.l0000 %9r've Sow Dieya CA 92/07 Developer's Address THE CITY OF NATIONAL CITY S`iyn4/lire s a/1De ve/oper-s veri;<i`ed 6y:, TOM G. McCABE CITY MANAGER ESTIMATED COMPLETION DATE: Sep.30, /9B8 Sf rivw / Eay, ((/59 224615i Developer's Telephone No. IMPROVEMENT SECURITY FOR Subdivision Improvements: 1. Faithful Performance of Improvement Agreement. Cash: Form of: Sofia/ Trust & Agency $ Amount: 'r29 9426 °a 2. Labor and Material for Improvement Form of: 80/70' Amount: ' /4" 993 °I' Receipt No. Agreement. Cash: Trust & Agency $ Receipt No. -6- P gpRVE ING „, ENGINEERING August 13, 1987 KAPPA Surveying & Engineering, Inc. 8392 Lemon Avenue, Suite B La Mesa, California 92041 (619) 465.8948 Project: Grading Plan -Case File No. LS-8-86 Job No. 694-14285 ITEM QUANTITY UNIT Sidewalk 1485 SF Retaining Walls 366 SF Pedestrian Ramp 1 EA Driveway Openings 3 EA Grading -excavation 1220 CY Grading -export 700 CY Sidewalk Underdrains 6 EA Catchbasins 6 EA 3" PVC 276 LF Monumentation LS UNIT PRICE $ 2.70 16.50 600.00 925.00 3.00 7.50 280.00 121.00 6.00 COST $4,010.00 6,039.00 600.00 2,775.00 3,360.00 5,250.00 1,680.00 726.00 1,656.00 1,164.00 SUB -TOTAL $27,260.00 #/ , % Cemn4i29eocie 2,724. Co %o/o/ "129; 986.o0 CIVIL ENGINEERING • LAND PLANNING • SURVEYING EXHIBIT 'B"