Loading...
HomeMy WebLinkAboutCC RESO 14,794RESOLUTION NO. 14,794 RESOLUTION AUTHORIZING EXECUTION OF AN AGREEMENT BETWEEN THE CITY OF NATIONAL CITY AND RICHARD GEORGE WHEELER AND W. GAYNE WIMER, ARCHITECTS, INC. FOR AE SERVICES FOR LAS PALMAS GYM BE IT RESOLVED by the City Council of the City of National City, California, that the City Manager is hereby authorized to execute an Agreement between the City of National City and Richard George Wheeler and W. Gayne Wimer, Architects, Incorporated, for Architectural Services for a new gymnasium and auxiliary facilities located at the southeast corner of Las Palmas Park in the City of National City, California. PASSED and ADOPTED this 19th day of November, 85. Kil Morgan, ayor ATTEST: IONE CAIGBELL Ione mpbell, City Clerk BY: -I-, el al._ APPROVED AS TO FORM UO THE AMERICAN INSTITUTE OF ARCHITECTS AIA Document B141 Standard Form of Agreement Between Owner and Architect 1977 EDITION THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY 1S ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION AGREEMENT made as of the FOURTH day of NOVEMBER in the year of Nineteen Hundred and EIGHTY—FIVE BETWEEN the Owner: CITY OF NATIONAL CITY 1243 NATIONAL CITY BOULEVARD NATIONAL CITY, CA; 92050 and the Architect: RICHARD GEORGE WHEELER AND W. GAYNE WIMER, ARCHITECTS; A CALIFORNIA CORPORATION For the following Project: (Include detailed description of Project location and scope.) A NEW GYMNASIUM AND AUXILIARY FACILITIES LOCATED AT THE SOUTHEAST CORNER OF LAS PALMAS PARK. The Owner and the Architect agree as set forth below. Copyright 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963. 1966, 1%7, 1970, 1974, © 1977 by The American Institute of Architects, 1735 New York Avenue, N.W., Washington, D.C. 2I1006. Reproduction of the material herein or substantial quotation of its provisions without permission of the AM violates the copyright laws of the United States and will be subject to legal prosecution. AIA DOCUMENT 8141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IULY 1977 • AIA• • 01977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, O.C. 20006 B141-1977 1 • (This Page Is Blank) 2 TERMS AND CONDITIONS OF AGREEMENT BETWEEN OWNER AND ARCHITECT ARTICLE 1 ARCHITECT'S SERVICES AND RESPONSIBILITIES BASIC SERVICES The Architect's Basic Services consist of the five phases described in Paragraphs 1.1 through 1.5 and include normal structural, mechanical and electrical engineering services and any other services included in Article 15 as part of Basic Services. 1.1 SCHEMATIC DESIGN PHASE rchitect shall review the pro fro)by the Owne • . - • • . nts of the Project and shalt 1 •ersta - •uirements e •wner. 1.1.2 The Architect shall provide a preliminary evalua- tion of the program and the Project budget requirements, each in terms of the other, subject to the limitations set forth in Subparagraph 3.2.1. 1.1.3 The Architect shall review with the Owner altema- tive approaches to design and construction of the Project. 1.1.4 Based on the mutually agreed upon program and Project budget requirements, the Architect shall prepare, for approval by the Owner, Schematic Design Documents consisting of drawings and other documents illustrating the scale and relationship of Project components. 1.1.5 The Architect shall submit to the Owner a State- ment of Probable Construction Cost based on current area, volume or other unit costs. 1.2 DESIGN DEVELOPMENT PHASE 1.2.1 Based on the approved Schematic Design Docu- ments and any adjustments authorized by the Owner in the program or Project budget, the Architect shall pre- pare, for approval by the Owner, Design Development Documents consisting of drawings and other documents to fix and describe the size and character of the entire Project as to architectural, structural, mechanical and elec- trical systems, materials and such other elements as may be appropriate. 1.2.2 The Architect shall submit to the Owner a further Statement of Probable Construction Cost. 1.3 CONSTRUCTION DOCUMENTS PHASE 1.3.1 Based on the approved Design Development Doc- uments and any further adjustments in the scope or qual- ity of the Project or in the Project budget authorized by the Owner, the Architect shall prepare, for approval by the Owner, Construction Documents consisting of Draw- ings and Specifications setting forth in detail the require- ments for the construction of the Project. 1.3.2 The Architect shall assist the Owner in the prepara- tion of the necessary bidding information, bidding forms, the Conditions of the Contract, and the form of Agree- ment between the Owner and the Contractor. 1.3.3 The Architect shall advise the Owner of any adjust- ments to previous Statements of Probable Construction Cost indicated by changes in requirements or general market conditions. 1.3.4 The Architect shall assist the Owner in connection with the Owner's responsibility for filing documents re- quired for the approval of governmental authorities hav- ing jurisdiction over the Project. 1.4 BIDDING OR NEGOTIATION PHASE 1.4.1 The Architect, following the Owner's approval of the Construction Documents and of the latest Statement of Probable Construction Cost, shall assist the Owner in obtaining bids or negotiated proposals, and assist in awarding and preparing contracts for construction. 15 CONSTRUCTION PHASE —ADMINISTRATION OF THE CONSTRUCTION CONTRACT 1.5.1 The Construction Phase will commence with the award of the Contract for Construction and, together with the Architect's obligation to provide Basic Services under this Agreement, will terminate when final payment to the Contractor is due, or in the absence of a final Certificate for Payment or of such due date, sixty days after the Date of Substantial Completion of the Work, whichever occurs first. 15.2 Unless otherwise provided in this Agreement and incorporated in the Contract Documents, the Architect shall provide administration of the Contract for Construc- tion as set forth below and in the edition of AIA Docu- ment A201, General Conditions of the Contract for Con- struction, current as of the date of this Agreement. 1.5.3 The Architect shall be a representative of the Owner during the Construction Phase, and shall advise and consult with the Owner. Instructions to the Contrac- tor shall be forwarded through the Architect. The Archi- tect shall have authority to act on behalf of the Owner only to the extent provided in the Contract Documents unless otherwise modified by written instrument in ac- cordance with Subparagraph 1.5.16. 1.5.4 The Architect shall visit the site at intervals ap- propriate to the stage of construction or as otherwise agreed by the Architect in writing to become generally familiar with the progress and quality of the Work and to determine in general if the Work is proceeding in accord- ance with the Contract Documents. However, the Archi- tect shall not be required to make exhaustive or con- tinuous on -site inspections to check the quality or quan- tity of the Work. On the basis of such on -site observa- tions as an architect, the Architect shall keep the Owner informed of the progress and quality of the Work, and shall endeavor to guard the Owner against defects and deficiencies in the Work of the Contractor. 1.5.5 The Architect shall not have control or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, for the acts or omissions of the Contractor, Sub- AIA DOCUMENT 1141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIM • 01977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20036 B141-1977 3 contractors or any other persons performing any of the Work, or for the failure of any of them to carry out the Work in accordance with the Contract Documents. 15.6 The Architect shall at all times have access to the Work wherever it is in preparation or progress. 15.7 The Architect shall determine the amounts owing to the Contractor based on observations at the site and on evaluations of the Contractor's Applications for Payment, and shall issue Certificates for Payment in such amounts, as provided in the Contract Documents. 15.8 The issuance of a Certificate for Payment shall constitute a representation by the Architect to the Owner, based on the Architect's observations at the site as pro- vided in Subparagraph 1.5.4 and on the data comprising the Contractor's Application for Payment, that the Work has progressed to the point indicated; that-, to the best of the Architect's knowledge, information and belief, the qual- ity of the Work is in accordance with the Contract Docu- ments (subject to an evaluation of the Work for con- formance with the Contract Documents upon Substantial Completion, to the results of any subsequent tests re- quired by or performed under the Contract Documents, to minor deviations from the Contract Documents cor- rectable prior to completion, and to any specific qualifica- tions stated in the Certificate for Payment); and that the Contractor is entitled to payment in the amount certified. However, the issuance of a Certificate for Payment shall not be a representation that the Architect has made any examination to ascertain how and for what purpose the Contractor has used the moneys paid on account of the Contract Sum. The Architect shall be the interpreter of th quire -.ts of the Contract Documents and th '..ge of the perfor •ce thereunder by both t. •wner and Contractor. The itect shall rend ' erpretations nec- essary for the proper -cutio progress of the Work with reasonable promptn written request of either the Owner or the Co. . ctor, art. • .11 render written de- cisions, within asonable time, on . laims, disputes and other - ers in question between the • • r and the Con or relating to the execution or progres the rk or the interpretation of the Contract Documents. Interpretations and decisions of the Architect be c from graphic the ance sho resul form. In the Architect shall endea ons : • with the intent of and reasonab erable the Contr. tocuments and steal in written or • • o erpreter and judge, . re faithful perform - by both the • er and the o or, shall not w partiali . either, and shall not be lia. • the t y interpretation or decision rendered in g.. in such capacity. 1 The Architect's decisions in matters relatin e ..II be final if consistent Contract Doc The artistic the any other claims, dispu those in questio shall b een the Owner an ect to arbitration as provided in this and in the Contract Documents. 1.5.12 The Architect shall have authority to reject Work which does not conform to the Contract Documents. Whenever, in the Architect's reasonable opinion, it is wit. tent of s decisions on matters, including tractor, necessary or advisable for the implementation of the intent of the Contract Documents, the Architect will have author- ity to require special inspection or testing of the Work in accordance with the provisions of the Contract Docu- ments, whether or not such Work be then fabricated, in- stalled or completed. 15.13 The Architect shall review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for conformance with the design concept of the Work and with the information given in the Contract Documents. Such action shall be taken with reasonable promptness so as to cause no delay. The Architect's ap- proval of a specific item shall not indicate approval of an assembly of which the item is a component. 1.5.14 The Architect shall prepare Change Orders for the Owner's approval and execution in accordance with. the Contract Documents, and shall have authority to order minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time Which are not inconsistent with the intent of the Contract Documents. 15.15 The Architect shall conduct inspections to deter- mine the Dates of Substantial Completion and final com- pletion, shall receive and forward to the Owner for the Owner's review written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall issue a final Certificate for Pay- ment. 15.16 The extent of the duties, responsibilities and lim- itations of authority of the Architect as the Owner's rep- resentative during construction shall not be modified or extended without written consent of the Owner, the Con- tractor and the Architect. 1.6 PROJECT REPRESENTATION BEYOND BASIC SERVICES 1.6:1 If the Owner and Architect agree that more ex- tensive representation at the site than is described in Paragraph 1.5 shall be provided, the Architect shall pro- vide one or more Project Representatives to assist the Architect in carrying out such responsibilities at the site. 1.6.2 Such Project Representatives shall be selected, em- ployed and directed by the Architect, and the Architect shall be compensated therefor as mutually agreed be- tween the Owner and the Architect as set forth in an ex- hibit appended to this Agreement, which shall describe the duties, responsibilities and limitations of authority of such Project Representatives. 1.6.3 Through the observations by such Project Repre- sentatives, the Architect shall endeavor to provide further protection for the Owner against defects and deficiencies in the Work, but the fumishing of such project representa- tion shall not modify the rights, responsibilities or obliga- tions of the Architect as described in Paragraph 1.5. 1.7 ADDITIONAL SERVICES The following Services are not included in Basic Services unless so identified in Article 15. They shall be provided if authorized or confirmed in writing by the Owner, and they shall be paid for by the Owner 3s provided in this Agreement, in addition to the compensation for Basic Services. 4 B141-1977 AIA DOCUMENT 1041 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IUEY 1977 • AIA • m 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20036 1.7.1 Providing analyses of the Owner's needs, and pro- gramming the requirements of the Project. 1.7.2 Providing financial feasibility or other special studies. 1.73 Providing planning surveys, site evaluations, envi- ronmental studies or comparative studies of prospective sites, and preparing special surveys, studies and submis- sions required for approvals of governmental authorities or others having jurisdiction over the Project. 1.7.4 Providing services relative to future facilities, sys- tems and equipment which are not intended to be con- structed during the Construction Phase. 1.75 Providing services to investigate existing conditions or facilities or to make measured drawings thereof, or to verify the accuracy of drawings or other information fur- nished by the Owner. 1.7.6 Preparing documents of altemate, separate or sequential bids or providing extra services in connection with bidding, negotiation or construction prior to the completion of the Construction Documents Phase, when requested by the Owner. 1.7.7 Providing coordination of Work performed by separate contractors or by the Owner's own forces. 1.7.8 Providing services in connection with the work of a construction manager or separate consultants retained by the Owner. 1.7.9 Providing Detailed Estimates of Construction Cost, analyses of owning and operating costs, or detailed quan- tity surveys or inventories of material, equipment and labor. 1.7.10 Providing interior design and other similar ser- vices required for or in connection with the selection, procurement or installation of fumiture, furnishings and related equipment. 1.7.11 Providing services for planning tenant or rental spaces. 1.7.12 Making revisions in Drawings, Specifications or other documents when such revisions are inconsistent with written approvals or instructions previously given, are required by the enactment or revision of codes, laws or regulations subsequent to the preparation of such doc- uments or are due to other causes not solely within the control of the Architect. 1.7.13 Preparing Drawings, Specifications and supporting data and providing other services in connection with Change Orders to the extent that the adjustment in the Basic Compensation resulting from the adjusted Con- struction Cost is not commensurate with the services re- quired of the Architect, provided such Change Orders are required by causes not solely within the control of the Architect. 1.7.14 Making investigations, surveys, valuations, inven- tories or detailed appraisals of existing facilities, and serv- ices required in connection with construction performed by the Owner. 1.7.15 Providing consultation concerning replacement of any Work damaged by fire or other cause during con- struction, and fumishing services as may be required in connection with the replacement of such Work. 1.7.16 Providing services made necessary by the default of the Contractor, or by major defects or deficiencies in the Work of the Contractor, or by failure of performance of either the Owner or Contractor under the Contract for Construction. e showing sign' construction aring a set of reproducible record es i e umished by the Contractor to the made during drawings andti.) 1.7.18 Providing extensive assistance in the utilization of any equipment or system such as initial start-up or testing, adjusting and balancing, preparation of operation and maintenance manuals, training personnel for operation and maintenance, and consultation during operation. 1.7.19 Providing services after issuance to the Owner of the final Certificate for Payment, or in the absence of a final Certificate for Payment, more than sixty days after the Date of Substantial Completion of the Work. 1.7.20 Preparing to serve or serving as an expert witness in connection with any public hearing, arbitration pro- ceeding or legal proceeding. 1.7.21 Providing services of consultants for other than the normal architectural, structural, mechanical and elec- trical engineering services for the Project. 1.7.22 Providing any other services not otherwise in- cluded in this Agreement or not customarily fumished in accordance with generally accepted architectural practice. 1.8 TIME 1.8.1 The Architect shall perform Basic and Additional Services as expeditiously as is consistent with professional skill and care and the orderly progress of the Work. Upon request of the Owner, the Architect shall submit for the' Owner's approval a schedule for the performance of the Architect's services which shall be adjusted as required as the Project proceeds, and shall include allowances for peri- ods of time required for the Owner's review and approval of submissions and for approvals of authorities having jurisdiction over the Project. This schedule, when approved by the Owner, shall not, except for reasonable cause, be exceeded by the Architect. ARTICLE 2 THE OWNER'S RESPONSIBILITIES e Owner shall provide full information rega requireme • he Project including a r •. , which shall set forth the •5• •es' . • ectives, constraints and criteria, includi e re • - •. nts and relation- ships, flex'•. ' n. expandability, specia • •' • •• nt and s and site requirements. 2.2 If the Owner provides a budget for the Project it shall include contingencies for bidding, changes in the Work during construction, and other costs which are the responsibility of the Owner, including those described in this Article 2 and in Subparagraph 3.1.2. The Owner shall, at the request of the Architect, provide a statement of funds available for the Project, and their source. A1A DOCUMENT 11141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IULY 1977 • AIA• • 0 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 B141-1977 5 2.3 The Owner shall designate, when necessary, a rep- resentative authorized to act in the Owner's behalf with respect to the Project. The Owner or such authorized representative shall examine the documents submitted by the Architect and shall render decisions pertaining thereto promptly, to avoid unreasonable delay in the progress of the Architect's services. 2.4 The Owner shall fumish a legal description and a certified land survey of the site, giving, as applicable, grades and lines •of streets, alleys, pavements and adjoin- ing property; rights -of -way, restrictions, easements, en- croachments, zoning, deed restrictions, boundaries and contours of the site; locations, dimensions and complete data pertaining to existing buildings, other improvements and trees; and full information conceming available serv- ice and utility lines both public and private, above and below grade, including inverts and depths. 2S The Owner shall furnish the services of sail engi- neers or other consultants when such services are deemed necessary by the Architect. Such services shall include test borings, test pits, soil bearing values, percolation tests, air and water pollution tests, ground corrosion and resistivity tests, including necessary operations for determining sub- soil, air and water conditions, with reports and appropri- ate professional recommendations. 2.6 The Owner shall furnish structural, mechanical, chemical and other laboratory tests, inspections and re- ports as required by law or the Contract Documents. e Owner shall fumish all legal, accounting a surance • • . ling services as may be ne time for the Pro • cluding s h Owner the may require .� - ••� t e tions for Paym o ascertain poses • ntractor uses the moneys pal o the Owner. •e services, information, surveys and repo quired •y - • s 2.4 through 2.7 fumished at the Owne _ .- . n • be entitled • • • • n the accur at any Icing services as Contractor's Applica- or for what pur- r on be- s all be the Architect shall ompleteness 2.9 If the Owner observes or otherwise becomes aware of any fault or defect in the Project or nonconformance with the Contract Documents, prompt written notice thereof shall be given by the Owner to the Architect. 2.10 The Owner shall furnish required information and services and shall render approvals and decisions as ex- peditiously as necessary for the orderly progress of the Architect's services and of the Work. ARTICLE 3 CONSTRUCTION COST 3.1 DEFINITION 3.1.1 The Construction Cost shall be the total cost or estimated cost to the Owner of all elements of the Project designed or specified by the Architect. 3.1.2 The Construction Cost shall include at current market rates, including a reasonable allowance for over- head and profit, the cost of labor and materials furnished by the Owner and any equipment which has been de- signed, specified, selected or specially provided for by the Architect. 3.1.3 Construction Cost does not include the compen- sation of the Architect and the Architect's consultants, the cost of the land, rights -of -way, or other costs which are the responsibility of the Owner as provided in Arti- cle 2. 3.2 RESPONSIBILITY FOR CONSTRUCTION COST 3.2.1 Evaluations of the Owner's Project budget, State- ments of Probable Construction Cost and Detailed Estimates of Construction Cost, if any, prepared by the Architect, represent the Architect's best judgment as a design professional familiar with the construction indus- try. It is recognized, however, that neither the Architect nor the Owner has control over the cost of labor, mate- rials or equipment, over the Contractor's methods of de- termining bid prices, or over competitive bidding, market or negotiating conditions. Accordingly, the Architect cannot and does not warrant or represent that bids or negotiated prices will not vary from the Project budget proposed, established or approved by the Owner, if any, or from any Statement of Probable Construction Cost or other cost estimate or evaluation prepared by the Archi- tect. 3.2.2 No fixed limit of Construction Cost shall be estab- lished as a condition of this Agreement by the furnishing, proposal or establishment of a Project budget under Sub- paragraph 1.1.2 or Paragraph 2.2 or otherwise, unless such fixed limit has been agreed upon in writing and signed by the parties hereto. If such a fixed limit has been estab- lished, the Architect shall be permitted to include con- tingencies for design, bidding and price escalation, to de- termine what materials, equipment, component systems and types of construction are to be included in the Con- tract Documents, to make reasonable adjustments in the scope of the Project and to include in the Contract Docu- ments alternate bids to adjust the Construction Cost to the fixed limit. Any such fixed limit shall be increased in the amount of any increase in the Contract Sum occurring after execution of the Contract for Construction. 3.2.3 If the Bidding or Negotiation Phase has not com- menced within three months after the Architect submits the Construction Documents to the Owner, any Project budget or fixed limit of Construction Cost shall be ad- justed to reflect any change in the general level of prices in the construction industry between the date of submis- sion of the Construction Documents to the Owner and the date on which proposals are sought. 3.2.4 If a Project budget or fixed limit of Construction Cost (adjusted as provided in Subparagraph 3.2.3) is ex- ceeded by the lowest bona fide bid or negotiated pro- posal, the Owner shall (1) give written approval of an increase in such fixed limit, (2) authorize rebidding or re- negotiating of the Project within a reasonable time, (3) if the Project is abandoned, terminate in accordance with Paragraph 10.2, or (4) cooperate in revising the Project scope and quality as required to reduce the Construction Cost. In the case of (4), provided a fixed limit of Construc- tion Cost has been established as a condition of this Agree- ment, the Architect, without additional charge, shall mod- ify the Drawings and Specifications as necessary to comply 6 B141-1977 AIA DOCUMENT 1141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA• • 01977 THE AMERIC,N INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20036 with the fixed limit. The providing of such service shall be the limit of the Architect's responsibility arising from the establishment of such fixed limit, and having done so, the Architect shall be entitled to compensation for all services performed, in accordance with this Agreement, whether or not the Construction Phase is commenced. ARTICLE 4 DIRECT PERSONNEL EXPENSE 4.1 Direct Personnel Expense is defined as the direct sal- aries of all the Architect's personnel engaged on the Proj- ect, and the portion of the cost of their mandatory and customary contributions and benefits related thereto, such as employment taxes and other statutory employee bene- fits, insurance, sick leave, holidays, vacations, pensions and similar contributions and benefits. ARTICLE 5 REIMBURSABLE EXPENSES 5.1 Reimbursable Expenses are in addition to the Com- pensation for Basic and Additional Services and include actual expenditures made by the Architect and the Archi- tect's employees and consultants in the interest of the Project for the expenses listed in the following Sub- paragraphs: S.1.1 Expense of transportation in connection with the Project; living expenses in connection with out-of-town travel; long distance communications/ and fees paid for securing approval of authorities having jurisdiction over the Project. 5.1.2 Expense of reproductions, postage and handling of Drawings, Specifications and other documents, excluding reproductions for the office use of the Architect and the Architect's consultants. 5.1.3 Expense of data processing and photographic pro- duction techniques when used in connection with Addi- tional Services. 5.1.4 If authorized in advance by the Owner, expense of overtime work requiring higher than regular rates. 5.15 Expense of renderings, models and mock-ups re- quested by the Owner. S.1.6 Expense of any additional insurance coverage or limits, including professional liability insurance, requested by the Owner in excess of that normally carried by the Architect and the Architect's consultants. ARTICLE 6 PAYMENTS TO THE ARCHITECT 6.1 PAYMENTS ON ACCOUNT OF BASIC SERVICES 6.1.1 An initial payment as set forth in Paragraph 14.1 is the minimum payment under this Agreement. 6.1.2 Subsequent payments for Basic Services shall be made monthly and shall be in proportion to services per- formed within each Phase of services, on the basis set forth in Article 14. 6.1.3 If and to the extent that the Contract Time initially established in the Contract for Construction is exceeded or extended through no fault of the Architect, compensa- tion tor any Basic Services required for such extended period of Administration of the Construction Contract shall be computed as set forth in Paragraph 14.4 for Addi- tional Services. 6.1.4 When compensation is based on a percentage of Construction Cost, and any portions of the Project are deleted or otherwise not constructed,. compensation for such portions of the Project shall be payable to the extent services are performed on such portions, in accordance with the schedule set forth in Subparagraph 14.2.2, based on (1) the lowest bona fide bid or negotiated proposal or, (2) if no such bid or proposal is received, the most recent Statement of Probable Construction Cost or Detailed Esti- mate of Construction Cost for such portions of the Project. 6.2 PAYMENTS ON ACCOUNT OF ADDITIONAL SERVICES 6.2.1 Payments on account of the Architect's Additional Services as defined in Paragraph 1.7 and for Reimbursable Expenses as defined in Article 5 shall be made monthly upon presentation of the Architect's statement of services rendered or expenses incurred. 6.3 PAYMENTS WITHHELD 6.3.1 No deductions shall be made from the Architect's compensation on account of penalty, liquidated damages or other sums withheld from payments to contractors, or on account of the cost of changes in the Work other than those for which ,the Architect is held legally liable. 6.4 PROJECT SUSPENSION OR TERMINATION 6.4.1 If the Project is suspended or abandoned in whole or in part for more than three months, the Architect shall be compensated for all services performed prior to receipt of written notice from the Owner of such suspension or abandonment, together with Reimbursable Expenses then due and all Termination Expenses as defined in Paragraph 10.4. If the Project is resumed after being suspended for more than three months, the Architect's compensation shall be equitably adjusted. ARTICLE 7 ARCHITECT'S ACCOUNTING RECORDS 7.1 Records of Reimbursable Expenses and expenses per- taining to Additional Services and services performed on the basis of a Multiple of Direct Personnel Expense shall be kept on the basis of generally accepted accounting principles and shall be available to the Owner or the Owner's authorized representative at mutually convenient times. ARTICLE 8 OWNERSHIP AND USE OF DOCUMENTS 8.1 Drawings and Specifications as instruments of serv- ice are and shall remain the property of the Architect whether the Project for which they are made is executed or not. The Owner shall be permitted to retain copies, in- cluding reproducible copies, of Drawings and Specifica- tions for information and reverence in connection with the Owner's use and occupancy of the Project. The Drawings and Specifications shall not be used by the Owner on AM DOCUMENT 1141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IULY 1977 • AIA• • 6)1977 THE AMERICAN INSTITUTE OF ARCHITECTS. 173S NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 B141-1977 7 other projects, for additions to this Project, or for comple- tion of this Project by others provided the Architect is not in default under this Agreement, except by agreement in writing and with appropriate compensation to the Archi- tect. 8.2 Submission or distribution to meet official regulatory requirements or for other purposes in connection with the Project is not to be construed as publication in derogation of the Architect's rights. 1 be relati decided tion Indust tion Associat ally agree othe lating to this Agr joinder or in any other a party to this Agreement taining a specific referent bythe Architect, th O e e er, to be joined. Any co nt to a ditional person or ersons shall arbitration of any person ment to dispute not t named or des itrate and any agr addict al person or persons pa s to this Agreement shall be specifically enfor der the prevailing arbitration law. Notice of the demand for arbitration shall be file h otherparty to Association. le tim described .• • writin: the the American •itration be made within a re. • . b or other matter in questio the institution such ARTICLE 9 ARBITRATION All claims, disputes and other matters in questio een the parties to this Agreement, arising out to this Agreement or the breach thereof, arbitration! in accordance with the Arbitration Rules of the Ame then obtaining unless t No arbitration, a nt, shall incl anner, c • an or be onstruc- n Arbitra- parties mutu- ng out of or re- e, by consolidation, additional person not .t by written consent con - his Agreement and signed ny other person sought rbi tion involving an ad - not c stitute consent to describe herein or with there) This Agree - with an duly consented t y the f r ..ble - this Agreemen with T • • emand shall r the claim, dispute arisen. In no event shall m.. .fter the date when proce •' • :s based on Id be demand for orb" on be o :a or equitable , dispute or other matter in questio ed by the applicable statute of limitations. rendered by the arbitrate n ma Tie••- • • in accordance with and judgment w in any court having juris icuo ARTICLE 10 TERMINATION OF AGREEMENT 10.1 This Agreement may be terminated by either party upon seven days' written notice should the other party fail substantially to perform in accordance with its terms through no fault of the party initiating the termination. 10.2 This Agreement may be terminated by the Owner upon at least seven days' written notice to the Architect in the event that the Project is permanently abandoned. 10.3 In the event of termination not the fault of the Ar- chitect, the Architect shall be compensated for all services performed to termination date, together with Reimburs- able Expenses then due an.f all Termination Expenses as defined in Paragraph 10.4. 10.4 Termination Expenses include expenses directly at- tributable to termination for which the Architect is not otherwise compensated, plus an amount computed as a percentage of the total Basic and Additional Compensa- tion eamed to the time of termination, as follows: .1 20 percent if termination occurs during the Sche- matic Design Phase; or .2 10 percent if termination occurs during the Design Development Phase; or .3 5 percent if termination occurs during any subse- quent phase. ARTICLE 11 MISCELLANEOUS PROVISIONS 11.1 Unless otherwise specified, this Agreement shall be govemed by the law of the principal place of business of the Architect. s in this Agreement shall have the sam �9 ing as those In ` • I ent E onditions 14) of the Contra c I • , - • • s of the date reement. As between the parties to this Agreement: as res to act by either party to this pplica. tute of limitations se of a acts o any a run a y g have accrued in any and van to Date and an allege ago an erect by y proper forth in the edition of ditions, curre . of the date Owne • t e Architect each shall re ar waivers from their contractors, cons agents. Bement, commence to shall be deemed to nts not later than the rele- f the Work, and as the relevant ate of t Date of Subst• • Comple • any acts . I ures to act occurring . • " I • stantial Completion, not later than ance of the final Certificate for Payment. The Owner and the Architect waive all ins h other and against the contract- ts, agents a mployees of the of an ro er • ' • uran • I sult- amages cov- ng construction as set ument A201, General Con - is Agreement. The appropriate s and ARTICLE 12 SUCCESSORS AND ASSIGNS 12.1 The Owner and the Architect, respectively, bind themselves, their partners, successors, assigns and legal representatives to the other party to this Agreement and to the partners, successors, assigns and legal representa- tives of such other party with respect to all covenants of this Agreement. Neither the Owner nor the Architect shall assign, sublet or transfer any interest in this Agreement without the written consent of the other. ARTICLE 13 EXTENT OF AGREEMENT 13.1 This Agreement represents the entire and integrated agreement between the Owner and the Architect and supersedes all prior negotiations, representations or agree- ments, either written or oral. This Agreement may be amended only by written instrument signed by both Owner and Architect. AIA DOCUMENT 3141 • OWNER.ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA• • ID 1977 8 8141-1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 2E006 ARTICLE 14 BASIS OF COMPENSATION The Owner shall compensate the Architect for the Scope of Services provided, in accordance with Article 6, Payments to the Architect, and the other Terms and Conditions of this Agreement, as follows: 14.1 AN INITIAL PAYMENT of THREE THOUSAND dollars 03, DOD. 00) shall be made upon execution of this Agreement and credited to the Owner's account as follows: 14.2 BASIC COMPENSATION SIXTY—ONE THOUSAND DOLLARS ($61,000.00). 14.2.1 FOR BASIC SERVICES, as described in Paragraphs 1.1 through 1.5, and any other services included in Article 15 as part of Basic Services, Basic Compensation shall be computed as follows: (Here insert basis of compensation, including fixed amounts, multiples or percentages, and identify Phases to which particular methods of compensa- tion apply, if necessary.) 14.2.2 Where compensation is based on a Stipulated Sum or Percentage of Construction Cost, payments for Basic Services shall be made as provided in Subparagraph 6.1.2, so that Basic Compensation for each Phase shall equal the following percentages of the total Basic Compensation payable: (include any additional Phases as appropriate.) Schematic Design Phase: Design Development Phase: Construction Documents Phase: Bidding or Negotiation Phase: Construction Phase: PAYMENT TOWARD EACH PHASE SHALL BE INVOICED MONTHLY AND SHAL WORK COMPLETED FOR THAT PHASE, 14.3 FOR PROJECT REPRESENTATION BEYOND BASIC SERVICES, as described in Paragraph be computed separately in accordance with Subparagraph 1.6.2. percent ( 10 %) percent ( 10 %) percent ( 50 %) percent ( 05 %) percent ( 25 %) L NOT EXCEED 1.6, Compensation shall A1A DOCUMENT 8141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • RAY 1977 • MA• • p 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 B141-1977 9 14.4 COMPENSATION FOR ADDITIONAL SERVICES 14.4.1 FOR ADDITIONAL SERVICES OF THE ARCHITECT, as described in Paragraph 1.7, and any other services in- cluded in Article 15 as part of Additional Services, but excluding Additional Services of consultants, Compen- sation shall be computed as follows: (Here insert basis of compensation, including ores and/or multiples of Direct Personnel Expense for Principals and employees, and identify Principals and classify employees, if required. Identify specific services to which particular methods of compensation apply, if necessary) As per following Fee Schedule: Junior Draftsman $ 25.00 Clerical $ 23.00 Draftsman $ 45.00 Senior Draftsman $ 50.00 Project Designer $ 60.00 Construction Supervisor $ 65.00 Project Architect/Project Manager $ 65.00 Principal $ 100.00 14.4.2 FOR ADDITIONAL SERVICES OF CONSULTANTS, including additional structural, mechanical and electrical engineering services and those provided under Subparagraph 1.7.21 or identified in Article 15 as part of Addi- tional Services, a multiple of ONE ( 1.0 ) times the amounts billed to the Architect for such services. (Identify specific types o1 consultants in Article 15. i1 required.) 14.5 FOR REIMBURSABLE EXPENSES, as described in Article 5, and any other items included in Article 15 as Reim- bursable Expenses, a multiple of ONE POINT ONE FIVE ( 415 ) times the amounts ex- pended by the Architect, the Architect's employees and consultants in the interest of the Project. 14.6 Payments due the Architect and unpaid under this Agreement shall bear interest from the date payment is due at the rate entered below, or in the absence thereof, at the legal rate prevailing at the principal place of business of the Architect. (Here insert any rate of interest agreed upon.) (Usury law, and requirements under the federal Truth in Lending Act, s,mdar eatr and local consumer credit law< and other regulations at the Owners and Architect's principal places of business, the location of the Project and elsewhere may ahect the validity of this provision. Specific legal advice should he obtained with respect to deletion, modification, or other requirements such as written disclosures or waivers.) 14.7 The Owner and the Architect agree in accordance with the Terms and Conditions of this Agreement that: 14.7.1 IF THE SCOPE of the Project or of the Architect's Services is changed materially, the amounts of compensation shall be equitably adjusted. 14.7.2 IF THE SERVICES covered by this Agreement have not been completed within TWELVE (12) months of the date hereof, through no fault of the Architect, the amounts of compensation, rates and multiples set forth herein shall be equitably adjusted. 10 B141-1977 . AIA DOCUMENT t141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIA• • © 1977 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 • ARTICLE 15 OTHER CONDITIONS OR SERVICES 1. Scope of Basic Services shall include landscaping design within the Architects stipulated fee of Sixty -One Thousand Dollars ($61,000.00). 2. Scope of Basic Services shall include site plan and parking lot layout. 3. It is understood that Section 1.7.9 as an exclusion refers only to a detailed, bidding quality estimate. Budget estimates as described in Article 3 will be provi ded. 4. Section 1.7.10 as an exclusion does not apply to equipment integral to func- tioning of the facility as a gymnasium. 5. Section 1.7.17 work described in this Section shall be included in the Scope of Basic Services. Refers to Record Drawings. 6. Section 5.1.1 shall not be taken to mean trips to City of National City, Job Site or other normal travel within the region. 7. A&E shall stay in substantial conformance to the following schedule. The following time schedule does not include review time as needed by the City of National City: OPERATION 1. SCHEMATIC DESIGN PHASE 2. CONSTRUCTION DOCUMENT PHASE 3. BIDDING PHASE 4. CONSTRUCTION PHASE TIME IN CALENDAR DAYS FROM N.T.P. 21 DAYS 101 DAYS 122 DAYS TERM OF CON- STRUCTION 5. POST CONSTRUCTION PHASE 90 DAYS FORM COMPLETION OF CONSTRUCTION. AIA DOCUMENT R141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • JULY 1977 • AIAIR • m 1977 THE AMERICAN INSTITUTE OE ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 B141-1977 11 This Agreement entered into as of the day and year first written above. OWNER ARCHITECT CITY RF NATTRNAI CITY WNF£!FR/WTNFR, AR!'HITFrTv IN!` BY rge Wheeler, 12 8141-1977 AIA DOCUMENT S141 • OWNER -ARCHITECT AGREEMENT • THIRTEENTH EDITION • IULY 1977 • AIA• • ® 1977 THE AMERICAN INSTITUTE Of ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006