Loading...
HomeMy WebLinkAbout2008 CON CDC Flores Sierra Contractors - Demolition 1820 G AvenueCONTRACT THE DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA SPECIFICATION NO. 08-1820 G AVENUE THIS CONTRACT, made and entered into this /07 ' day of, 6 I22008 by and between the Community Development Commission of the City of National City, California, herein after designated as the "City", and Flores Sierra Contractors, Inc., hereinafter designated as the "Contractor". WITNESSETH: that the parties hereto do mutually agree as follows: 1. For and in consideration of the payments and agreements hereinafter mentioned to be made and performed by the City, the Contractor agrees with the City to furnish all materials and labor for: THE DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA SPECIFICATION NO. 08-1820 G AVENUE and to perform and complete in a good and workmanlike manner all the work pertaining thereto shown on the plans and specifications therefore; to furnish at his own proper cost and expense all tools, equipment, labor and materials necessary therefore; and to do everything required by this agreement and the said plans and specifications. 2. For furnishing all said materials and labor, tools and equipment, and doing all the work contemplated and embraced in this Contract, also for all loss and damage arising out of the nature of the work aforesaid, or from the action of the elements, or from any unforeseen difficulties which may arise or be encountered in the prosecution of the work until its acceptance by the City and for all risks of every description connected with the work; also, for all expenses incurred by or in consequence of the suspension or discontinuance of work, except such as in said specifications are expressly stipulated to be borne by the City and for well and faithfully completing the work and the whole thereof, in the manner shown and described in the said plans and specifications, the City will pay and the Contractor shall receive in full compensation therefore the sum of thirty-three thousand three hundred and fifty-two exactly dollars ($33,352.00). 3. The City hereby promises and agrees to employ, and does hereby employ said Contractor to provide the materials and to do the work according to the terms and conditions herein contained and referred to for the price aforesaid and hereby conditions set forth in the specification; and the said parties for themselves, their heirs, executors, administrators, successors and assigns, do hereby agree to the full performance of the covenants herein contained. 4. The Notice Inviting Bids, Instructions To Bidders, Bid Proposal, Bid Forms, Agreement and Bond Forms, the Plans and Specifications, General Provisions and Special Provisions, Appendix, Addenda, Construction Administration Forms, Completion of the Project Forms, and all amendments thereof, are hereby incorporated in and made part of this Contract. 5. The City, the City's representative, the Consultants and authorized volunteers shall not be answerable or accountable in any manner for any loss or damage that may occur to the work rev 6/24/08 1 or any part thereof, or for any of the materials or other things used or employed in performing the work, of for injury or damage to any person or persons, either workers, employees of Contractor or its subcontractors or the public, or for damage to adjoining or other property, from any cause whatsoever arising out of or in connection with the performance of the work. The Contractor shall be responsible for any damage or injury to any person or property resulting from defects or obstructions or from any cause whatsoever arising out of or in connection with the performance of the work, provided, however, that the Contractor shall not be liable for the sole established negligence, willful misconduct or active negligence of the City, its representatives, employees, agents and authorized volunteers who are directly responsible to the City. a. Contractor shall indemnify the City, City Council, City officials, City employees, City representatives, and authorized volunteers against and will hold and save them and each of them harmless from any and all actions, claims, damages to persons or property, penalties, obligations or liabilities that may be asserted or claimed by any person, firm entity, corporation, political subdivision or other organization arising out of or in connection with the work, operation or activities of Contractor, its agents, employees, subcontractors or invitees, provided for herein, whether or not there is concurrent passive or active negligence on the part of the City, City Council, City officials, City employees, City representatives, and authorized volunteers, but excluding such actions, claims, damages to persons or property penalties, obligations or liabilities arising from the sole established negligence, willful misconduct or active negligence of the City, City Council, City officials, City employees, City representatives, authorized volunteers, or those who are directly responsible to them; and in connection therewith: 1) Contractor will defend any action or actions filed in connection with any of said claims, damages, penalties, obligations or liabilities and will pay all costs and expenses, including attorney's fees incurred in connection therewith. 2) Contractor will promptly pay any judgment rendered against Contractor, the City, City Council, City officials, City employees, City representatives, and authorized volunteers covering such claims, damages, penalties, obligations and liabilities arising out of or in connection with such work, operations, or activities of Contractor hereunder and Contractor agrees to save and hold the City, City Council, City officials, City employees, City representatives, and authorized volunteers harmless there from. 3) In the event the City, City Council, City officials, City employees, City representatives, and authorized volunteers are made a party to any action or proceeding filed or prosecuted against Contractor for such damages or other claims arising out of or in connection with the Work, or operation or activities of Contractor hereunder, Contractor agrees to pay to the City, City Council, City officials, City employees, City representatives, and authorized volunteers any and all costs and expenses incurred by the City, City Council, City officials, City employees, City representatives, and authorized volunteers in such action or proceeding together with reasonable attorney's fees. rev 6/24/08 2 V 4) The City may retain, to the extent it deems necessary, the money due to the Contractor under and by virtue of the Contract Documents until disposition has been made of such actions or claims for damages as specified herein above. 6. Claims, disputes and other matters in question between the parties to this Contract, arising out of or relating to this Contract or the breach thereof, may be decided by arbitration if both parties to this Contract consent in accordance with the rules of the American Arbitration Association then obtaining unless the parties mutually agree otherwise. No arbitration arising out of or relating to this Contract, shall include, by consolidation, joinder or in any other manner, any additional person not a party to this Contract except by written consent containing a specific reference to this Contract and Signed by CONTRACTOR, City, and any other person sought to be joined. (Any Consent to arbitration involving an additional person or persons shall not constitute consent of any dispute not described therein or with any person not named or described therein.) This agreement to arbitrate and any agreement to arbitrate with an additional person or persons duly consented to by the parties to this Contract shall be specifically enforceable under the prevailing arbitration law. Notice of the demand for arbitration is to be filed in writing with the other party to this Contract and with the America Arbitration Association. The demand is to be made within a reasonable time after the claim, dispute or other matter in question has arisen. In no event is the demand for arbitration to be made after the date when institution of legal or equitable proceedings based on such claim, dispute or other matter in question would be barred by the applicable statute of limitations. The award rendered by the arbitrators shall be final and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. 7. The Contractor agrees to comply with all Local, State and Federal regulations and with all applicable standards, orders, or regulations issued pursuant to the Removal, Disposal, and Transportation of Hazardous Material and Waste, Clean Air Act of 1970 (42 U.S.C. 1857 et seq.) and the Federal Water Pollution Control Act, (33 U.S.C. 1251 et seq.) as amended. 8. If any party brings a suit or action against the other party arising from any breach of any of the covenants or agreements or any inaccuracies in any of the representations and warranties on the part of the other party arising out of this Agreement, then in that event, the prevailing party in such action or dispute, whether by final judgment or out -of -court settlement, shall be entitled to have and recover of and from the other party all costs and expenses of suit, including attorneys fees. 9. Each and every provision of law and clause required to be inserted in this Contract shall be deemed to be inserted herein and this Contract shall be read and enforced as though it were included herein, and if through mistake or otherwise any such provision is not inserted or is not inserted correctly, then upon application of either party the Contract shall forthwith by physically amended to make such insertion or correction. 10. In accordance with Government Code, Section 8546.7, records of both the City and the Contractor shall be subject to examination and audit for a period of three (3) years after final payment. rcv 624 08 3 IN WITNESS WHEREOF, the parties hereto have caused this Contract to be executed in three counterparts, each of which shall be deemed an original the day and year first above written. CONTRACTOR: By: CITY: Title: p)o'.°°8 l By: Title: Federal ID. No. 2 ! 15 $ 90 3`-i- By: Title: Mayor, City of National City ATTEST: By: Title: City Clerk, City of National City (Notarial acknowledgement of execution by all PRINCIPALS OF CONTRACTOR must be attached.) rcv 6/24.!08 4 CONTRACT (CONTINUED) THE DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA SPECIFICATION NO. 08-1820 G AVENUE CORPORATE CERTIFICATE certify that I am the Secretary of the Corporation the foregoing Contract; that , who igne said contract on behalf of the Contractor, was then (`ILS : of said Corporation; that said contract was d y signed for and in behalf of said Corporation by authority of its governing body and is within the scope of its corporate powers. I, certify that I am the Secretary of the Corporation named as Contractor in the foregoing Contract; that , who signed said contract on behalf of the Contractor, was then - of said Corporation; that said contract was duly signed for and in behalf of said Corporation by authority of its governing body and is within the scope of its corporate powers. Corporate Seal: rev 6/24/08 5 Bond No. BDC12143 Prem:$834.00 PERFORMANCE BOND THE DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA SPECIFICATIQN NO. 08-1820 G AVENUE KNOW ALL MEN BY THESE PRESENTS: That WHEREAS, The City Council of the City of National City, by Resolution No. 2008-_, passed the 21st day of October, 2008 has awarded to Flores Sierra Contractors, Inc., hereinafter designated as the "Principal", the contract for the Demolition and Disposal of Buildings Located at 1820 G Avenue, National City, California. WHEREAS, said Principal is required under the terms of said contract to furnish a bond for the faithful performance of said contract. NOW, THEREFORE, we, the Principal and Western InsjancP ('.omparly as surety, are held and firmly bound unto The Community Development Commission of the City of National City, hereinafter called the "City", in the penal sum of thirty thousand three hundred fifty-two and 0/100 Dollars ($33,352.00) lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH THAT if the above bounden Principal, his/her or its heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions and agreements in the said contract any alteration thereof made as therein provides, on his or their part, to be kept and performed at the time and in the amount therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City of National City, the City Council, the Community Development Commission, their officers, agents, and employees, as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and virtue. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of tune, alteration or addition to the terms of the contract or to the work to be performed thereunder or the specifications accompanying the same shall in any wise affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration or additions to the terms of the contract or to the work or co the specifications. ,cv (,ne,00 7 PERFORMANCE BOND (CONTINUED) THE DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA SPECIFICATION NO, 08-1820 G AVENUE In the event suit is brought upon this bond by the Community Development Commission of the City of National City and judgment is recovered, the surety shall pay all costs incurred by the Council in such suit, including a reasonable attorney's fee to be fixed by the Court. IN WITNESS WHEREOF three identical counterparts of this instrument, each of which shall for an purposes be deemed an original thereof, have been duly executed by the Principal and Surety above named, on the 5th day of November_. 2008. Western Insurance Company (SEAL) (SEAL) (SEAL) Clovia L. Lehto, Attorney -In -Fact Surety Principal APPROVED AS TO FORM: George H. ser, III City Attorney F1 r s Si ra mn rartnrs(SEAL) Inc. (SEAL) (SEAL) 8 PERFORMANCE BOND (CONTINUED) THE DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA SPECIFICATION NO. 08-1820 G AVENUE ATTORNEY -IN -FACT ACKNOWLEDGEMENT OF SURETY STATE OF Nevada ) COUNTY OF Washoe ) ) ss On this day _5th ofNovembe_, 2008, before me, the undersigned, a Notary Public in and for said County and State, personally appeared Clovia L. Lehto proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument as the attorney -in - fact of the Western Insurance Company , the corporation named as Surety in said instrument, and acknowledged to me that he subscribed the name of said corporation thereto as Surety, and his own name as attorney -in -fact. NOTE: Signature of those executing for Surety must be properly acknowledged. NOTE: The Attorney -in -fact must attach a certified copy of the Power of Attorney. Signature: Name (Type or Print): Laurie Darzert Notary Public in and for said County and State My Commission expires: July 24_, 2011 APPROVED AS TO FORM: By: George H. Eiser, IIi City Attorney LAURIE DARGERT Notary Public - State of Nevada Recorded in Washoe County No: oral sz-2 • Expires e •res Jury 24, 2011 N........................-...,..,;: try 6.1NOx 9 Bond No. BDC12143 Prem: See Performance Bond PAYMENT BOND THE DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA SPECIFICATION NO. 08-020 G AVENUE KNOW ALL MEN BY THESE PRESENTS: That WHEREAS, The Community Development Commission of the City of National City, • by Resolution No. 2008-_, passed the 21st day of October, 2008 has awarded to Flores Sierra Contractors, Inc., hereinafter designated as the "Principal", the contract for the DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA, SPECIFICATION NO. 08-1820 G AVENUE WHEREAS, said Principal is required by Chapter 5 (commencing at Section 3225) and Chapter 7 (commencing at Section 3247), Title 15, Part 4, Division 3 of the California Civil Code to furnish a bond in connection with said contract; NOW, THEREFORE, we, the Principal and Western Jnsurangx Company as surety, are held and firmly bound unto The Community Development Commission of the City of National City, hereinafter called the "City", in the penal sum of thirty thousand three hundred fifty -two exactly dollars ($33,352.00.) lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if said Principal, his/her or its subcontractors, heirs, executors, administrators, successors, or assigns, shall fail to pay any of the persons named in Section 3181 of the California Civil Code, or amounts due under the Unemployment Insurance Code with respect to work or labor performed by any such claimant, or for any amounts required to be deducted, withheld, and paid over to the Franchise Tax Board from the wages of employees of the Contractor and his subcontractors pursuant to Section 18806 of the Revenue and Taxation Code, with respect to such work and labor the Surety will pay for the same in an amount not exceeding the sum hereinafter specified, and also, in case suit is brought upon this bond, a reasonable attorney's fee, to be fixed by the Court. This Bond shall inure to the benefit of any of the persons named in Section 3181 of the California Civil Code, so as CO give a right of action to such persons or their assigns in any suit brought upon this bond. Nv 6n/rot 10 PAYMENT BOND (CONTINUED) THE DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA SPECIFICATION NO. 084820 G AVENUE It is further stipulated and agreed that the Surety on this bond shall not be exonerated or released from the obligation of this bond by any change, extension of time for performance, addition, alteration or modificationin, to, or of any contract, plans, specifications, or agreement pertaining or relating to any scheme or work of improvement hereinabove described or pertaining or relating to the furnishing of labor, materials, or equipment therefore, not by any change or modification of any terms of payment or extension of the time for any payment pertaining or relating to any scheme or work of improvement hereinabove described, nor by any rescission or attempted rescission of the contract, agreement or bond, nor by any conditions precedent or subsequent in the bond attempting to limit the right of recovery of claimants otherwise entitled to recover under any such contract or agreement or under the bond, nor by any fraud practiced by any person other than the claimant seeking to recover on the bond and that this bond be construed most strongly against the Surety and in favor of all persons for whose benefit such bond is given, and under no circumstances shall Surety be released from liability to those for whose benefit such bond has been given, by reason of any breach of contract between the owner of Public Entity and original contractor or on the part of any obliges named in such bond, but the sole conditions of recovery shall be that claimant is a person described in Section 3110 or 3112 of the California Civil Code, and has not been paid the lull amount of his claim and that Surety does hereby waive notice of any such change, extension of time, addition, alteration or modification herein mentioned. IN WITNESS WHEREOF three identical counterparts of this instrument, each of which shall for all purposes be deemed an original thereof, have been duly executed by the Principal and Surety above named, on the 5th day of November , 2008. Western Insurance Company (SEAL) Flores Sierra Contractors (SEAL) inc. (SEAL) /vv k / (SEAL) Clovia L. l,ehto, Attorney -In -Fact Surety (SEAL) (SEAL) 11 PAYMENT BOND (CONTINUED) THE DEMOLITION AND DISPOSAL OF BUILDINGS LOCATED AT 1820 G AVENUE, NATIONAL CITY, CALIFORNIA SPECIFICATION NO. 08-1820 G AVENUE ATTORNEY -IN -FACT ACKNOWLEDGEMENT OF SURETY STATE OF Nevada ) ) ss COUNTY OF Washoe ) On this day 5th of November , 2008, before me, the undersigned, a Notary Public in and for said County and State, personally appeared Jlovia L. Lehto __ proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument as the attorney -in - fact of the Western Insurance Company , the corporation named as Surety in said instrument, and acknowledged to me that he subscribed the name of said corporation thereto as Surety, and his own name as attorney -in -fact. NOTE: Signature of those executing for Surety must be properly acknowledged. NOTE: The Attorney -in -fact must attach a1 certified copy of the Power of Attorney. Name (Type or Print): Laurie Dargert (Notary Public in and for said County and State) My Commission expires: July 24, 2011 APPROVED AS TO FORM: By: f 7 George H. Eiser, III City Attorney GERT ......................................................... •^^"""""" .. LAURIE DARGERT ", Notary Public - Stateto £ A ; J •�; lment Recorded WaGtioe County 07�c 52.2 • Expires July 24, 2011 rev Af24 12 Bond No. BDC12143 WESTERN INSURANCE COMPANY POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That WESTERN INSURANCE COMPANY. a corporation organized and existing under the laws (tithe State of Nevada and having its principal office at the City of Reno. in the State of Nevada. does hereh� constitute and appoint 319100 Dick L. Rottman, Bradley A. Pearce, Janice L. Bowman, R. Scott Rottman, Clovia L. Lehto, Amy J. Simpson, Robert G. Shattuck, Kathy M. Harshbarger Of the STATE OF NEVADA its true and lawful Attorncy(s)-in-Fact, each in their separate capacity if more than one is named above. to sign its name as surety to, and to execute, seal and acknowledge any and all bonds. undertakings, contracts and other written instruments in the nature thereof on behalf of the Company in its business of guaranteeing the fidelity' of persons: guaranteeing the performance of contracts: and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. In Witness Whereoff, the said WESTERN INSURANCE COMPANY has caused this instrument to he sealed with its corporate seal. duly attested by the signatures of its President and Secretary, this 19°' day of June, 2006. WESTERN INSURANCE COMPANY (Signed) By (Signed) By e-erif Secretary STATE OF NEVADA) CO(;NIY OF WASHOE ) On this 19 ' day olJunc, 2006, before me personally came DICK L. ROTTMAN, PRESIDENT of the WESTERN SS: INSURANCE COMPANY and CAROL B. INGALLS. SECRETARY of said acquainted. who being by me severally duly sworn, said, that they, the sa respectively the PRESIDENT and the SECRETARY of the said tW1AT which executed the tbregoing Power of Attorney. that they e of Attorney was such corporate seal, that it was so aftij d by their names thereto by like order as PRESIDENT My Commission expires the 31 1 + AT the seal1 er of the 4r�(/didirectors 1 RETAR , bipLhvely. of thek-S•n arch. _0l� (1)V PATRIC:IAA LE rSON k'S-torgne�it) y, with both of whom I am personally ROTTMAN and CAROL B. INGALLS were INSUR • E COMPANY. the corporation described in o 'a .. .oration. that the seal affixed to said Power said corporation, and that they signed y icia A. Letson Notary Public This Power of Attorney is grants t1ftO nd by authority of the following Resolutions adopted by the Board of Directors of the WESTERN INSURANCE COMPA, on June 19. 2006. RESOLVED. that in connection with the fidelity and surety insurance business of the Company. all bonds, undertakings. contracts and other instruments relating to said business may he signed. executed, and acknowledged by person or entities appointed as Attorneyls)-in-Fact pursuant to a Power or Attorney issued in accordance with these resolutions. Said Powcr(s) of Attorney for and on behalf of the Company may and shall be executed in the name and on behalf of the Company, either by the Chairtnan. or the President. or a Vice President. jointly with the Secretary, under their respective designations. The signature of such officers may be engraved, printed or lithographed. The signature of each of the foregoing officers and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any certificate relating thereto appointing Attomey(s)-in-Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof. and , unless subsequently revoked and subject to any limitations set forth therein, any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is validly attached. RESOLVED. that Attorney(s)-in-Fact shall have the power and authority. unless subsequently revoked and, in any case. subject to the terms and limitations of the Power of Attorney issued to them, to execute and deliver on behalf of the Company and to attach the seal of the Company to any and all bonds and undertakings. and other writings obligatory in the nature thereof, and any such instrument executed by such Attorney(s)-in-Fact shall be as binding upon the Company as if signed by an Executive Officer and sealed and attested to by the Secretary of the Company. 1, CAROL B. INGALLS. Secretary of the WESTERN INSURANCE COMPANY, do hereby certify that the foregoing is a true excerpt from the Resolution of the said Company as adopted by its Board of Directors on June 19. 2006 and that this Resolution is in lull force and effect. I. the undersigned Secretary of the WESTERN INSURANCE COMPANY do hereby certify that the foregoing Power of Attorney is in till forcean i effect and has not been revoked. In Testimony Whereof, I have hereunto set my hand and the seal of the WESTERN INSURANCE COMPANY on this 5thdaC.:of�ii�y.�t?Zqber -------..__200$ _ � � _. _- •`P+'OMo a'.,1 Secretary SEAL 1994Eo J State of ' 1' County of criit / -y On / Zeog' before me, Notary Public, personally appeared ALL-PURPOSE ACKNOWLEDGEMENT Name(s) of Dodument Signer(s) who proved to me on the basis of satisfactory evidence to be the person(&} whose name(e) isLafe subscribed to the within instrument and acknowledged to me that hefshe/they. executed the same in his/her/their authorized capacity(ies), and that by his/ l er/t} rein signature(&} on the instrument the person($, or the entity upon behalf of which the person(e) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the forgoing paragraph is true and correct. t'ITNESS hand and official seal Signature of Notary M. LOPEZ Commission . 1609539 Notary Pubic - CaMlomia t San Diego County kV Comm. balms Sep Za (Affix seal in the above blank space) 11/24/2008 15:31 FAX 6196280593 FLORES_SIERRA I,J UU2/O11 ACORD,,, CERTIFICATE OF LIABILITY INSURANCE PRODUCER (916) 770-2900 FAX: (916) 728-2224 J6 Insurance Sorvicee 2204 Plaza Dr. Ste 200 Rocklin CA 95765 INSORED Flores/Sierra Contractors, Inc. 1547 Jayken Way Suite B Chula Viet* CA 91911 DATE (MM/OD/YYYY) 11/4/200S THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE INSURER A:ACA WEI IStchester S cialty M9uRER s: Century National INSURER C: Evanston Insurance NAIC 0 INSUESRD State Fund INSURER E• THE POLICIES REQUIREMENT, THE INSURANCE AGGREGATE OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUF_O OR MAY PERTAIN. AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS ANC) CONDITIONS OF SUCH POLICIES. LIMITS_SHOWN MAY HAVE BEEN REDUCEDAY PA/D CLAIMS, INSR LTR ADM1NSR0 INSRO TYPE OF INSURANCE POLICY NUMBER PDATEYMMP/DOmE i L pp POLICY ( MIPO N � LIMITS A GENERAL UAsun, COMMERCIAL GENERAL UABIUTY o8PKG016Bo 3/14/2008 3/14/2009 G .,�.pAOf�Hq oG!<URgENCE s 1,000 , 000 X ]AMAI�yQ i RENTED REM @ES ME) TEDr 50,000 I CLAIMSMADE © OCCUR MCDExP(Any), one rarscu_ s 5,000 X Pollution (OOOur) PERSONAL I(s ADV INJURY 3 1,000,000 Asbestos 6 Lead GENERALA13SiBE0ATE $ 2,000,000, S 2,000,000 GENL AGGREGATE LIMIT�APPLIES PER: PRODUCTS - COMPIDP ADE. I POLICY n';0 1: El LQC AUTOMOBILE LIABILITY ANY AUTO ALLOWNeDAutos SCHEDULED AUTOS HIRED AUTOS NON.OWNED AUTOS cosop Dad Q 1, 000 T.AP0161931 6/2/2000 6/2/2009 COMBINED SINGLE LIMIT (Eaeccldenl) 3 1,000,000 —_ X BODILY INJURY (Per pardoh) 3 BODILY INJURY (Per accident) S X X PROPERTY DAMAGE (P9r sAuldellI) 3 X X Collision Ded 01, 000 GARAGE LIABILITY ANY AUTO AUTQ ONLY • § ACCIDENT $ OTHER THAN MCC $ 1 AUTO ONLY: AGO C EXCESSIUMSRELLA UABIUTY 088SX00010 3/14/2008 3/14/2009 oLCURRFl•ICE 3 2,000,000 _EACH AGPREGATE I- 2,000,000 $ OccUR CLAIMSMADE DEDUCTIBLE RETENTION 3_10,000 - I 9 $ X D WORKERS EMptoANY PROPRIETOR/PARTNER/E%ECUTIVE OFFICER/MEMBEREXCLUDED7 If yes, SPECIAL deech00 PROYISI0NU3ldh COMPENSATION' LIN EAND under 713001588206 4/1/2000 4/1/2009 X T097 ThJ Tr E.L. EACH ACCIDENT 3 1,000,000 EL D16wE•,Ft,EMPLOYEE! 1,000,000 E LgSEA -POLI_L1W $ 1,000,000 OTHER -0B6CRJPT10N or OPERATON3ILOCATIONSNEHICLC5ICXCLUSi0NS ADDID BY ENDORSEMENTI9PECUAL PROVISIONS CITY OF NATIONAL CITY (1243 NATIONAL CITY SOJ EVARD, NATIONAL CITY, C.D. 91950) in named •■ additional insured •s raapeots ineured•a operations. P. JOB * R07060-0e (1820 G. AVE., NATIONAL CITY, C7 91950) ECU Coverage Iio1uded_ *10 Day Notice of Cancellation for Non-PAysnente Thin document ifs used to provide evidence of insnrenoa and does not amend, expand, or alter the terms of the policy. CERTIFICATE HOLDER CANCELLATION CITY OF NATIONAL CITY 1243 NATIONAL CITY BOULEVARD NATIONAL CITY, CA 91950 ACORD 25 (2001 /00) ILgr C,A.Ae, na. SHOULD ANY OP THE ABOVE DESCRIBED POLICIES DE CANCELLED BEFORE THE EXPIRATION GATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL * 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE MOLDER NAMED TO THE LEFT, DtJT FAILURE TO 00 50 SHALL IMPOSE NO OBLIGATION OR UABILRY OF ANY KIND UPON THE INSURER, ITS AGENTS OR REPREBYNTATIVER. AUTHORIZED REPRESENTATIVE Administrator/JAMIE tB ACORD CORPORATION 1988 11/24/2008 MON 14:54 (JOB NO. 89611 Z002 11/24/2008 15:31 FAX B196280593 FLORES_SIERRA IQJVVJ/V I I POLICY NUMBER: 08PKG01680 ENDORSEMENT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART CONTRACTORS POLLUTION LIABILITY COVERAGE PART PROFESSIONAL LIABILITY COVERAGE PART SCHEDULE Name of Person or Organization: AS PER WRITTEN CONTRACT (If no entry appears above, information required to complete this endorsement will be shown in the Declarations as applicable to this endorsement.) WHO IS AN INSURED (Section II) is amended to include as an insured the person or organization shown in the Schedule, but only with respect to liability arising out of "your work" for that insured by or for you. "Insureds are advised that certificates of insurance should be used only to provide evidence of insurance in lieu of an actual copy of the applicable insurance policy. Certificates should not be used to amend, expand, or otherwise alter the terms of the actual policy." ALL OTHER TERMS AND CONDITIONS REMAIN THE SAME. IE-0036-0404 1 of 1 11/24/2008 MON 14:54 [JOB NO. 8961I f 003 11/24/2008 15:32 FAX 6188280593 FLORES_SIERRA tjUU4/U 1 I MU r VK r✓^ Wcr<IER POLICIES OF INSURANCE FOR P 'AC LIABILITY UNDER S� J'7NS 29 AND 30 OF THE MOTOR CARFs/ ACT OF 1980 Issued to Pacific Treatment Environmental Services, SA de CV. of El CAJON, CA 97020 Dated at _ GLENDALE, CALIFORNIA OMB No. 2125-0074 Amending Policy No. $aP/1131104 -07 effective Date .12/01/07 Name of Insurance Company ZURICH AMERICAN IN_SURANE.CQMPANY Telephone Number _ (818) Ji00-4700 . Countersigned by The policy to which thls endorsement is attached provides primary or excess insurance, es indl :ted.y (2) . or thn: X This Insurance is primary and the company shall not be liable for amounts in excess of $ 1.000,000. CSL for each accident. X This insurance is excess and the company shall not be !fable for amounts In excess of $ 5.000.000 for each accident in excess of the underlying limit of 31.000.000 POLICY NUMBER SEO 3773010-05 for each accident. Whenever required by the Federal Highway Administration (FHWA) or the Interstate Commerce Commission (ICC), the company agrees to furnish the FHWA or the ICC a duplicate of said policy and all its endorsements. The company also agrees, upon telephone request by an authorized representative of the P1-tWA or the ICC, to verify that the policy Is In force as of a particular date. Cancellation of this endorsement may be effected by the company or the insured by giving (1) thirty-five (35) days notice in writing to the other party (said 35 days notice to commence from the date the notice Is mailed, proof of mailing shall be sufficient proof of notice), and (2) if the insured la subject to the iCC's Jurisdiction, by providing thirty (30) days notice to the ICC (said 30 days notice to commence from the date the notice is received by the ICC at he office In Washington, D.C.). DEFINITIONS AS USED iN THiS ENDORSEMENT ACCIDENT includes continuous or repeated exposure to conditions which results In bodily Injury. property damage, or environmental damage which the insured neither expected nor intended. MOTOR VEHICLE means a land vehicle, machine, truck, tractor, trailer, or sernttrafer propelled or drawn by mechanical power and used on a highway for transporting property. or any combination thereof. BODILY INJURY means injury to the body, sickness, or disease to any person. Including death resulting from any of these. ENVIRONMENTAL RESTORATION means restitution for the loss, damage, or destruction of natural resources arising out of the acddantal discharge, dispersal, release or escape Into or upon the !and, atmosphere, watercourse, or body of water. of any commodity transported by a motor carrier. This shall Include the cast of removal and the cost of necessary measures taken to minimize or mitigate damage to human health, the natural environment, fish, shelltlate and wildlife. PROPERTY DAMAGE means damage to or loss of use of tangible property. PUBLIC LIABILITY means liability for bodily injury, property damage, and environmental restoration. The insurance policy to which this endorsement is attached endorsement thereon, or violation thereof, shall relieve the provides automobile liability insurance and la amended to assure company from liability or from the payment of any final Judgment, compliance by the insured, within the limits stated herein, as a Within the limit of liability herein described, irrespective of the motor carrier of property, with Sections 29 and 30 of the Motor financial condition, insolvency or bankruptcy of the Insured. Carrier Act of 1980 and the rules and regulations of the Federal However, all terms, conditions and limitations in the policy to Highway Administration (FHWA) and the Interstate Commerce which the endorsement Is attached shalt remain in full force and Commission (ICC). effect as binding between the Insured and the company. The ln consideration of the premium stated in the policy to which this Insured agrees to reimburse the company for any payment made byendorsement is attached, the insurer(the company) egreee to to the company on account ofoany icy. accident, claim, or suit Involving a breach of the terms the policy, and for any payment pay, Within the limits of Uabltlly described herein, any fine( that the company would not have been obligated to make under Judgment recovered against the Ensured for public liability resulting the provisions of the policy except for the agreement contained In from negligence in the operation, maintenance or use of motor this endorsement. vehicles subject to the financial responsibility requirements of Sections 29 and 30 of the Motor Cartier Act of 1980 regardless of It Is further understood and agreed that, upon failure of the whether or not each motor vehicle is specifically described in the company to pay any final Judgment recovered against the Insured policy and whether or not such negligence occurs on any mute or as provided herein, the judgment creditor may maintain an action in any territory authorized to be served by the insured or in any court of competent jurisdiction against the company to elsewhere. Such insurance as is afforded, for public liability, does compel such payment. not apply to injury to or death of the insuod's'employees while The Limits of the company's liability for the amounts prescribed in engaged in the course of their employment, or property this endorsement apply separately, to each accident, and any transported by the insured, designated as cargo. It Is understood payment under the policy because of any one accident shall not and agreed that no condition, provision, stipulation. or limitation operate to reduce the !lability of the company for the payment of contained In the policy, this endorsement, or any other final judgments resulting from any other accident The Motor Carrier Act of 1980 requires limits of financial responsibility according to the type of carriage and commodity transported by the motor carrier. it la the MOTOR CARRIER'S obligation to obtain the required limits of financial responsibility, THE SCHEDULE OF LIMITS SHOWN ON THE NEXT PAGE DOES NOT PROVIDE COVERAGE. The Umlts shown In the schedule ere for infuriation purposes only. Form MCS-80 (Over) UNIFORM INPORMATION SERVICES, INC. MC 1822k (0099) 11/24/2008 MON 14i54 ( JOB NO. 8961) LA004 11/24/2008 15:32 FAX 6196280593 FLORES_SIERRA JOOS/oii Type of Carriage Public Liability Commodity Transported Minimum Insurance (1) For -hire (in interstate or foreign commerce). (2) For -hire and Private (In interstate, ' foreign, or intrastate commerce). (3) For -hire and Private (In interstate or foreign commerce: In any quantity) or ((n intrastate com- merce: In bulk only). (4) For -hire end Private (In interstate or foreign commerce). Property (nonhazardous). 750,000 Hazardous substances, as defined in 49 CPR 1711, 5,000,000 transported in cargo tanks, portable tanks, or hopper - type vehicles with capacities in excess of 3,500 water gallons; or In bulk Divisions 1.1, 1.2, and 1.3 materials; any quantity of Division 2.3 Hazard Zone A or Division 6.1, Packing Group 1, Hazard Zone A material; in bulk Division 2.1 or 2.2; or highway route controlled quantities of a Class 7 materiel as defined in 49 CFR 173.403. Oil listed in 49 CFR 172.101, hazardous materials and hazardous substances defined in 49 CFR 171.8 and listed in 49 CFR 172.101, but not mentioned in (2) above or (4) below. Any quantity of Division 1.1, 1.2 or 1.3 material; any quantity of a Division 2.3, Hazard Zone A, or Division 6,1, Packing Group 1, Hazard Zone A material; or highway route controlled quantities of Class 7 material as defined in 49 CFR 173,403. 1,000,000 5,000,000 Note: The type of carriage listed under (1), (2), and (3) applies to vehicles with a gross vehicle weight rating of 10.000 pounds or more. The type of carriage listed under number (4) applies to all vehlcies with a gross vehicle weight rating of less than 10,000 pounds. SCHEDULE OF LIMITS Public Liability For -hire motor carriers of passengers operating in interstate or foreign commerce Vehicle Seating Capacity (1) Any vehicle with a seating capacity of 16 passengers or more. ;2) Any vehicle with a seating capacity of 15 passengers or Tess. Minimum Insurance 5,000,000 1,500,000 )rrfl MCS-90 (OVef) UNIFORM INFORMATION S6RWcr:3. INC. MC 1622k (10.99) 11/24/2008 MON 14:54 [JOB NO. 8961) t1005 11/24/2008 15 32 FAX 6136280583 FLORES_SIERRA to UUti/U I I Type of Unit SCHEDULE OF UNITS Unit Designation Number "ANY VEHICLE OPERATED BY THE NAMED INSURED" (if more space is needed, attach a separate sheet) stave of caiitornio FO OSPR•1930 ()/0]) • 11/24/2008 MON 14:54 [JOB NO. 8961] lJ006 11/24/2008 15:32 FAX 8196280593 FLORES_SIERRA LA 007/01 1 FT Ito .revi- 04AmE AGDAEss, AND Ptioks1t ZURICH AMERICAN 2Z,1rg, Q 1PANY B01 N. BRAND ELvD., •pH GLE DALE, CA 92203 sater A Put* Saabs Atoney CERTIFICATE OF INSURANCE Motor Carriers Of Property NAOS00IMAM'SAvt1•QRQZO110RlteONTATIVE ALEX INSURED (JOTOq CAF RI6R MAC ANO ADOR PACIFIC TREATMENT ENVIRONMENTAL SERVICES, SA DE CV 1452 N. JCeNSCIN AVENGE EL cAJal, CA 92020 Status: Licensed to write Insurance In the State of California (Admitted Insurer! ❑ Non drntaoa Insurer subject to Section 1763 of the Calif rule InsuranCe Code. ❑Vde Charltablo Filak Pool WAp1.ue�INZOFC EAl1A Alert with the: Callfoml4 aepenvnent of Motor Vehicles Motor Corder Permit aranoh P. O. Bo:111237U MS OA75 Sacramento. CA ra4232.3700 insurer certifies that the motor carrier of (018) 657-0153 Injury or r death liability, 6liability property Identified herein (In uredd) Is Cdvered by an Insurance lie Iifiut! balsa and as re , prop r C� n al obi ity Insurance, �lo a Workersp 34631,5 d p0 y a o IImpp bodily of Federal Regulations. y P q Compensation Insurance within the coverage Illttfts !clan. 8 640, and by Pan 367 of Title 49 of the Code lYP6 vF Pt8UA11NCE . _ Insurer certifies that this insurance policy cdvers all vehicles used in conducting the service performed by the Insured ter a motor carrier permit is required whether or not said vehicle is listed In the Insurance policy. • • Insurer eerll/Ids that a fully executed Endersement, on a form authoAzed by o which Vehicles to thg referenced o cy, td conform the policy to the requtrement9 of the Motor Carriers or Property Permit Act Col' Vehicle Code Beetle p the Carriers of Property Motor Vmit A s (California Is EN II egg) and the rules and regulations bf the OMIT, (This provision does not apply to Workers' Ia oeDMV. tten on en authonzof of Cancellationrm an Irly_(3p] da a notice 1 m the Insuter to the . the Notbe o! Cancel cdved at the office of theCalifornia y period common s to run rRim e Branch In S f Cartlpnto.ta fv S mia aparitment of Motor Vehicles,ate o Insurer agrees to furnish DMV withduplicateI lulotor Carrier Permit a original of the referenced policy,:OMV authorized endorsement, end elf other related endorsements to f andOMV with documentation upon o.,Aet, of the CVC Soction o54.2. Insuere w thatfor the purposes of Charitable Aisk Pool Coverage Net title policy meets the reQulremerlts of subdivision (b) By signing fh/y form, the Insurer certifies under penalty of o Information contained In this Cerfll1Cafo of Insurance IS true end P �u ry under the laws of the State of California that all fl; AT tcsrArp correct. . dratiaArds CA 71►YVq@ OF 1.18JNEAT +4rrr10h= Rare tsiorr e ()ATE 2010.2 GED rr! 11/24/2008 MON 14:54 [JOB NO. 8961) L1007 .11/24/2008 15:32 FAX 6198280593 FLORES_SIERRA 4100b/011 TOIREF AlSUAAt COMPANY) (MIME. ADORESB. MO PHONE A A Pltlik Service Agency CERTIFICATE OF INSURANCE Motor Carriers of Property =MICR AMERICAN INS, COMPANY 801 N. BRAND BL.VD-, #Pt9 Q•END►LE► CA 91203 N♦ 1653g muff Cr wst'1nWs £uT1.1011 PO AVADserfrenve ALEX JQZJ INSURED (MOTOR CARRIER Awe AND ADORES.% PActrxC TARNSENVIRCIMINTAL SERVILI&S, x c. 1452 N. JOIDZSCH AVENUE FZ. civari. CA 92020 Status: 12 Licartsed to write Insurance In the Stele of California (Admitted Insurer) ❑ Nonadmitted Insurer subject to Section 1763 el the Cefffm(a insurance Code. 0 Charitable Risk Poet eUe1'1115 LOU unease wNis Filed with the: C& fomla Department of Motor Vehidee Motor Denier Permit Branch P. O. Box 832370 MS G875 Socrnmento, CA 94232.3700 (916) s57-8153 Insurer oerilfle., that the motor carrier of AA party identified herein (Iured) is covered by an Insurance policy providing bodily . Injury or death liability, property damage !lab!!! insurance. or Workers' Compensation Insurance within the coverage limas Iden- tified below and as required by CBlifprnht Vet)! le Code sections 34630, 34631.5, 34640, and by Part 387 of Title 49 of the Code of Federal Regulations. TYPE of iNsuRAWCe POIJCY NdbtAER maim ar►eonve Ial1TL'1WwWrTI LIMITS PRIMARY LiLWUTY Q Cedar>Ipo 0etaw.mtulary nitrpmum MJm. (� Cavetapo equal to or e®eeaing statutory minimum thole. BAP 3773004 12/01/07 ZOMBimED SBK LIMIT. UOOIL.YINJURY ORDEATH PONE PERSOM OCI.Y U'R 1 on' Oes- .4Pea THAN ONE PeiSDN) FIROP RTYDAMAGE $ 1,000,000. axCEDG 0 cavUe*aas bowmen lUDr platy ad statutory Nedrr minimum O. aCaveraaa prorldaa et or above' atntuary minimum Omits. SEEIO 3773g10 12101/07 eciABINED 9INOLE LIMY UbOILY INJURY (QNE PERSON) O LY INJURY OR o P RE THAN et heoaoua t 1M $ In mots or 3 lrl Wadi of 1 PhOPERTY DAMAI3E letmom d s WORKERS' cOMPCNBATian 377300E 1 /01 /07_ )(I) we eetAlory Umu. lasuret Godlike that ibis Insurance pollcy coi}ens all vehldes used In conducting t service performed by the insured for which a motor carrier permit le required whether of ric t snld vehicle Is listed In the Insuran poflcy. Insurer Earl/fine Oaf a fully executed Endorsement, on a form authorized by the Departrrhent of Motor Vehicles (DMV), Is attached to the referenced np icy, to totifbtm the poky to the requirements of the Mgfor Carriers of Property Permit Ad (CallFornie Vehicle de Sect! 'LA 9) and the rules end regulations of the DMV. (this provision does not apply to Workers' o Jn . ree►nes t at this �at�if(cstg Iof In ranee sha((�,Q�glyrttbstpg on s trim((( IS01 days notice from the Insurer to the DMV, written on an authaiftl:ed Notice or Cartc>elranon forth Land that (Shia thirty (30 Weanedreommences to rum from the' date of the Notice of Cancellattke�io��rr��ss� ved at the office of the Catftornla Deparjrnent of Motor Vehicles. Motor Carrier Permit 'ranch in Secramenta,,te�►1Pif� insurer agrees to furnish DMV with a dupliceite original of the referenced policy.+DMV authorized endorsement, and all other elated endorsements and documentation upon request. Insurer agrees that for the purposes of Charltoble Risk Poo? Coverage that this policy meets the requirements of subdivision (b) r the CVC Section 15054,2. y signing this farm, fro Insurer certifies under penel(y of perjury under lips laws al the State of California that all Formation contained In this Cortifleate of Insurance is true and correct. aarr o •Y loll, Wr*Tn diStiDAL134 CA rATutle OP IN:WAWJt A AUTOeIZto PIO Hte tl'rATNe DATE 1JL lain -- 11/24/2008 MON 14:54 I JOB NO. 8961) V1008 11/24/2003 15:32 FAX 6196280593 FLORES_SIERRA l0009/Ul 1 4✓ CALIFORNIA ENDORSEMENT FOR MOBILE TRANSFER UNITS AND TRANSPORTABLE TREATMENT UNITS OIL SPILL LIABILITIES 1. This Endorsement forms a part of the Policy to which it is attached; 2. This Endorsement provides coverage for any legal liability or damages as specified under the Lempert-Keene-Seastrand Oil Spill Prevention and Response Act (California Government Code Section 8670.1 et seq.; herein "the Act") including Government Code Section'8670.56.5, as a result of a discharge of oil into or upon the Marine waters of the State of California or a discharge of oil in an area that threatens to impact those marine waters from or by any of • the Insured's Mobile Transfer units or Transportable 'Treatment Units covered by .the Policy; 3. The Insurer agrees to pay such amounts, subject to the monetary limits prescribed within the Policy, for which the Insured assumes, or is or may be judicially, - administratively, or other*Kise legally obligated to pay under the Act. The Policy shall apply to all such claims arising under the Act during the period covered by the Policy and before the effective date of the termination or cancellation; 4. Notwithstanding this Endorsement, the Insurer does not agree to be a guarantor for purposes of the Act or the Federal Oil Pollution Act Of 1990, nor does this evidence of insurance constitute consent to allow third party claims to be • asserted directly against the Insurer, nor create a direct action right against the Insurer. . 5, Termination or cancellation of this policy— insofar as it servea as proof of the Insured's financial responsibility pursuant to Title 14, California Code of Regulations, Section 795(a), shall not become effective until 60 days after notice, with the exception for nonpayment of premium which will require 30 days notice, has been submitted in writing by *the Insurer to the Insured and to the California Department of Fish and Game Office of Spill Prevention and Response; Start of California PG OSPA-1930 (3/01) 11/24/2008 MON 14:54 (JOB NO. 89611 0009 11/24/2008 15:33 FAX 6196280593 FLORES_SIERRA ------------- lJJo1o/oll 6. 'Except as expressed in this Endorsement, all other terms and conditions of the Policy remain unchanged. The policy to which this Endorsement is attached provides primary or excess insurance as indicated by "x", for at least the limits shown: This insurance is primary and the company shall not be liable for amounts in excess of $ ki44000,000 for each oil spill incident. The insurance deductible amount is $ 5,000 PER ACCIDENT o This insurance is excess and the company shall not be liable for amounts in excess of $ _ for each oil spill occurrence in excess of the underlying limit of $ for each oil spill incident. The insurance deductible amount is $ PACIFIC TREATMENT ENVIRONMENTAL 1452 N. JOHNSON AVE. Issued to SERVICES, SA DE CV of EL CAJON, CA 92020 Insured ' Dated at _SJ .ENT-AL.E Amending Policy No , BAP 3773004 Name of Insurance Company Countersigned by State of calUEorn;a rc OSPR-t910 (3/01) this. _ day of NDVEL1AF1't Effective Date i2/ni In7 Authorized Underwriter Representative 11/24/2008 MON 14:54 (JOB NO. 89611 ( i 010 .11/24/2008 15:33 FAX 6198280593 FLORES_SIERRA tM 011/011 - tI-2 k 006 OT:86am From _._.,, - cs,CENTURY-NATIONAL INSURANCE COMPANY BUSINESS AUTO POLICY - ENDORSEMENT COmr0nr2OR9 2,0LtcT 242=0, Policy cowry l2a( 12:01 MI Car 06/02/200B To 06/02/2009 IISDOie,9 IDi4T 21nr=f1V2 P. , 11/20/2006 Mot 03,43 Y!e INSURED- 'LORES-SIERRA CONTRACTORS IN 1547 JAYKEN WAY SUITE B Cf ULA VISTA CA 91911 T-Teo P,001/001 F-062 POLICY NO.: BAP0161931 21Q8, 1 12olusR X0.: 166700 ExDORgrs90IT Ho., 21 BROKER: WEITCOMB SURPLUS LINES BILKS 1612 CAT J.INA AVE R.EDONDO BEACH CA 90277--8710 ADDITtoNAL INSURED ENDORsEMZNr CN613 (5/99) CA IT IS AGREED TR9►T INSURANCE AFFORDED BY THE ABOVE POLICY RBALL APPLY TO TEE pAATY(0) NAB BXLOW, AD THEIR INTEREST NAY APPEAR BUT BRALL NOT Mil:RAVI To INCBEASS YEN = IITS OF TEM COMPANY'S LIABILITY. ANY ADDITIONAL INSUM= LANOUAGB ON A CS;i2'iBICATS OP INSURANCE IS VOTE. The additional insured named below is only an insured for liability which is the result of an aCt or eamiasien of the suggodem ig8U7tEDo et the policy and shall have an coverage under this endorsement or the policy for its own aebs or oaaissions, those of its agents or amptoyneS, or these of any other person or entity for which it is vicariouesly liable, save for acts of mmisaie= of the nNANND MRSURED" of the policy. Further, any insurance provided by this endorsement aha,ll be exceed insurance to all other insurance available to any person or entity who becomes an insured by reason of this andoreeQmant whether the other assurance be primary or excess and whether or not the other insurance be collectible. in the event the other insurer has a duty to defend any person or entity added to our policy by reason of this endorsement, we w1X1 have no duty to defend that parson or entity however, we may elect to do so, and, if wo do, we will be entitled to the rights of any pereoa or • tity we -- defend against the other insurer. Sys Authorised .pr- Y..tativs ADDXTIO2 1. INSURED CITY OF NATIONAL CITY 1243 NATIONAL CITY BLVD NATIONAL CITY CA 91950 Date Printed : 11/21/200B LYTTA VAMORA 11/24/2008 MON 14:54 [JOB NO. 8961] CJ011 RESOLUTION NO. 2008 — 227 RESOLUTION OF THE COMMUNITY DEVELOPMENT COMMISSION OF THE CITY OF NATIONAL CITY AWARDING A CONTRACT TO FLORES SIERRA CONTRACTORS , INC., IN THE AMOUNT OF $33,352 FOR THE DEMOLITION OF A SINGLE-FAMILY RESIDENTIAL UNIT LOCATED AT 1820 G AVENUE, NATIONAL CITY, AND AUTHORIZING THE APPROPRIATION OF SAID FUNDS FROM THE TAX INCREMENT UNDESIGNATED FUND BALANCE ACCOUNT TO THE 1820 G AVENUE DEMOLITION ACCOUNT WHEREAS, the CDC acquired the property located at 1820 G Avenue using $875,000 in federal HOME funds to develop an affordable housing project; and WHEREAS, on November 21, 2006, the CDC entered into an Exclusive Negotiations Agreement (ENA) with Habitat for Humanity to prepare plans for the development of affordable housing on the site; and WHEREAS, on October, 7, 2008, the CDC approved a Disposition and Development Agreement (DDA) with Habitat For Humanity for the development of an eight (8) unit townhome development affordable for families at sixty (60%) of the area median income; and WHEREAS, pursuant to the ENA and DDA, the CDC agreed to demolish an existing single-family residential unit and an out -building on the site prior to turning the property over to Habitat for Humanity; and WHEREAS, representatives of the Community Development Commission of the City of National City ("CDC"), in open session on October 1, 2008, did publicly open, examine, and declare four sealed bids for the demolition of a single-family residential unit located at 1820 G Avenue in National City. NOW, THEREFORE, BE IT RESOLVED that the Community Development Commission of the City of National City hereby awards the contract for the demolition of a single-family residential unit and out -building located at 1820 G Avenue to the lowest responsive, responsible bidder, to wit: FLORES SIERRA CONTRACTORS, INC. BE IT FURTHER RESOLVED by the City Council of the City of National City that the Chairman is hereby authorized to execute on behalf of the City a contract in the amount of $33,352 with Flores Sierra Contractors, Inc., for the demolition of a single-family residential unit located at 1820 G Avenue in National City. Said contract is of file in the office of the City Clerk. BE IT RESOLVED that the Community Development Commission of the City of National City hereby authorizes the following appropriation of funds: FROM: Account No. 522-2501 Tax Increment Undesignated Fund Balance TOTAL AMOUNT: $33,352 TO: Account No. 522-445-462-650-9024 1820 G Avenue Demolition AMOUNT: $33,352 Resolution No. 2008 — 227 October 21, 2008 Page 2 PASSED and ADOPTED this 21st day of Octo08. on Morrison, Chairman ATTEST: Bra T , Secretary APPROVED AS TO FORM: George H. Eiser, III City Attorney Passed and adopted by the Community Development Commission of the City of National City, California, on October 21, 2008, by the following vote, to -wit: Ayes: Commissioners Morrison, Natividad, Parra, Ungab, Zarate. Nays: None. Absent: None. Abstain: None. AUTHENTICATED BY: RON MORRISON Chairman, Community Development Commission Secret algc-t tuft Development Commission By: Deputy I HEREBY CERTIFY that the above and foregoing is a full, true and correct copy of RESOLUTION NO. 2008-227 of the Community Development Commission of the City of National City, California, passed and adopted on October 21, 2008. Secretary, Community Development Commission By: Deputy City of National City, California COMMUNITY DEVELOPMENT COMMISSION AGENDA STATEMENT MEETING DATE October 21, 2008 AGENDA ITEM NO. 26 ITEM TITLE Resolution of the Community Development Commission of the City of National City awarding a contract to Flores Sierra Contractors, Incorporated, in the amount of $33,352 for the demolition of a single-family residential unit located at 1820 G Avenue in National City; and establish an appropriation of $33,352 in account 522- 445-462-650-9024 PREPARED BY Jim Ridley-S (Ext. 4266) DEPARTMENT Community Development Housing and Grants EXPLANATION On November 30, 2004, the CDC received title to the property located at 1820 G Avenue in National City. Subsequently, on October 17, 2006, the CDC directed staff to work with San Diego Habitat for Humanity to prepare plans to develop the acquired site. Habitat for Humanity is a qualified and experienced affordable housing developer, and has previously partnered with the City in developing affordable for -sale units, such as the three single family residences at 1401, 1409, and 1410 Sheryl Lane. On November 21, 2006, the CDC entered into an Exclusive Negotiations Agreement (ENA) with Habitat to prepare plans for the development of affordable housing on the site. On October, 7, 2008, the CDC approved a Disposition and Development agreement with Habitat For Humanity for the development of an eight (8) unit town home development affordable for families at sixty (60%) of the area median income. As part of the Cities' agreement with Habitat for Humanity it was agreed that the City would demolish an existing house and out building on the site prior to turning the property over to Habitat for Humanity. On October 1, 2008, four (4) bids were received on the project. The low bidder was Flores Sierra Contractors, Inc., 1547 Jayken Way, Suite B, Chula Vista, CA 91911. The low bid amount was $33,352. The total estimate for the project is $33,352 and appropriations in that amount will be established in account number 522-445-462-650-9024 to fund the contract and the demolition of the single-family residential unit. Environmental Review Ni N/A Financial Statement Approved By: inance Director Funds were not budgeted, but are available in undesignated fund balance account 522-2501 and establish appropriations in account 522-445-462-650-9024. Account No. STAFF RECOMMENDATION Adopt Resolution of the Community Development Commission approving a demolition contract with Flores Sierra Contractors in the amount of $33,352 for the property located at 1820 G Avenue BOARD / COMMISSION RECOMMENDATION ATTACHMENTS ( Listed Below) Resolution No. Attachment 1: Bid Submittal Documentation Attachment 2: Bid Results Attachment 3: Bid Results Line Item Comparison Matrix A-200 (9/99) City of National City Office of the City Clerk 1243 National City Boulevard, National City, CA 91950-4397 Michael R. Dalla, CMC - City Clerk (619) 336-4228 Fax: (619) 336-4229 December 9, 2008 Mr. Alberto Flores President Flores Sierra Contractors, Inc. 1547 Jayken Way, Suite B Chula Vista, CA 91911 Dear Mr. Flores, On October 21st, 2008, Resolution No. 2008-227 was passed and adopted by the Community Development Commission of the City of National City, awarding a contract to Flores Sierra Contractors, Inc. We are forwarding for your records a certified copy of the above Resolution and a fully executed original contract. Sincerely, Michael R. Dalla, CMC City Clerk Enclosures cc: Housing & Grants Dept. ® Recycled Paper