Loading...
HomeMy WebLinkAboutCC RESO 14,857RESOLUTION NO. 14,857 A RESOLUTION AUTHORIZING THE CITY MANAGER TO ENTER INTO AN AGREEMENT WITH PWNA ENGINEERS FOR CIVIC CENTER HVAC SYSTEM, ROOF AND CANOPY WHEREAS, the approved capital improvement budget for FY 1984-85 provided funding for the city to obtain professional services to upgrade the heating, ventilating and air conditioning (HVAC) system for the Civic Center; and WHEREAS, it has been determined that it would be beneficial to include a roof and canopy as part of the HVAC system; and WHEREAS, city staff has determined that the firm of PWNA ENGINEERS is best qualified to undertake the project in accordance with the conditions set forth in the request for proposal. NOW, THEREFORE, BE IT RESOLVED by the City Council of the City of National City that the City Manager is hereby authorized to enter into an agreement with PWNA ENGINEERS for the HVAC system, roof and canopy for the Civic Center. PASSED and ADOPTED this 28th day of January, 1986. ATTEST: Ior►� Campbell, City erk t APPROVED AS TO FORM: George H. Eiser, III City Attorney 111111I//.IA I WV I®I% RECE1Vcp EPr1i`= E,�11,r`DEPT CIVIL MECHANICAL ELECTRICAL ENGINEERS ;988 JAN 31 P3 1: 15 HATIOH F 1' A. L TY, : . �.I R A TRANSMITTAL 1493 Jerry Stafford City of National City 1243 National City Boulevard National City, California 92050 Project: HVAC AND ROOFING REPAIR FOR NATIONAL CITY CIVIC CENTER Subject: Agreement I have enclosed the original agreement with modifications 1 through 15 initialled. Please execute and return the agreement to our office. We will proceed with the construction documents on receipt of the completed agreement. Lyle E. Willis PE President rm Enclosures FIRST CLASS MAIL 30 January 1986 7175 CONSTRUCTION COURT SUITE A SAN DIEGO, CALIFORNIA 92121-2690 (619) 578-5910 THE AMERICAN INSTITUTE OF ARCHITECTS BIM AIA Document B141 Standard Form of Agreement Between Owner and Architect 1977 EDITION THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY 15 ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION AGREEMENT Z ts-ctk made as of the 4*tir Hundred and Eighty-six day of JANUARY in the year of Nineteen BETWEEN the Owner: NATIONAL CITY and the Architect: PWNA For the following Project: (Inc`cfde detailed description of Project location and scope.) Repair and Replace HVAC Systemsl; National City Administration Building, 1243 National City Bcuievard, National. City, . California Ep u4ov al cw.a /Le egAmam't- O-C n�X is OC CRAA6pi-6. \- 'A ���� /too1MDf.' The Owner and the Architect agree as set forth below. Amo-SaLA 0sin s4 ti-ux-41-0°1n 144ec.0 LMic fLQLu�W`0.� Copyright 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, CO 1977 by The American Institute of Architects, 1735 New York Avenue, N.W., Washington, D.C. 20006. Reproduction of the material herein or substantial quotation of its provisions without permission of the AIA violates the copyright laws of the United States and will be subject to legal prosecution. AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA® • © 1977 THE AMERICAN INSTITUTE Of ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 B141-1977 1 contractors or any other persons performing any of the Work, or for the failure of any of them to carry out the Work in accordance with the Contract Documents. 1.5.6 The Architect shall at all times have access to the Work wherever it is in preparation or progress. 1.5.7 The Architect shall determine the amounts owing to the Contractor based on observations at the site and on evaluations of the Contractor's Applications for Pay -n C_ • constitute a representation by the Architect to the Own , based on the Architect's observations at the site as • o- vided in Subparagraph 1.5.4 and on the data compr'-ing the Contractor's Application for Payment, that the ork has progressed to the point indicated; that, to the est of the Architect's knowledge, information and belief, t e qual- ity of the Work is in accordance with the Contr. t Docu- ments (subject to an evaluation of the Wor for con- formance with the Contract Documents upon .ubstantial Completion, to the results of any subsequ t tests re- quired by or performed under the Contrac Documents, to minor deviations from the Contract Dcuments cor- rectable prior to completion, and to any s. -cific qualifica- tions stated in the Certificate for Payme' ); and that the Contractor is entitled to payment in the .mount certified. However, the issuance of a Certificat- for Payment shall not be a representation that the Arc sect has made any examination to ascertain how and f r what purpose e Contractor has used the moneys p d on account of Contract Sum. 0 1.5.9 The Architect shall be t - interpreter of the fe- quirements of the Contract Do' ments and the judge of the performance thereunder •y both the Owner and Contractor. The Architect sha' render interpretations nec- essary for the proper execu on or progress of the Work with reasonable promptne•. on written request of either the Owner or the Contrac • r, and shall render written de- cisions, within a reasonable time, on all claims, dispute% and other matters in qu tion between the Owner and the Contractor relating to he execution or progress of the Work or the interpre .tion of the Contract Documents. 1.5.10 Interpretatis and decisions of the Architect shall be consistent with he intent of and reasonably inferable from the Contrac Documents and shall be in written or graphic form, i the capacity of interpreter and judge, the Architect shall endeavor to secure faithful perform- ance by both he Owner and the Contractor, shall not show pa tiali / to either and shall not be liable for the .result of anq interpretation or decision rendered in good faith in su i capacity. 1.5.11 T e Architect's decisions in matters relating to artistic = ect shall be final if consistent with the intent of the C. tract Documents. The Architect's decisions on any o er claims, disputes or other matters, including thos in question between the Owner and the Contractor, sha be subject to arbitration as provided in this Agree- m t and in the Contract Documents. .12 The Architect shall have authority to reject Work hich does not conform to the Contract Documents. .,, J.; hl f-. tL :...pl_..._. t t:_.. ill of the Cont act Documents, the Architect ity to requ re special inspect' accordance with ments, - o author- ing of the Work in fi- sions of the Contract Docu- not such Work be then fabricated, in- p& 1.5.13 The Architect shall review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for conformance with the design concept of the Work and with the information given in the Contract Documents. Such action shall be taken with reasonable promptness so as to cause no delay. The Architect's ap- proval of a specific item shall not indicate approval of an assembly of which the item is a component. i.5.14 The Architect shall prepare Change Orders for the Owner's approval and execution in accordance with the Contract Documents,- ' ' " 'rr - ra- "-- c t' a `hia-'c rot :- e' g an adjustment 0 tcne'.t a` t'-e ca-t ,9Eiiv 1.5.15 The Architect shall conduct inspections to deter- mine the Dates of Substantial Completion and final com- pletion, shall receive and forward to th4 Owner for the Owner's review written warranties and related docu nts required by the Contract Documents and assen by the Contractor, and shall •if•a a final Certificate ment. ?u. eavnrl.+utot-ri 1.5.16 The extent of the dutes, responsibilities lim- itations of authority of the Architect as the Owner's rep- resentative during construction shall not be modified or extended without written consent of the Owner, the Con- tractor and the Architect. 1.6 PROJECT REPRESENTATION BEYOND BASIC SERVICES 1.6.1 If the Owner and Architect agree that more ex- tensive representation at the site than is described in Paragraph 1.5 shall be provided, the Architect shall pro- vide one or /more Project Representatives to assist the Architect in carrying out such responsibilities at the site. 1.6.2 Such Project Representatives shall be selected, em- ployed and directed by the Architect, and the Architect shall ;be compensated therefor as mutually agreed be- tween the Owner and the Architect as set forth in an ex- hibit appended to this Agreement, which shall describe the duties, responsibilities and limitations of authority of such Project Representatives. 1.6.3 ' Through the observations by such Project Repre- sentatives, the Architect shall endeavor to provide further protection for the Owner against defects and deficiencies in the Work, but the furnishing of such project representa- tion :hall not modify the rights, responsibilities or obliga- tions of the Architect as described in Paragraph 1.5. 1.7 ADDITIONAL SERVICES The following Services are not included in Basic Services unless so identified in Article 15. They shall be provided if authorized or confirmed in writing by the Owner, and they shall be paid for by the Owner as provided in this Agreement, in addition to the compensation for Basic Services. 4 B141-1977 AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA® • © 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 TERMS AND CONDITIONS OF AGREEMENT BETWEEN OWNER AND ARCHITECT ARTICLE 1 ARCHITECT'S SERVICES AND RESPONSIBILITIES BASIC SERVICES The Architect's Basic Services consist of the five phases described in Paragraphs 1.1 through 1.5 and include normal structural, mechanical and electrical engineering services and any other services included in Article 15 as part of Basic Services. 1. 1 The Architect shall review the program furnished by t - Owner to ascertain therequirements of the Project and s' .II review the understanding of such requirements with th- Owner. 1.1.2 Th Architect shall provide a preliminary evalua- tion of the • ogram and the Project budget requirements, each in term of the other, subject to the limitations set forth in Subpar.graph 3.2.1. 1.1.3 The Architect shall review with the Owner alterna- tive approaches to esign and construction of the Project. 1.1.4 Based on the utually agreed upon program and Project budget require gents, the Architect shall prepare, for approval by the Owner, Schematic Design Documents consisting of drawings an other documents illustrating the scale and relationship o roject components. 1.1.5 The Architect shall subit to the Owner a State- ment of Probable Construction Cost based on current area, volume or other unit costs. 1.2 DESIGN DEVELOPMENT PHASE 1.2.1 Based on the approved Schem tic Design Docu- ments and any adjustments authorized •v the Owner in the program or Project budget, the Arch ect shall pre- pare, for approval by the Owner, Design Development Documents consisting of drawings and other •ocuments to fix and describe the size and character of e entire Project as to architectural, structural, mechanical a elec- trical systems, materials and such other elements may be appropriate. 1.2.2 The Architect shall submit to the Owner a fury 1.3 CONSTRUCTION DOCUMENTS E HASE S ilia 1.3.1 Based on the approved tT �-,e,'04,pma^t Doc- uments and any further adjustments in the scope or qual- ity of the Project or in the Project budget authorized by the Owner, tile Architect shall prepare, for approval by the Owner, Construction Documents consisting of Draw- ings and Specifications setting forth in detail the require- ments for the construction of the Project. 1.3.2 The Architect shall assist the Owner in the prepara- tion of the necessary bidding information, bidding forms, the Conditions of the Contract, and the form of Agree- ment between the Owner and the Contractor. 1.3.3 The Architect shall advise the Owner of any adjust- ments to previous Statements of Probable Construction Cost indicated by changes in requirements or general market conditions. 1.3.4 The Architect shall assist the Owner in connection with the Owner's responsibility for filing documents re- quired for the approval of governmental authorities hav- ing jurisdiction over the Project. 1.4 BIDDING OR NEGOTIATION PHASE 1.4.1 The Architect, following the Owner's approval of the Construction Documents and of the latest Statement of Probable Construction Cost, shall assist the Owner in obtaining bids or negotiated proposals, and assist in awarding and preparing contracts for construction. 1.5 CONSTRUCTION PHASE —ADMINISTRATION OF THE CONSTRUCTION CONTRACT 1.5.1 The Construction Phase will commence with the award of the Contract for Construction and, together with the Architect's obligation to provide Basic Services under this Agreement, will terminate when final payment to the Contractor is due, or in the absence of a final Certificate for Payment or of such due date, sixty days after the Date of Substantial Completion of the Work, whichever occurs first. 1.5.2 Unless otherwise provided in this Agreement and incorporated in the Contract Documents, the Architect shall provide administration of the Contract for Construc- tion as set forth below. — - A I A n .. 291, Se. Cowl ' -__ .w 1.5.3 The Architect shall be a representative of the Owner during the Construction Phase, and shall advise and consult with the Owner. ' ' - -"" c ..,. a tti. ,,Q •I__ A_"'"--... The Archi- tect shall have authority to act on behalf of the Owner only to the extent provided in the Contract Documents unless otherwise modified by written instrument in ac- cordance with Subparagraph 1.5.16. 1.5.4 The Architect shall visit the site at intervals ap- propriate to the stage of construction or as otherwise agreed by the Architect in writing to become generally familiar with the progress and quality of the Work and to determine in general if the Work is proceeding in accord- ance with the Contract Documents. However, the Archi- tect shall not be required to make exhaustive or con- tinuous on -site inspections to check the quality or quan- tity of the Work. On the basis of such on -site observa- tions as an architect, the Architect shall keep the Owner' informed of the progress and quality of the Work, and shall endeavor to guard the Owner against defects and deficiencies in the Work of the Contractor. 1.5.5 The Architect shall not have control or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, for the acts or omissions of the Contractor, Sub- AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIAa' • © 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, NAV., WASHINGTON, D.C. 20006 - B141-1977 3 1.7.1 Providing analyses of the Owner's needs, and pro- gramming the requirements of the Project. 1.7.2 Providing financial feasibility or other special studies. 1.7.3 Providing planning surveys, site evaluations, envi- ronmental studies or comparative studies of prospective sites, and preparing special surveys, studies and submis- sions required for approvals of governmental authorities or others having jurisdiction over the Project. 1.7.4 Providing services relative to future facilities, sys- tems and equipment which are not intended to be con- structed during the Construction Phase. 1.7.5 Providing services to investigate existing conditions or facilities or to make measured drawings thereof, or to verify the accuracy of drawings or other information fur- nished by the Owner. 1.7.6 Preparing documents of alternate, separate or sequential bids or providing extra services in connection with bidding, negotiation or construction prior to the completion of the Construction Documents Phase, when requested by the Owner. 1.7.7 Providing coordination of Work performed by separate contractors or by the Owner's own forces. 1.7.8 Providing services in connection with the work of a construction manager or separate consultants retained by the Owner. 1.7.9 Providing Detailed Estimates of Construction Cost, analyses of owning and operating costs, or detailed quan- tity surveys or inventories of material, equipment and labor. 1.7.10 Providing interior design and other similar ser- vices required for or in connection with the selection, procurement or installation of furniture, furnishings and related equipment. 1.7.11 Providing services for planning tenant or rental spaces. 1.7.12 Making revisions in Drawings, Specifications or other documents when such revisions are inconsistent with written approvals or instructions previously given, are required by the enactment or revision of codes, laws or regulations subsequent to the preparation of such doc- uments or are due to other causes not solely within the control of the Architect. 1.7.13 . Preparing_Drawings, Specifications and supporting data and providing other services in connection with Change Orders to the extent that the, adjustment in the Basic Compensation resulting from the adjusted Con- struction Cost is not commensurate with the services re- quired of the Architect, provided such Change Orders are required by causes not solely within the control of the Architect. 1.7.14 Making investigations, surveys, valuations, inven- tories or detailed appraisals of exist,1g facilities, and serv- ices required in connection with construction performed by the Owner. 1.7.15 Providing consultationconcerning replacement of any Work damaged by fire or other cause during con- struction, and furnishing services as may be required in connection with the replacement of such Work. 1.7.16 Providing services made necessary by the default of the Contractor, or by major defects or deficiencies in the Work of the Contractor, or by failure of performance of either the Owner or Contractor under the Contract for Construction. showing significant changes i - a.e during construction •- -- - .r e.-up prints, drawings and® 1.7.18 Providing extensive assistance in the utilization of any equipment or system such as initial start-up or testing, adjusting and balancing, preparation of operation and maintenance manuals, training personnel for operation and maintenance, and consultation during operation. 1.7.19 Providing services after issuance to the Owner of the final Certificate for Payment, or in the absence of a final Certificate for Payment, more than sixty days after the Date of Substantial Completion of the Work. 1.7.20 Preparing to serve or serving as an expert witness in connection with any public hearing, arbitration pro- ceeding or legal proceeding. 1.7.21 Providing services of consultants for other than the normal architectural, structural, mechanical and elec- trical engineering services for the Project. 1.7.22 Providing any other services not otherwise in- cluded in this Agreement or not customarily furnished in accordance with generally accepted architectural practice. 1.8 TIME 1.8.1 The Architect shall perform Basic and Additional Services as expeditiously as is consistent with professional skill and care and the orderly progress of the Work. Upon request of the Owner, the Architect shall submit for the Owner's approval a schedule for the performance of the Architect's services which shall be adjusted as required as the Project proceeds, and shall include allowances for peri- ods of time required for the Owner's review and approval of submissions and for approvals of authorities having jurisdiction over the Project. This schedule, when approved by the Owner, shall not, except for reasonable cause, be exceeded by the Architect. ARTICLE 2 ThWNER`S, RESPONSIBILITIES requirE„-for the Project ncIu dinga shall set forth the Owner's de and criteria, inclu ships ,ich fives, constraints e requirements and relation - and expandability, special equipment and 2.2 If the Owner provides a budget for the Project it shall include contingencies for bidding, changes in the Work during construction, and other costs which are the responsibility of the Owner, including those described in this Article 2 and in Subparagraph 3.1.2. The Owner shall, at the request of the Architect, provide a statement of funds available for the Project, and their source. AIA DOCUMENT 13141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA® • © 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 B141-1977 5 2.3 The Owner shall designate, when necessary, a rep- resentative authorized to act in the Owner's behalf with respect to the Project. The Owner or such authorized representative shall examine the documents submitted by the Architect and shall render decisions pertaining thereto promptly, to avoid unreasonable delay in the progress of the Architect's services. 2.4 The Owner shall furnish a legal description and a certified land survey of the site, giving, as applicable, grades and lines of streets, alleys, pavements and adjoin- ing property; rights -of -way, restrictions, easements, en- croachments, zoning, deed restrictions, boundaries and contours of the site; locations, dimensions and complete data pertaining to existing buildings, other improvements and trees; and full information concerning available serv- ice and utility lines both public and private, above and below grade, including inverts and depths. 2.5 The Owner shall furnish the services of soil engi- neers or other consultants when such services are deemed necessary by the Architect. Such services shall include test borings, test pits, soil bearing values, percolation tests, air and water pollution tests, ground corrosion and resistivity tests, including necessary operations for determining sub- soil, air and water conditions, with reports and appropri- ate professional recommendations. 2.6 The Owner shall furnish structural, mechanical, chemical and other laboratory tests, inspections and re- ports as required by law or the Contract Documents. 47 TI.c O. At. led' f ...: I, ,.II surance counseling services as may be ne at any time for the Project, including su ding services as the Owner may require t e Contractor's Applica- tions for Paym o ascertain how or for what pur- pose ntractor uses the moneys paid by or on be- quired by Paragraphs 2.4 through 2.7 furnished at the Owner' be entitl e s all be and the Architect shall upon the accuracy and completeness 2.9 If the Owner observes or otherwise becomes aware of any fault or defect in the Project or nonconformance with the Contract Documents, prompt written notice thereof shall be given by the Owner to the Architect. 2.10 The Owner shall furnish required information and services and shall render approvals and decisions as ex- peditiously as necessary for the orderly progress of the Architect's services and of the Work. ARTICLE 3 CONSTRUCTION COST 3.1 DEFINITION 3.1.1 The Construction Cost shall be the total cost or estimated cost to the Owner of all elements of the Project designed or specified by the Architect. 3.1.2 The Construction Cost shall include at current market rates, including a reasonable allowance for over- head and profit, the cost of labor and materials furnished by the Owner and any equipment which has been de- signed, specified, selected or specially provided for by the Architect. 3.1.3 Construction Cost does not include the compen- sation of the Architect and the Architect's consultants, the cost of the land, rights -of -way, or other costs which are the responsibility of the Owner as provided in Arti- cle 2. 3.2 RESPONSIBILITY FOR CONSTRUCTION COST 3.2.1 Evaluations of the Owner's Project budget, State- ments of Probable Construction Cost and Detailed Estimates of Construction Cost, if any, prepared by the Architect, represent the Architect's best judgment as a design professional familiar with the construction indus- try. It is recognized, however, that neither the Architect nor the Owner has control over the cost of labor, mate- rials or equipment, over the Contractor's methods of de- termining bid prices, or over competitive bidding, market '"or negotiating conditions. Accordingly, the Architect cannot and does not warrant or represent that bids or negotiated prices will not vary from the Project budget proposed, established or approved by the Owner, if any, or from any Statement of Probable Construction Cost or other cost estimate or evaluation prepared by the Archi- tect. 3.2.2 No fixed limit of Construction Cost shall be estab- lished as a condition of this Agreement by the furnishing, proposal or establishment of a Project budget under Sub- paragraph 1.1.2 or Paragraph 2.2 or otherwise, unless such fixed limit has been agreed upon in writing and signed by he parties hereto. If such a fixed limit has been estab- lished, the Architect shall be permitted to include con- tingencies for design, bidding and price escalation, to de- termine what materials, equipment, component systems and types of construction are to be included in the Con- tract Documents, to make reasonable adjustments in the scope of the Project and to include in the Contract Docu- ments alternate bids to adjust the Construction Cost to the fixed limit. Any such fixed limit shall be increased in the amount of any increase in the Contract Sum occurring after execution of the Contract for Construction. 3.2.3 If the Bidding or Negotiation Phase has not com- menced within three months after the Architect submits the Construction Documents to the Owner, any Project budget or fixed limit of Construction Cost shall be ad- justed to reflect any change in the general level of prices in the construction industry hetween the date of submis- sion of the Construction Documents to the Owner and the ds.te on which !jroposals are sough.. 3.2.4 If a Projec. budget or fixed limit of Cc.astruction Cost (adjusted as provided in Subparagraph 3.2.3) is ex- ceeded by the lowest bona fide bid or negotiated pro- posal, the Owner shall (1) give written approval of an increase in such fixed limit, (2) authorize rebidding or re- negotiating of the Project within a reasonable time, (3) if the Project is abandoned, terminate in accordance with Paragraph 10.2, or (4) cooperate in revising the Project scope and quality as required to reduce the Construction Cost. In the case of (4), provided a fixed limit of Construc- tion Cost has been established as a condition of this Agree- ment, the Architect, without additional charge, shall mod- ify the Drawings and Specifications as necessary to comply AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA® • © 1977 6 B141-1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.Q' 20006 with the fixed limit. The providing of such service shall be the limit of the Architect's responsibility arising from the establishment of such fixed limit, and having done so, the Architect shall be entitled to compensation for all services performed, in accordance with this Agreement, whether or not the Construction Phase is commenced. ARTICLE 4 DIRECT PERSONNEL EXPENSE 4.1 Direct Personnel Expense is defined as the direct sal- aries of all the Architect's personnel engaged on the Proj- ect, and the portion of the cost of their mandatory and customary contributions and benefits related thereto, such as employment taxes and other statutory employee bene- fits, insurance, sick leave, holidays, vacations, pensions and similar contributions and benefits. ARTICLE 5 REIMBURSABLE EXPENSES 5.1 Reimbursable Expenses are in addition to the Com- pensation for Basic and Additional Services and include actual expenditures made by the Architect and the Archi- tect's employees and consultants in the interest of the Project for the expenses listed in the following Sub- paragraphs: 5.1.1 Expense of transportation in connection with the Project; living expenses in connection with out-of-town travel; long distance communications; and fees paid for securing approval of authorities having jurisdiction over the Project. 5.1.2 Expense of reproductions, postage and handling of Drawings, Specifications and other documents, excluding reproductions for the office use of the Architect and the Architect's consultants. 5.1.3 Expense of data processing and photographic pro- duction techniques when used in connection with Addi- tional Services. 5.1.4 If authorized in advance by the Owner, expense of overtime work requiring higher than regular rates. 5.1.5 Expense of renderings, models and mock-ups re- quested by the Owner. 5.1.6 Expense of any 'additional insurance coverage or limits, including professional liability insurance, requested by the Owner in excess of that normally carried by the Architect and the Architect's consultants. ARTICLE 6 PAYMENTS TO THE ARCHITECT 6.1 PAYMENTS ON ACCOUNT OF BASIC SERVICES 6.1.1 An initial payment as set forth in Paragraph 14.1 is the minimum payment under this Agreement. 6.1.2 Subsequent payments for Basic Services shall be made monthly and shall be in proportion to services per- formed within each Phase of services, on the basis set forth in Article 14. 6.1.3 If and to the extent that the Contract Time initially established in the Contract for Construction is exceeded or extended through no fault of The Arctiitect, compensa- tion tor any Basic Services required for such extended period of Administration of the Construction Contract shall be computed as set forth in Paragraph 14.4 for Addi- tional Services. Con ction Cost, and any portions of the Project are deleted or erwise not constructed, compensation for such portions o - Project shall be payable to the extent services are performe. : • such portions, in accordance with the schedule set forth in ...aragraph 14.2.2, based on (1) the lowest bona fide bid or n--c iated proposal or, (2) if no such bid 'or proposal is received, ost recent Statement of Probable Construction Cost or Detai ' Esti- 6.2 PAYMENTS ON ACCOUNT OF ADDITIONAL SERVICES 6.2.1 Payments on account of the Architect's Additional Services as defined in Paragraph 1.7 and for Reimbursable Expenses as defined in Article 5 shall be made monthly upon presentation of the Architect's statement of services rendered or expenses incurred. 6.3 PAYMENTS WITHHELD 6.3.1 No deductions shall be made from the Architect's compensation on account of penalty, liquidated damages or other sums withheld from payments to contractors, or on account of the cost of changes in the Work other than those for which;the Architect is held legally liable. 6.4 PROJECT SUSPENSION OR TERMINATION 6.4.1 If the Project is suspended or abandoned in whole or in part for more than three months, the Architect shall be compensated for all services performed prior to receipt of written notice from the Owner of such suspension or abandonment, together with Reimbursable Expenses then due and all Termination Expenses as defined in Paragraph 10.4. If the Project is resumed after being suspended for more than three months, the Architect's compensation shall be equitably adjusted. ARTICLE 7 ARCHITECT'S ACCOUNTING RECORDS 7:1 Records -of Reimbursable Expenses and -expenses per- taining to Additional Services and services performed on the basis of a Multiple of Direct Personnel Expense shall be kept on the basis of generally accepted accounting principles andshall be available to the Owner or the Owner's authorized representative at mutually convenient times. ARTICLE 8 OWNERSHIP AND USE OF DOCUMENTS Prawn and Specificati ns as instrumcnts f scr'' ice ar- ..d shall remain the property of the Architect whether the .'- t for which they are made is executed or not. The Owner s ermitted to retain copies, in- cluding reproducible copies, Irawings and Specifica- tions for information and reference in . - • •ction with the Owner's use and occupancy of the Project. • .wings and Specificat, ns shall n t be ::,cd b, the wncr • AIA DOCUMENT 8141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA® • © 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 .?141-.1977 7 tion of t is ' , others provided the Architect is not in default under this Agre -xcept by agreement in writing and with appropriate compensa I. o . - Archi- • e rni9aal e••e. l.:b 'requirements or forother pur.. c ion with the Project is n. • - - ueas publication in derogation ARTICLE 9 9.• ATI claims, disputes and other matters in question 'bet • een the parties to this Agreement; -arising out of or relate 'g to this Agreement or the breach thereof, shall be decideby arbitration in accordance with the Construc- tion In..stry Arbitration Rules of the American Arbitra- tion Asso 'ation then obtaining unless the parties mutu- ally agree o. erwise. No arbitration, arising out of or re- lating to this greement, shall include, by consolidation, joinder or in a other manner, any additional person not a party to this A: eement except by written consent con- taining a specific reference to this Agreement and signed by the Architect, the Owner, and any other person sought to be joined. Any co ent to arbitration involving an ad- ditional person or pers• s shall not constitute consent to arbitration of any disput- not described therein or with any person not named or 'escribed therein. This Agree- ment to arbitrate and any a: eement to arbitrate with an additional person or persons .uly consented to by the parties to this Agreement shall • - specifically enforceable under the prevailing arbitration la 9.2 Notice of the demand for arbit .tion shall be filed in writing with the other party to this :reement and with the American Arbitration Association. ` he demand shall be made within a reasonable time after t e claim, dispute or other matter in question has arisen. In o event shall the demand for arbitration be made after t' - date when institution of legal or equitable proceeding • based on such claim, dispute or other matter in question ould be barred by the applicable statute of limitations. 9.3 The award rendered by the arbitrators shall b- final, and judgment may be entered upon it in accordance ith ajei•j.Ii,._r.l_ I... > i ti f ARTICLE 10 TERMINATION OF AGREEMENT 10.1 ThisAgreement may be terminated by either party upon seven days' written notice should the other party fail substantially to perform in accordance with its terms through no fault of the party initiating the termination. 10.2 This Agreement may be terminated by the Owner upon at least seven days' written -notice-to' the Architect in the event that the Project is permanently abandoned. 10.3 In the event of termination not the fault of the Ar- chitect, the Architect shall be compensated for al! services performed to termination date, together with Reimburs- able Expenses -then due and all Termination Expenses as defined in Paragraph 10.4. 10.4 Termination Expenses include expenses directly at- tributable to termination for which the Architect is not otherwise compensated, plus an amount computed as a percentage of the total Basic and Additional Compensa- tion earned to the time of termination, as follows: .1 20 percent if termination occurs during the Sche- matic Design Phase; or .2 10 percent if termination occurs during the Design Development Phase; or .3 5 percent if termination occurs during any subse- quent phase. ARTICLE 11 MISCELLANEOUS PROVISIONS 11.1 Unless otherwise specified, this Agreement shall be governed by the law of the principal place of business of the Architect. ing as those in AIA Document A201, General Conditi of the Contract for Construction, current as of th- .ate of this Agreement. 11.3 As between the parties to this Agreeme• as to all acts or failures to act by either party to ' Agreement, any applicable statute of limitations shcommence to run and any alleged cause of action all be deemed to have accrued in any and all events r •t later than the rele- vant Date of Substantial Compl• •n of the Work, and as to any acts or failures to act curring after the relevant Date of Substantial Compl- .n, not later than the date d issuance of the final Cer ' cate for Payment. �a 11.4 The Owner . : the Architect waive all rig is against each othe .nd against the contractors, consult- ants, agents an. -mployees of the other for damages cov- ered by any • .perty insurance during construction as set forth in th• edition of AIA Document A201, General Con- ditions ' urrent as of the date of this Agreement. The Ow - and the Architect each shall require appropriate si ar waivers from their contractors, consultants and ARTICLE 12 SUCCESSORS AND ASSIGNS 12.1 The Owner and the Architect, respectively, bind themselves, their partners, successors, assigns and legal representatives to the other party to this Agreement and to the partners, successors, assigns and legal representa- tives of such other party with respect to all covenants of this Agreement. Neither the Owner nor the Architect shall assign, sublet or transfer any interest in this Agreement without the written consent of the other. ARTICLE 13 EXTENT OF AGREEMENT 13.1 This Agreement represents the entire and integrated agreement between the Owner and the Architect and supersedes all prior negotiations, representations or agree- ments, either written or oral. This Agreement may be amended only by written instrument signed by both Owner and Architect. AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA®• © 1977 8 B141-1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 ARTICLE 14 BASIS OF COMPENSATION The Owner shall compensate the Architect for the Scope of Services provided, in accord tnce with Article 6, Payments to the Architect, and the other Terms and Conditions of this Agreement, as follows: 14.1 AN INITIAL PAYMENT of ZERO dollars ($ 0 shall be made upon execution of this Agreement and credited to the Owner's account as follows: 14.2 BASIC COMPENSATION 14.2.1 FOR BASIC SERVICES, as described in Paragraphs 1.1 through 1.5, and any other services included in Article 15 as part of Basic Services, Basic Compensation shall be computed as follows: (Here insert basis of compensation, including fixed amounts, multiples or percentages, and identify Phases to which particular methods of compensa- tion apply, if necessary.) 1. Upon completion at Preliminary Construction Document Submittal: $18,700. 2. Upon completion of Construction Documents Submittal: $10,080. 3. Upon completion of Bidding Phase: $ 1,450. 4. Through completion of the Construction Phase: Monthly as invoiced and not to exceed: $ 4,350. 11. 4 Wlacrc eompeosat-i n is based -ea a Stipulated Sum r Percentage of Coos4euetion Cgs payments f F Basic vices shall be made as provided in Subparagraph 6.1.2, so that Basic Compensation for each Phase shall equa following percentages of the total Basic Compensation payable: (Include any additiona - es as appropriate.) Schematic Design Phase: Design Development Phase: Construction Documents Phase: Bidding or Negotiation Phase: Construction Phase: percent ( %) percent ( %) percent ( %) percent ( %) percent( %) 14.3 FOR PROJECT REPRESENTATION BEYOND BASIC SERVICES, as described in Paragraph 1.6, Compensation shall be computed separately in accordance with Subparagraph 1.6.2. AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • jULY 1977 • AIA® • © 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 B141-1977 9 14.4 COMPENSATION FOR ADDITIONAL SERVICES 14.4.1 FOR ADDITIONAL SERVICES OF THE ARCHITECT, as described in Paragraph 1.7, and any other services in- cluded in Article 15 as part of Additional Services, but excluding Additional Services of consultants, Compen- sation shall be computed as follows: (Here insert basis of compensation, including rates and/or multiples of Direct Personnel Expense for Principals and employees, and identify Principals and classify employees, if require°. Identify specific services to which particular methods of compensation apply, if necessary.) Principal: $ 75/Hr. All other employees: 2.5 multiplier times direct personnel expense. 14.4.2 FOR ADDITIONAL SERVICES OF CONSULTANTS, including additional structural, mechanical and electrical engineering services and those provided under Subparagraph 1.7.21 or identified in Article 15 as part of Addi- tional Services, a multiple of 1.15 ) times the amounts billed to the Architect for such services. (Identify specific types of consultants in Article 15, if required.) 14.5 FOR REIMBURSABLE EXPENSES, as described in Article 5, and any other items included in Article 15 as Reim- bursable Expenses, a multiple of 7 1.15 "" 7' times the amounts ex- pended by the Architect, the Architect's employees and consultants in the interest of the Project. 14.6 Payments due the Architect and unpaid under this Agreement shall bear interest from the date payment is due at the rate entered below, or in the absence thereof, at the legal rate prevailing at the principal place of business of the Architect. (Here insert any rate of interest agreed upon.) r 'Usury laws and requirements under the Federal Tvth in lending Act, similar state and local consumer credit laws and other regulations at the Owner's and Architect's principal places of business, thedocation of the Project and elsewhere may affect the validity of this provision. Specific legal advice should he obtained with respect to deletion, modification, or other requirements such as written disclosures or waivers.) 14.7 The Owner and the Architect agree in accordance with the Terms and Conditions of this Agreement that: 14.7.1 IF THE SCOPE of the Project or of the Architect's Services is changed materially, the amounts of compensation shall be equitably adjusted. 14.7.2 IF THE SERVICES covered by this Agreement have nbt been completed -within Si X 6 ) months of the date hereof, through no fault of the Architect, the amounts of compensation, rates and multiples set forth herein shall be equitably adjusted. .AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • MA® • © 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 10 B141-1977 ARTICLE 15 OTHER CONDITIONS OR SERVICES 1. The scope of remedial work required will be based on the recommendations provided in the project report dated 16 October 1985 and as amended by the City of National City Review comments. 2. Construction Administration Requirements shall consist of review of shop drawings, submittals and as -built drawings and periodic construction observation. 3. The following items are indentifi.ed as extra services: Reproduction Costs Building Permit Cost Structural Engineering Consultants(Structural Engineering Consultants are not anticipated for this project) 4. Period of Service: Provide Preliminary Construction Documents Submittal (approx. 65% completion) within 60 calendar days following Notice to Proceed. Provide Final Construction Documents Submittal within 90 calendar days following Notice to Proceed. 1�.c..e yi et se.4- .a o dEA.e. lA f - J 01n a w S�nDwwla slaryl �aN�- Ckalttes i4A -i-k Wotk made ciwr 's c yt s4 n u.(-s-. (base d a i wLan._fkect ./A-p d n e, w Ct s aktc ' LMAdd w ei Ut -e Ale),,14-C2-A. lo-: A e AIA DOCUMENT B141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA® • © 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK. AVENUE, N.W., WASHINGTON, D.C. 20006 B141.1977 11 This Agreement entered into as of the day and year first written above. OWNER ARCHITECT NATIONAL CITY PWNA 2100 Hoover BY 7175 Constrvcti;in Cort, 'an Diego, Ca. BY ti �. ,'.-„ Joseph P. Paoiuccio AIA,PE 12 B141-1977 AIA DOCUMENT 5741 • OWNER -ARCH TECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA • ® 1977 THE AMERICAN INSTITUTE OF .ARCHITFCTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006