Loading...
HomeMy WebLinkAboutDownstream Services, Inc. - 4133 Calmoor St Storm Drain Repair - CIP No. 26-04 - 2026OWNER - CONTRACTOR AGREEMENT 4133 CALMOOR ST- STORM DRAIN REPAIR, CIP No. 26-04 This Owner -Contractor Agreement ("Agreement") is made by and between the City of National City, 1243 National City Boulevard National City, California 91950 and Downstream Services, Inc. ("Contractor"), 2855 Progress Place, Escondido, CA 92029, on the day of 2026, for the construction of the above referenced Project. In consideration of the mutual covenants and agreements set forth herein, the Owner and Contractor have mutually agreed as follows: 1. CONSTRUCTION The Contractor agrees to do all the work and furnish all the labor, services, materials and equipment necessary to construct and complete the Project in a turn -key manner in accordance with this Agreement and all documents and plans referenced in Exhibit "A", (hereinafter "Contract Documents"), in compliance with all relevant Federal, State of California, County of San Diego and City of National City codes and regulations, and to the satisfaction of the Owner. 2. CONTRACT PRICE Owner hereby agrees to pay and the Contractor agrees to accept as full compensation for constructing the project in accordance with these Contract Documents in an amount not to exceed the contract price as set forth in Exhibit "B" attached hereto and incorporated herein by reference. Payments to the Contractor shall be made in the manner described in the Special Provisions. TIME FOR PERFORMANCE Time is of the essence for this Agreement and the Contractor shall construct the project in every detail to a complete and turn -key fashion to the satisfaction of the Owner within the specified duration set forth in the Special Provisions. 4. NON-DISCRIMINATION In the performance of this Agreement, the Contractor shall not refuse or fail to hire or employ any qualified person, or bar or discharge from employment any person, or discriminate against any person, with respect to such person's compensation, terms, conditions or privileges of employment because of such person's race, religious status, sex or age. 5. AUTHORIZED OWNER REPRESENTATIVES On behalf of the Owner, the Project Manager designated at the pre -construction meeting shall be the Owner's authorized representative in the interpretation and enforcement of all Work performed in connection with this Agreement. 6. WORKERS' COMPENSATION INSURANCE a) By my signature hereunder, as Contractor, I certify that I am aware of the provisions of Section 3700 of the Labor Code, which requires every employer to be insured against liability for Workers' Compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the Work of this Agreement. b) The Contractor shall require each subcontractor to comply with the requirements of Section 3700 of the Labor Code. Before commencing any Work, the Contractor shall cause each subcontractor to execute the following certification: "I am aware of the provisions of Section 3700 of the Labor Code, which requires every employer to be insured against liability for worker's compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the Work of this Agreement." 7. ENTIRE AGREEMENT; CONFLICT The Contract Documents comprise the entire agreement between the Owner and the Contractor with respect to the Work. In the event of conflict between the terms of this Agreement and the bid of the Contractor, then this Agreement shall control and nothing herein shall be considered as an acceptance of the terms of the bid conflicting herewith. MAINTENANCE OF AGREEMENT DOCUMENTATION Contractor shall maintain all books, documents, papers, employee time sheets, accounting records and other evidence pertaining to costs incurred and shall make such materials available at its office at all reasonable times during the term of this Agreement and for three (3) years from the date of final payment under this Agreement, for inspection by Owner and copies thereof shall be furnished to Owner if requested. 9. INDEPENDENT CONTRACTOR At all times during the term of this Agreement, Contractor shall be an independent contractor and shall not be an employee, agent, partner or joint venturer of the Owner. Owner shall have the right to control Contractor insofar as the results of Contractor's services rendered pursuant to this Agreement; however, Owner shall not have the right to control the means by which Contractor accomplishes such services. 10. LICENSES AND PERMITS Contractor represents and declares to Owner that it has all licenses, permits, qualifications and approvals of whatever nature which are legally required to practice its profession. Contractor represents and warrants to Owner that Contractor shall, at its sole cost and expense, keep in effect at all times during the term of this Agreement, any licenses, permits, qualifications or approvals which are legally required for Contractor to practice its profession. 11. GOVERNING LAW, VENUE This Agreement and the Contract Documents shall be construed under and in accordance with the laws of the State of California, and the appropriate venue for any action or proceeding arising from this Agreement and/or the Contract Documents shall be had in the Superior Court of San Diego, Central Branch. 12. COUNTERPARTS This Agreement may be executed in any number of counterparts, each of which shall for all purposes be deemed to be an original. 13. FALSE CLAIMS Contractor acknowledges that if a false claim is submitted to the Owner, it may be considered fraud and Contractor may be subject to criminal prosecution. Contractor acknowledges that the False Claims Act, Califomia Government Code sections 12650, et seq., provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include within their scope false claims made with deliberate ignorance of the false information or in reckless disregard of the truth or falsity of the information. In the event the Owner seeks to recover penalties pursuant to the False Claims Act, it is entitled to recover its litigation costs, including attorneys' fees. Contractor hereby acknowledges that the filing of a false claim may the Contractor to an administrative debarment proceeding wherein Contractor may be prevented from further bidding on public contracts for a period of up to five (5) years. I have read and understood all of the provisions of this ction 13, above: (Initial) (Initial) 14. AGREEMENT MODIFICATION This Agreement and the Contract Documents may not be modified orally or in any manner other than by an amendment in writing and signed by the Owner and the Contractor. IN WITNESS WHEREOF this Agreement is executed as of the date first written above. Acting City Manager, City of National City Appr v d as to form: Heidi Skinner, Interim City Attorney, City of National City Contractor: Inc. (Owner/Officer signature) Loren Wynne, President Print name and title ,,••''�Q,............. . -�SF,AT• C-)i '••.,,qC lF.OFtN�,.•�•. (Sekil"d"of icer signature if a corporation) Clark Roberts, Vice President Print name and title 09002800 Contractor's City Business License No. 807953 A, C31, HAZ State Contractor's License No. and Class 2855 Progress Place Business street address Escondido, CA City, State and Zip Code +>-- CALIFORNIA --�+ NA ONU Cilry INCOROR PORATED Project: 4133 Calmoor Street — Storm Drain Repair CIP 26-04 Estimated construction costs: $100,000.00 Lowest bid Construction Costs: $104,339.00 In accordance with the municipal code, staff employed the informal bidding procedure outlined below. NC Municipal Code, Chapter 2.62 — Informal Bid Procedure Informal Bid Procedure The written estimate is the dollar limits set forth for informal bidding, which are applicable to the City Engineer's written estimate of the cost to complete any public project. If the written estimate is between $75,000 and $220,000 the contractor should be selected under the following Informal Bid Procedure: • Staff will post the project on P1anetBids and identify the necessary contract license require to perform the work. The project must be advertised for a minimum of ten calendar days. Staff will award the lowest responsible bidder. • The City Manager is the signed authority to award and execute the contract without needing approval from City Council. The City Manager may approve change orders in amount not exceeding the greater of 25% or $50,000, over the original authorized contract price without prior city council approval. If all bids received excess $220,000, the city council may award the contractor by adopting a resolution with a four -fifth vote, if it determined that the public agency's cost estimate is reasonable. Engineering & Public Works Department 1243 National City Boulevard, National City, CA 91950-4301 619/336-4380 Fax 619/336-4397 www.nationalcityca.gov — e411100401XIA — NkTiONALciry ucoaroBAn'- Exhibit B — Bid Result Engineering & Public Works Department Line Totals (Unit Price' Quantity) Downstream Services, Inc Item Num Section Description Unit Quantity Unit Price Line Total 1 General Mobilization/Demobilization LS 1 $4,612.00 $4,612.00 2 General Clearing and Grubbing LS 1 $3,127.00 $3,127.00 3 General Invert Grout existing 24" CMP CY 6 $7,007.00 $42,042.00 4 General 24" CIPP Liner LF 120 $305.00 $36,600.00 5 General Protection and Restoration of Existing Improvements (Repair Sinkhole) LS 1 $17,958.00 $17,958.00 CONTRACT AMOUNTI $ 104,339.00 CORPORATE CERTIFICATE I, Loren Wynne certify that I am the Secretary of the Corporation named as Contractor in the foregoing Contract; that Loren Wynne who signed said contract on behalf of the Contractor, was then President of said Corporation; that said contract was duly signed for and in behalf of said Corporation by authority of its governing body and is within the scope of its corporate powers. 1, Loren Wynne certify that I am the Secretary of the Corporation named as Contractor in the foregoing Contract; that Clark Roberts who signed said contract on behalf of the Contractor, was then Vice President of said Corporation; that said contract was duly signed for and in behalf of said Corporation by authority of its governing body and is within the scope of its corporate powers. o��rQ�,M' S... y A�' _ Q SE V1- O r: Z`YpC : l-'W",Q- �'�••,,,,qC r,FOR.�•�. Corporate Seal: BOND NUMBER: 30266795 Premium: $1,252.00 Subject to adjustment based on final contract price PERFORMANCE BOND WHEREAS, the City Manager of the City of National City, on the day of 20 , has awarded to DOWNSTREAM SERVICES, INC., hereinafter designated as the "Principal", the 4133 CALMOOR ST- STORM DRAIN REPAIR, CIP No. 26-04. WHEREAS, said Principal is required under the terms of said contract to furnish a bond for the faithful performance of said contract. NOW, THEREFORE, we, the Principal and Western Surety Company as surety, are held and firmly bound unto the City of National City, hereinafter called the "City", in the penal sum of (one hundred and four thousand, three hundred thirtv-nine (S104,339.00) dollars lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT if the above bounden Principal, his/her or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the said contract any alteration thereof made as therein provides, on his or their part, to be kept and performed at the time and in the amount therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City of National City, its officers, agents, employees, and volunteers as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and virtue. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract or to the work to be performed herein or the specifications accompanying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or additions to the terms of the contract or to the work or to the specifications. In the event suit is brought upon this bond by the City and judgment is recovered, the surety shall pay all costs incurred by the City in such suit, including a reasonable attorney's fee to be fixed by the Court. IN WITNESS WHEREOF three identical counterparts of this instrument, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Principal and Surety above named, on the Western SuAy Company (SEAL) (SEAL) Lawr reF. Mahon, Attorney -in -Fact (SEAL) Surety 18th day of March 20 26 Inc. VIVA Principal Please see attached California All -Purpose Acknowledgment for Surety PERFORMANCE BOND ATTORNEY -IN -FACT ACKNOWLEDGEMENT OF SURETY STATE OF ) ss COUNTY OF On this day of , 20 , before me, the undersigned, a Notary Public in and for said County and State, personally appeared known to me to be the person whose name is subscribed to the within instrument as the attorney -in -fact of the the corporation named as Surety in said instrument, and acknowledged to me that he subscribed the name of said corporation thereto as Surety, and his own name as attorney -in -fact. NOTE: Signature of those executing for NOTE: The Attorney -in -fact must attach a Surety must be properly certified copy of the Power of acknowledged. Signature: Name (Type or Print): Attorney. Notary Public in and for said County and State My Commission expires: ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Diego On �kGcc'� \ Zo l' b before me, personally appeared Lo ��h w 'I K nt Maureen McLaughlin, Notary Public (insert name and title of the officer) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and icial seal. MAUREENMCU,UC,HLIN Notary Public • California San Diego County > Commission N 2507594 e y Comm. Expires Dec 21, 2028 Signature (Seal) CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California ) County of San Diego ) On MAR 1 8 2026 before me, Maria Guise, Notary Public , Date Here Insert Name and Title of the Officer personally appeared Lawrence F. McMahon Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and gfficial seal. MARIA GUISE nature Com !��,ll,/� mission # 2444156 Si V � g �� Notary Public - Caldornia � SAN DIEGO County � Signature of Notary Public My Comm. Expires APR 14, 2027 Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Individual Z Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Surety Company Number of Pages: Signer's Name: ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator n Other: Signer Is Representing: 02015 National Notary Association - www.NationaiNotary.org • 1-800-US NOTARY (1-800-876-6827) Item #5907 Western Surety Compare POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN -FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint Lawrence F Me Mahon, Sarah Myers, Maria Guise, Lilia De Loera, Christopher J Conte, Tara Bacon, Individually of San Diego, CA, its true and lawful Attomey(s)-in-Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the Authorizing By -Laws and Resolutions printed at the bottom of this page, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 8th day of August, 2025. � !ETyC% WESTERN SURETY COMPANY Wt Z *'' • sf A,' JQY Lary Kasten, Vice President State of South Dakota 1 ss County of Minnehaha I On this 8th day of August, 2025, before me personally came Larry Kasten, to me known, who, being by me duly sworn, did depose and say: that he residjs in the City of Sioux Falls, State of South Dakota; that he is a Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires i M. BENT HOTAW IC March 2, 2026 . sour[+ treturt'a M. Bent, Notary Public CERTIFICATE 1, Paula Kolsrud, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Laws and Resolutions of the corporation printed below this certificate are still in force. In testimony whereof 1 have hereunto subscribed my name and affixed the seal of the said corporation this 1 8th day of March 2026 0�00411 WESTERN SURETY COMPANY Paula Kolsrud, Assistant Secretary Authorizing By -Laws and Resolutions ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. This Power of Attorney is signed by Larry Kasten, Vice President, who has been authorized pursuant to the above Bylaw to execute power of attorneys on behalf of Westem Surety Company. This Power of Attorney may be signed by digital signatureand sealed by a digital or otherwise electronic -formatted corporate seal under and by the authority of the following Resolution adopted by the Board of Directors of the Company by unanimous written consent dated the 27' day of April, 2022: "RESOLVED: That it is in the best interest of the Company to periodically ratify and confirm any corporate documents signed by digital signatures and to ratify and confirm the use of a digital or otherwise electronic -formatted corporate seal, each to be considered the act and deed of the Company." Go to wi+w.cnasu reh.conr > Owner I Obligee Services > Validate Bond Coverage, if you want to verify bond authenticity. Form F4280-&2023 , , ) I , I . t, . I 1j3g /'MVI -1/11`401044/ 1 1 1 t I t,l i0vabi-vind ,fltl-tull IrtnT .71,1— 'k-lillclor- -s� cv�'t 'Al "Ai i I,; .If, dt).�;e -t,Aw) *fit. j I lk� w ei li Mt. At 1 i,tt Jl BOND NUMBER: 30266795 Premium included in Performance Bond PAYMENT BOND WHEREAS, the City Manager of the City of National City, on the day of 20 has awarded DOWNSTREAM SERVICES, INC., hereinafter designated as the "Principal", the 4133 CALMOOR ST- STORM DRAIN REP AIR, CIP No. 26-04 WHEREAS, said Principal is required by Chapter 5 (commencing at Section 3225) and Chapter 7 (commencing at Section 3247), Title 15, Part 4, Division 3 of the California Civil Code to furnish a bond in connection with said contract; NOW, THEREFORE, we, the Principal and Western Surety Company as surety, are held and firmly bound unto the City of National City, hereinafter called the "City", in the penal sum of (one hundred and four thousand, three hundred thirty-nine ($104,339.00) dollars lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if said Principal, his/her or its subcontractors, heirs, executors, administrators, successors, or assigns, shall fail to pay any of the persons named in Section 3181 of the California Civil Code, or amounts due under the Unemployment Insurance Code with respect to work or labor performed by any such claimant, or for any amounts required to be deducted, withheld, and paid over to the Franchise Tax Board from the wages of employees of the Contractor and his subcontractors pursuant to Section 18806 of the Revenue and Taxation Code, with respect to such work and labor the Surety will pay for the same in an amount not exceeding the sum hereinafter specified, and also, in case suit is brought upon this bond, a reasonable attorney's fee, to be fixed by the Court. This Bond shall inure to the benefit of any of the persons named in Section 3181 of the California Civil Code, so as to give a right of action to such persons or their assigns in any suit brought upon this bond. It is further stipulated and agreed that the Surety on this bond shall not be exonerated or released from the obligation of this bond by any change, extension of time for performance, addition, alteration or modification in, to, or of any contract, plans, specifications, or agreement pertaining or relating to any scheme or work of improvement hereinabove described or pertaining or relating to the furnishing of labor, materials, or equipment therefore, not by any change or modification of any terms of payment or extension of the time for any payment pertaining or relating to any scheme or work of improvement hereinabove described, nor by any rescission or attempted rescission of the contract, agreement or bond, nor by any conditions precedent or subsequent in the bond attempting to limit the right of recovery of claimants otherwise entitled to recover under any such contract or agreement or under the bond, nor by any fraud practiced by any person other than the claimant seeking to recover on the bond and that this bond be construed most strongly against the Surety and in favor of all persons for whose benefit such bond is given, and under no circumstances shall Surety be released from liability to those for whose benefit such bond has been given, by reason of any breach of contract between the owner of Public Entity and original contractor or on the part of any obliges named in such bond, but the sole conditions of recovery shall be that claimant is a person described in Section 3110 or 3112 of the California Civil Code, and has not been paid the full amount of his claim and that Surety does hereby waive notice of any such change, extension of time, addition, alteration or modification herein mentioned. IN WITNESS WHEREOF three identical counterparts of this instrument, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Principal and Surety above named, on the 18th day of March 2026 . L) DoatvnstTIm SLrvigs, Inc. L) L) Surety Principal �F1EAM S n z - '• � ao q? .,FORNI P ed ion AN onod en" a Wov/ Aj 161'1 &xYgE lym bwcWqjv WYA a 1,; to nNOW ginsnunfisu Ki 10 "nu as 616101 11 in-imny Inoqw, 10 enm4mwuqq� iodW fulAdmfout -u Wingn ?;.,) nwi ;QW1 tv qP050 VMG qw lon .910111042 YnAw yru U! it.) *'1w,.1kiFv Y,-.41 �,fli lo 4;jqQWv w rwAhnew yfm id ion b9dianob 9vod5nmed >-inw wi tj ,�z VJ bon(,� tio 10SM99, 961 'nwjs k w lu 1415 5nny a qd(I; an 0a NMI Wad 9"1 A P, no 10 bnwi tl,fi; rtu, q; SnAge 9fit 1,Vil Hc to ion! A UT wivue 911 Jn*yR; Qmij. Lima bso0epai A hind wt W wlii yd vis iv? 060 cei i-knu los , W4 Y Wad I= vinwid own A ew. no. od nw-o,4 ro,?--,d �.wi UtIcul dw "Knod ""Aw lol •.otwf! Ino'+ itiniino ins vMn3 !"IS-4aw In A ssimi Vw A Hsdp yi9vow to wuclnci Aue Al fud :-sfi iii b-lrt!fn etj�pl&, e-Inrj -,fi? yb03 W 10 KHE ui (OLE r1(Y091 ni Whsib nnnsq 6 6 wws"Ai 101 swow yAW e9ch 49M mdf biG NW nd ic? inuorn W all IN (Old wi n o bof, nigind Upf"AS YK w, Please see attached California All -Purpose Acknowledgment for Surety ATTORNEY -IN -FACT ACKNOWLEDGEMENT OF SURETY STATE OF ) ss COUNTY OF ) On this day of , 20 , before me, the undersigned, a Notary Public in and for said County and State, personally appeared known to me to be the person whose name is subscribed to the within instrument as the attorney -in -fact of the the corporation named as Surety in said instrument, and acknowledged to me that he subscribed the name of said corporation thereto as Surety, and his own name as attorney -in -fact. NOTE: Signature of those executing for NOTE: The Attorney -in -fact must attach a Surety must be properly certified copy of the Power of acknowledged. Attorney. Signature: Name (Type or Print): (Notary Public in and for said County and State) My Commission expires: ATTACH ALL BONDS ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Diego On o wl� 01 Zo Z (o before me, personally appeared L o cc, V 7 r n4,, Maureen McLaughlin, Notary Public (insert name and title of the officer) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and off ial seal. MAUREENMCLAUGHLIN Notary Public - California San Diego County Commission / 2507594 My Comm. Expires Dec 21, 2026 Signature (Seal) ALL-PURPOSECALIFORNIA •. .A A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California ) County of San Diego ) On MAR 1 8 2026 before me, Maria Guise, Notary Public Date Here Insert Name and Title of the Officer personally appeared Lawrence F. McMahon Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. .•• , ; ., MAGUISE # 2444156 � e ; Commission Notary Public - Caldomie Signature SAN DIEGO County My Comm. Expires APR 14, 2027 Signature of Notary Public Place Notary Seal Above OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Individual X Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: Surety Company Number of Pages: Signer's Name: ❑ Corporate Officer — Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: 02015 National Notary Association - www.NationaiNotary.org • 1-800-US NOTARY (1-800-876-6827) Item #5907 Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN -FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint Lawrence F Mc Mahon, Sarah Myers, Maria Guise, Lllia De Loera, Christopher J Conte, Tara Bacon, Individually of San Diego, CA, its true and lawful Attomey(s}in-Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the Authorizing By -Laws and Resolutions printed at the bottom of this page, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 8th day of August, 2025. EXro WESTERN SURETY COMPANY L% ,. *-r State of South Dakota Larry Kasten, Vice President ss County of Minnehaha On this 8th day of August, 2025, before me personally came Larry Kasten, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is a Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires M. BENT NOTARY Ntalic March 2, 2026 i SOUTH nAKOTA(S�Vl M. Bent, Notary Public CERTIFICATE I, Paula Kolsrud, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Laws and Resolutions of the corporation printed below this certificate are still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this 18th day of March 2026 err WESTERN SURETY COMPANY �*''•t`4C p,%- •e � Paula Kolsrud, Assistant Secretary Authorizing By-1,aws and Resolutions ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. This Power of Attorney is signed by Larry Kasten, Vice President, who has been authorized pursuant to the above Bylaw to execute power of attorneys on behalf of Westem Surety Company. This Power of Attorney may be signed by digital signature and sealed by a digital or otherwise electronic -formatted corporate seal tinder and by the authority of the following Resolution adopted by the Board of Directors of the Company by unanimous written consent dated the 27' day of April, 2022: "RESOLVED: That it is in the best interest of the Company to periodically ratify and confirm any corporate documents signed by digital signatures and to ratify and confirm the use of a digital or otherwise electronic -formatted corporate seal, each to be considered the act and deed of the Company." Go to wN w.cnasuretv.com > Owner / Obligee Services > Validate Bond Coverage, if you want to verify bond authenticity. Form F4280-6-2023 10 ''I jW, :Wv 7'.Z Ott jok 1WWWO... , A e; -1 Kf kYl AL -t'H1 ig!?; Kr :if f:1 q ;p..: 10 J)e f Q PC%( fwj" I JLN ena"o Ism& Num", QV WDU 10 W ITIONAU I'Th 1.