HomeMy WebLinkAbout2013 CON SANDAG - Downtown Westside Community Corridor Project #5004283TransNet SMART GROWTH INCENTIVE GRANT PROGRAM FISCAL YEAR 2013
GRANT AGREEMENT 5004283 BETWEEN
THE SAN DIEGO ASSOCIATION OF GOVERNMENTS
AND THE CITY OF NATIONAL CITY
REGARDING DOWNTOWN - WESTSIDE COMMUNITY CONNECTIONS
THIS GRANT AGREEMENT 5004283 ("Agreement") is made this 15th day of August, 2013,
by and between the San Diego Association of Governments (hereinafter referred to as "SANDAG"),
401 B Street, Suite 800, San Diego, California, and the City of National City (hereinafter referred to
as "Grantee"), 1243 National City Boulevard, National City, California. This agreement expires on
August 15th, 2015.
The following recitals are a substantive part of this Agreement:
A. The TransNet Extension Ordinance, which became effective April 1, 2008, contains provisions
for the Smart Growth Incentive Program (SGIP).
B. Pursuant to the TransNet Extension Ordinance, the SANDAG Board of Directors allocates SGIP
monies through a regional competitive grant process to provide funding for a broad array of
transportation -related infrastructure improvements that will assist local agencies in better
integrating transportation and land use.
C. On October 12, 2012, SANDAG issued a Call for Projects from local jurisdictions in San Diego
County wishing to apply for a portion of the TransNet SGIP funding for use on capital
improvement and planning projects meeting certain criteria.
D. Grantee successfully applied for SGIP Funding for the following project: Downtown —
Westside Community Connections (hereinafter referred to as the "Project"). The scope of
work, schedule, and budget for the Project is attached as Attachment A.
E. On June 28, 2013, the Board of Directors approved the award of $9.6 million in TransNet SGIP
funds for this FY 2013 cycle of the SGIP.
F. The purpose of this Agreement is to establish the terms and conditions for SANDAG to
provide Grantee with funding to implement the Project.
G. Grantee's Project is funded with $2,000,000 in SGIP funds. The TransNet Metropolitan
Planning Organization (MPO) ID is V10.
H. Although SANDAG will be providing financial assistance to Grantee to support the Project,
SANDAG will not be responsible for Project implementation or hold any substantial control of
the Project.
NOW, THEREFORE, it is agreed as follows:
Section 1. Definitions
A. Application. The signed and dated grant application, including any amendment thereto,
with all explanatory, supporting, and supplementary documents filed with SANDAG by or on
behalf of. the Grantee and accepted or approved by SANDAG. All of Grantee's application
materials, not in conflict with this Agreement, are hereby incorporated into this Agreement
as though fully set forth herein.
B. Agreement. This Grant Agreement, together with all Attachments hereto, which are hereby
incorporated into this Agreement and contain additional terms and conditions that are
binding upon the parties.
C. Approval, Authorization, Concurrence, Waiver. A written statement (transmitted in
typewritten hard copy or electronically) of a SANDAG official authorized to permit the
Grantee to take or omit an action required by this Agreement, which action may not be taken
or omitted without such written permission. Except to the extent that SANDAG determines
otherwise in writing, such approval, authorization, concurrence, or waiver permitting the
performance or omission of a specific action does not constitute permission to perform or
omit other similar actions. An oral permission or interpretation has no legal force or effect.
(See also Notice to Proceed, below at paragraph H in this Section 1.)
D. Approved Project Budget. The most recent statement of the costs of the Project, the
maximum amount of assistance from SANDAG for which the Grantee is currently eligible, the
specific tasks (including specific contingencies) covered, and the estimated cost of each task,
that has been approved by SANDAG. The Approved Project Budget is attached hereto as a
section of Attachment A.
E. SGIP Funds and Funding. Funding from the TransNet Extension Ordinance for the Smart
Growth Incentive Program (SGIP).
F. Grantee. The local jurisdiction that is the recipient of SGIP Funding under this Agreement. If
the Grantee enters into agreements with other parties to assist with the implementation of
the Project, each participant in, member of, or party to that agreement is deemed a
"subgrantee" and for purposes of compliance with applicable requirements of the
Agreement for its Project will be treated as a Grantee.
G. Maximum Percentage of SANDAG Participation. Grantee submitted an application and
was evaluated based on its representation that it would provide matching funds for the
Project. Grantee agrees to provide 50%, or $2,000,000 of the Approved Project Budget as
matching funds from resources other than Smart Growth Incentive Program funds. Therefore,
the maximum percentage that SANDAG will pay Grantee for amounts invoiced under this
Agreement is 50%, or $2,000,000, whichever is the lesser of these two amounts.
H. Notice to Proceed. Means a written notice from SANDAG issued to the Grantee authorizing
the Grantee to proceed with all or a portion of the work described in the scope of work.
Grantee shall not proceed with the work and shall not be eligible to receive payment for
work performed prior to SANDAG's issuance of a Notice to Proceed.
2
I. Subgrantee. Any contractor or consultant, at any tier, paid directly or indirectly with funds
flowing from this Agreement for the Project.
J. Term. The Term of this Agreement begins on the date SANDAG issues the Notice to Proceed
and ends on the last date indicated in the Project Schedule, (Attachment A), unless amended
consistent with the terms of this Agreement and SANDAG Board Policy No. 035, as amended.
Section 2. Project Implementation
A. General. The Grantee agrees to carry out the Project as follows:
1. Project Description. Grantee agrees to perform the work as described in the Project
Description/Scope of Work attached as Attachment A.
2. Effective Date. The effective date of this Agreement or any amendment hereto is the
date on which this Agreement or an amendment is fully executed. The Grantee agrees
to undertake Project only after receiving a written Notice to Proceed from SANDAG.
3. Grantee's Capacity. The Grantee agrees to maintain or acquire sufficient legal,
financial, technical, and managerial capacity to: (a) plan, manage, and complete the
Project and provide for the use of any Project property; (b) carry out the safety and
security aspects of the Project, and (c) comply with the terms of the Agreement and all
applicable laws, regulations, and policies pertaining to the Project and the Grantee,
including but not limited to the Extension Ordinance.
4. Project Schedule. The Grantee agrees to complete the Project according to the Project
Schedule attached hereto as a section of Attachment A and in compliance with
SANDAG Board Policy No. 035: Competitive Grant Program Procedures, as amended,
attached hereto as Attachment B.
5. Project Implementation and Oversight. Grantee agrees to comply with the Project
Implementation and Oversight Requirements attached hereto as Attachment C and
SANDAG Board Policy No. 035 as amended. Additionally, if Grantee hires a consultant
to carry out professional services, funded under this Agreement, Grantee shall: prepare
an Independent Cost Estimate (ICE) prior to soliciting proposals; publicly advertise for
competing proposals for the work; use cost as an evaluation factor in selecting the
consultant; document a Record of Negotiation (RON) establishing that the amount paid
by Grantee for the consultant services is fair and reasonable; and pass through the
relevant obligations in this Agreement to the consultant. If Grantee hires a contractor
to carry out construction services funded under this Agreement, Grantee shall: prepare
an ICE, (e.g., a construction cost estimate), prior to soliciting bids; publicly advertise for
competing bids for the work; award the work to the lowest responsive and responsible
bidder; document a RON establishing that the amount paid by Grantee for the
construction services is fair and reasonable; and pass through the relevant obligations
in this Agreement to the contractor.
6. Changes to Project's Scope of Work. This Agreement was awarded to Grantee
based on the application submitted by Grantee, which contained representations by
3
Grantee regarding project parameters, project proximity to transit, and other criteria
relevant to evaluating and ranking the Project based on SANDAG SGIP scoring criteria.
Any substantive deviation from Grantee's representations in the Project Justification
provided with Grantee's application during project implementation may require
reevaluation or result in loss of funding. If Grantee knows or should know that
substantive changes in the Project Justification have occurred or will occur, Grantee will
immediately notify SANDAG in writing. SANDAG will then determine whether the
Project is still consistent with the overall objectives of the SGIP Program and that the
changes would not have negatively affected the Project ranking during the competitive
grant evaluation process. SANDAG reserves the right to have SGIP Funding withheld
from, or refunded to SANDAG from Grantee due to Grantee's failure to satisfactorily
complete the Project or due to substantive changes to the Project Justification. See
Section 9, paragraph F of this Agreement regarding amendments to the Scope of Work.
B. Application of Laws. Should a federal or state law pre-empt a local law, regulation, or the
TransNet Extension Ordinance, the Grantee must comply with the federal or state law and
implementing regulations. No provision of this Agreement requires the Grantee to observe or
enforce compliance with any provision, perform any other act, or do any other task in
contravention of federal, state, territorial, or local law, regulation, or ordinance. If
compliance with any provision of this Agreement violates or would require the Grantee to
violate any law, the Grantee agrees to notify SANDAG immediately in writing. Should this
occur, SANDAG and the Grantee agree that they will make appropriate arrangements to
proceed with or, if necessary, terminate the Project or portions thereof expeditiously.
C. Notice Regarding Prevailing Wages. SANDAG SGIP Grants are funded with TransNet
revenues consistent with the TransNet Extension Ordinance adopted by the voters in
November 2004 (SANDAG Ordinance 04-01). Although SANDAG Ordinance 04-01 does not
require payment of prevailing wages, a California appellate court case (Asuza Land Partners v.
Department of Industrial Relations 191 Cal. App. 4th 1 (2010)), may require that TransNet-
funded public works projects pay prevailing wages for workers. Grantee acknowledges that
SANDAG has strongly encouraged Grantee to seek legal counsel regarding whether the Asuza
case will subject the grant project to prevailing wage laws consistent with Labor Code Section
1720 et seq. This Grant Agreement requires Grantee's compliance with all federal, state, and
local laws and ordinances as applicable.
D. Significant Participation by a Subgrantee. Although the Grantee may delegate any or
almost all Project responsibilities to one or more subgrantees, the Grantee agrees that it,
rather than any subgrantee, is ultimately responsible for compliance with all applicable laws,
regulations, and this Agreement.
E. Grantee's Responsibility to Extend Agreement Requirements to Other Entities
1. Entities Affected. If an entity other than the Grantee is expected to fulfill any
responsibilities typically performed by the Grantee, the Grantee agrees to ensure that
the entity carries out the Grantee's responsibilities as set forth in this Agreement.
2. Documents Affected. The applicability provisions of laws, regulations, and policies
determine the extent to which those provisions affect an entity (such as a subgrantee)
4
participating in the Project through the Grantee. Thus, the Grantee agrees to use a
written document to ensure that each entity participating in the Project complies with
applicable laws, regulations, and policies.
3. Required Clauses. The Grantee agrees to use a written document (such as a
subagreement, lease, third -party contract or other) including all appropriate clauses
stating the entity's responsibilities under applicable laws, regulations, or policies.
4. Flowdown. The Grantee agrees to include in each document (subagreement, lease,
third -party contract, or other) any necessary provisions requiring the Project participant
(third -party contractor, subgrantee, or other) to impose applicable laws, Agreement
requirements and directives on its subgrantees, lessees, third -party contractors, and
other Project participants at the lowest tier necessary.
F. No SANDAG Obligations to Third -Parties. In connection with the Project, the Grantee
agrees that SANDAG shall not be subject to any obligations or liabilities to any subgrantee,
lessee, third -party contractor, or other person or entity that is not a party to the Agreement
for the Project. Notwithstanding that SANDAG may have concurred in or approved any
solicitation, subagreement, lease, or third -party contract at any tier, SANDAG has no
obligations or liabilities to any entity other than the Grantee, including any subgrantee,
lessee, or third -party contractor at any tier.
G. Changes in Project Performance. The Grantee agrees to notify SANDAG immediately, in
writing, of any change in local law, conditions (including its legal, financial, or technical
capacity), or any other event that may adversely affect the Grantee's ability to perform the
Project in accordance with the terms of the Agreement and as required by SANDAG Board
Policy No. 035: Competitive Grant Program Procedures. The Grantee also agrees to notify
SANDAG immediately, in writing, of any current or prospective major dispute, breach,
default, or litigation that may adversely affect SANDAG's interests in the Project; and agrees
to inform SANDAG, also in writing, before naming SANDAG as a party to litigation for any
reason, in any forum. At a minimum, the Grantee agrees to send each notice to SANDAG
required by this subsection to the SANDAG Office of General Counsel. Grantee further agrees
to comply with the procedures set forth in SANDAG Board Policy No. 035 attached hereto as
Attachment B if it anticipates a delay in performance.
H. Standard of Care. The Grantee expressly warrants that the work to be performed pursuant
to this Agreement shall be performed in accordance with the applicable standard of care.
Where approval by SANDAG, its Executive Director, or other representative of SANDAG is
indicated in the Scope of Work, it is understood to be conceptual approval only and does not
relieve the Grantee of responsibility for complying with all laws, codes, industry standards,
and liability for damages caused by negligent acts, errors, omissions, noncompliance with
industry standards, or the willful misconduct of the Grantee or its subgrantees.
Nondiscrimination. SANDAG implements its programs without regard to income level,
disability, race, color, and national origin in compliance with the Americans with Disabilities
Act and Title VI of the Civil Rights Act. Grantee shall prohibit discrimination on these grounds,
notify the public of their rights under these laws, and utilize a process for addressing
complaints of discrimination. Furthermore, Grantee shall make the procedures for filing a
5
complaint available to members of the public and will keep a log of all such complaints.
Grantee must notify SANDAG immediately if a complaint is lodged that relates to the Project
or program funded by this grant.
Section 3. Ethics
A. Grantee Code of Conduct/Standards of Conduct. The Grantee agrees to maintain a
written code of conduct or standards of conduct that shall govern the actions of its officers,
employees, council or board members, or agents engaged in the award or administration of
subagreements, leases, or third -party contracts supported with SGIP Funding. The Grantee
agrees that its code of conduct or standards of conduct shall specify that its officers,
employees, board members, or agents may neither solicit nor accept gratuities, favors, or
anything of monetary value from any present or potential subgrantee, lessee, or third -party
contractor at any tier or agent thereof. Such a conflict would arise when an employee,
officer, council or board member, or agent, including any member of his or her immediate
family, partner, or organization that employs, or intends to employ, any of the parties listed
herein has a financial interest in the entity selected for award. The Grantee may set
de minimis rules where the financial interest is not substantial, or the gift is an unsolicited
item of nominal intrinsic value. The Grantee agrees that its code of conduct or standards of
conduct shall also prohibit its officers, employees, board members, or agents from using their
respective positions in a manner that presents a real or apparent personal or organizational
conflict of interest or personal gain. As permitted by state or local law or regulations, the
Grantee agrees that its code of conduct or standards of conduct shall include penalties,
sanctions, or other disciplinary actions for violations by its officers, employees, board
members, or their agents, or its third -party contractors or subgrantees or their agents.
1. Personal Conflicts of Interest. The Grantee agrees that its code of conduct or
standards of conduct shall prohibit the Grantee's employees, officers, council or board
members, or agents from participating in the selection, award, or administration of any
third -party contract or subagreement supported by SGIP Funding if a real or apparent
conflict of interest would be involved. Such a conflict would arise when an employee,
officer, board member, or agent, including any member of his or her immediate family,
partner, or organization that employs, or intends to employ, any of the parties listed
herein has a financial interest in the firm selected for award.
2. Organizational Conflicts of Interest. The Grantee agrees that its code of conduct or
standards of conduct shall include procedures for identifying and preventing real and
apparent organizational conflicts of interest. An organizational conflict of interest
exists when the nature of the work to be performed under a proposed third -party
contract or subagreement may, without some restrictions on future activities, result in
an unfair competitive advantage to the third -party contractor or subgrantee or impair
its objectivity in performing the contract work.
B. SANDAG Code of Conduct. SANDAG has established policies concerning potential conflicts
of interest. These policies apply to Grantee. For all awards by SANDAG, any practices which
might result in unlawful activity are prohibited including, but not limited to, rebates,
kickbacks, or other unlawful considerations. SANDAG staff are specifically prohibited from
6
participating in the selection process when those staff have a dose personal relationship,
family relationship, or past (within the last 12 months), present, or potential business or
employment relationship with a person or business entity seeking a contract with SANDAG. It
is unlawful for any contract to be made by SANDAG if any individual board member or staff
has a prohibited financial interest in the contract. Staff are also prohibited from soliciting or
accepting gratuities from any organization seeking funding from SANDAG. SANDAG's
officers, employees, agents, and board members shall not solicit or accept gifts, gratuities,
favors, or anything of monetary value from consultants, potential consultants, or parties to
subagreements. By signing this Agreement, Grantee affirms that it has no knowledge of an
ethical violation by SANDAG staff or Grantee. If Grantee has any reason to believe a conflict
of interest exists with regard to the Agreement or the Project, it should notify the SANDAG
Office of General Counsel immediately.
C. Bonus or Commission. The Grantee affirms that it has not paid, and agrees not to pay, any
bonus or commission to obtain approval of its SGIP Funding application for the Project.
D. False or Fraudulent Statements or Claims. The Grantee acknowledges and agrees that by
executing the Agreement for the Project, the Grantee certifies or affirms the truthfulness and
accuracy of each statement it has made, it makes, or it may make in connection with the
Project, including, but not limited to, the Grantee's grant application, progress reports and
invoices.
Section 4. Approved Project Budget
Except to the extent that SANDAG determines otherwise in writing, the Grantee agrees as follows:
The Grantee and SANDAG have agreed to a Project budget that is designated the "Approved
Project Budget." The Grantee will incur obligations and make disbursements of Project funds only
as authorized by the Approved Project Budget. An amendment to the Approved Project Budget
requires the issuance of a formal amendment to the Agreement, except that re -allocation of funds
among budget items or fiscal years that does not increase the total amount of the SGIP Funding
awarded for the Project may be made by the SANDAG Project Manager consistent with applicable
laws, regulations, and policies. Prior written SANDAG Project Manager approval is required for
transfers of funds between Approved Project Budget line items.
Section 5. Payments
A. Funding Commitment. The Grantee agrees that SANDAG's maximum commitment for
Project Costs will not exceed the Maximum SANDAG Contribution of $2,000,000. Within 30
days of notification to the Grantee that specific amounts are owed to, or withheld by,
SANDAG, whether for excess payments of SGIP Funding, Grantee's failure to comply with the
Agreement, SANDAG Board Policy No. 035 (Attachment B) and any policy amendments
thereto, disallowed costs, or funds recovered from third -parties or elsewhere, the Grantee
agrees to remit the owed amounts to SANDAG, including applicable interest, penalties, and
administrative charges.
B. Payment by SANDAG. Grantee is required to submit invoices no more often and no less
frequently than quarterly. Invoices must be accompanied by a quarterly report (Attachment
7
D). SANDAG will make payments for eligible amounts to Grantee within 30 days following
receipt of Grantee's invoice(s) if Grantee has complied with the requirements of the
Agreement, including quarterly reporting requirements, has satisfied SANDAG that the SGIP
Funding requested is needed for Project purposes in that requisition period, and is making
adequate progress toward Project completion consistent with SANDAG Board Policy No. 035
and any policy amendments thereto. After the Grantee has demonstrated satisfactory
compliance with the preceding requirements, SANDAG will reimburse the Grantee's apparent
allowable costs incurred consistent with the Approved Project Budget for the Project.
SANDAG shall retain ten percent (10%) from the amounts invoiced until satisfactory
completion of work. SANDAG shall promptly pay retention amounts to Grantee following
Grantee's satisfactory completion of work, receipt of Grantee's final invoice, and all required
documentation.
C. Eligible Costs. The Grantee agrees that Project costs eligible for SGIP Funding must comply
with all the following requirements. Except to the extent that SANDAG determines otherwise,
in writing, to be eligible for reimbursement, Project costs, must be:
1. Consistent with the Project Scope of Work, the Approved Project Budget, and other
provisions of the Agreement,
2. Necessary in order to accomplish the Project,
3. Reasonable for the goods or services purchased,
4. Actual net costs to the Grantee (i.e., the price paid minus any refunds, rebates, or other
items of value received by the Grantee that have the effect of reducing the cost
actually incurred, excluding program income),
5. Incurred for work performed, only on a reimbursement, not advance basis, after both
the Effective Date of the Agreement and following Grantee's receipt of a Notice to
Proceed from SANDAG,
6. Satisfactorily documented with supporting documentation which is to be submitted
with each invoice,
7. Treated consistently in accordance with generally accepted accounting principles and
procedures for the Grantee and any third -party contractors and subgrantees, (see
Section 6 Accounting Records), and
8. Expended allowable direct and indirect costs. Indirect costs will be reimbursed only if
the Grantee has an approved indirect cost allocation plan and prior written approval
has been obtained by SANDAG. The Grantee shall annually submit to SANDAG, prior to
reimbursement of indirect costs, an approved indirect cost allocation plan in accordance
with Office of Management and Budget (OMB), Circular A-87 Cost Principles for State,
Local, And Indian Tribal Governments, which can be viewed at
http://www.whitehouse.gov/omb/circulars. Indirect Costs are only allowable with either:
(1) an approved indirect cost rate from a Federal Cognizant agency (or its designee) or
an independent certified accounting firm; or (2) the applicant's proposed method for
allocating indirect costs must be submitted in accordance with applicable OMB
8
guidelines and approved by SANDAG. If the Grantee does not have an acceptable
approved indirect cost allocation plan, then indirect costs are not eligible for
reimbursement.
9. Project generated revenue realized by the Grantee shall be utilized in support of the
Project. Project generated revenue and expenditures, if any, shall be reported at the
end of the Agreement period.
10. In the event the Grantee receives payment from SANDAG, for which reimbursement is
later deemed ineligible and disallowed by SANDAG, the Grantee shall promptly refund
the disallowed amount to SANDAG on request, or SANDAG may offset the amount
disallowed from any payment due to or to become due to the Grantee under this
Agreement.
D. TransNet Project Eligibility
TransNet SGIP Funds may be expended for capital projects such as pedestrian improvements,
bicycle and transit facilities, and other innovative smart growth supporting infrastructure, as
well as planning projects such as updates to land use plans to qualify for "potential" smart
growth opportunity area as "existing/planned," and other planning activities that facilitate
smart growth.
E. Excluded Costs
1. In determining the amount of SGIP Funding SANDAG will provide for the Project,
SANDAG will exclude:
a. Any Project cost incurred by the Grantee before either the date SANDAG issues a
Notice to Proceed to Grantee or the Effective Date of the Agreement or any
Amendment thereto;
b. Any cost that is not included in the latest Approved Project Budget;
c. Any cost for Project property or services received in connection with a
subagreement, lease, third -party contract, or other arrangement that is required
to be, but has not been, concurred in or approved in writing by SANDAG;
d. Any cost ineligible for SANDAG participation as provided by applicable laws,
regulations, or policies.
2. The Grantee understands and agrees that payment to the Grantee for any Project cost
does not constitute SANDAG's final decision about whether that cost is allowable and
eligible for payment under the Project and does not constitute a waiver of any
violation by the Grantee of the terms of the Agreement for the Project, and/or Board
Policy No. 035. The Grantee acknowledges that SANDAG will not make a final
determination about the allowability and eligibility of any cost until the final payment
has been made on the Project or the results of an audit of the Project requested by
SANDAG or its Independent Taxpayer Oversight Committee (ITOC) has been completed,
whichever occurs latest. If SANDAG determines that the Grantee is not entitled to
9
receive any portion of the SGIP Funding requested or paid, SANDAG will notify the
Grantee in writing, stating its reasons. The Grantee agrees that Project closeout will not
alter the Grantee's responsibility to return any funds due SANDAG as a result of later
refunds, corrections, performance deficiencies, or other similar actions; nor will Project
closeout alter SANDAG's right to disallow costs and recover funds provided for the
Project on the basis of a later audit or other review.
F. Maximum SANDAG Participation. Upon receipt of an invoice from Grantee documenting
Grantee's incurred and eligible expenses, SANDAG agrees to pay its Maximum
Percentage/Amount of SANDAG Participation based on the invoiced amount.
G. Matching Funds. Grantee has proposed matching funds for the project and therefore agrees
as follows:
1. Duty to Obtain Matching Funds, The Grantee agrees to provide sufficient funds or
approved in -kind resources, together with the TransNet Extension Ordinance assistance
awarded that will ensure payment of the actual cost of each Project activity covered by
the Agreement for the Project. The amount of matching funds and percentage(s) of
matching funds and/or in -kind contributions Grantee shall provide are set forth in the
Approved Project Budget. The Grantee agrees to complete all proceedings necessary to
provide its share of the Project costs at or before the time the matching funds are needed
for the Project. Each of Grantee's invoices must include its pro-rata matching fund
contribution as reflected in the Approved Project Budget, along with supporting,
descriptive and/or explanatory documentation for the matching funds provided.
2. Prompt Payment of Matching. The Grantee agrees to provide the minimum
proportionate amount of the matching funds upon submittal of reimbursement for each
invoice and cumulatively over the life of the project as it incurs Projects costs. If the
minimum match is not provided with each invoice submittal or cumulatively over the life
of the project, the identical amount to make up the difference may be withheld as
retention for each invoice until the minimum match cumulatively over the life of the
project is satisfactorily provided. The retention withholding would be released upon the
minimum match provided, in accordance with the invoice payment terms as stated in this
Agreement.
3. Reduction of Matching Funds. The Grantee agrees that no reduction of the amount of
matching funds may be made unless, at the same time, a reduction of the proportional
amount of TransNet Extension Ordinance assistance provided is made to SANDAG in order
to maintain Maximum Percentage(s) of SANDAG participants. No refunds of matching
funds will be made.
10
Section 6. Accounting Records
In compliance with applicable laws, regulations, and policies, the Grantee agrees as follows:
A. Project Accounts. The Grantee agrees to establish and maintain for the Project either a
separate set of accounts or separate accounts within the framework of an established
accounting system that can be identified with the Project. The Grantee also agrees to
maintain documentation of all checks, payrolls, invoices, contracts, vouchers, orders, or other
accounting documents related in whole or in part to the Project so that they may be clearly
identified, readily accessible, and available to SANDAG upon request and, to the extent
feasible, kept separate from documents not related to the Project.
B. Documentation of Project Costs and Program Income. Except to the extent that
SANDAG determines otherwise, in writing, the Grantee agrees to maintain all documentation
of costs charged to the Project, including any approved services or property contributed by
the Grantee or others, with properly executed payrolls, time records, invoices, contracts, or
vouchers describing in detail the nature and propriety of the charges, including adequate
records to support the costs the Grantee has incurred underlying any payment in which
SANDAG has agreed to participate.
Section 7. Reporting, Record Retention, and Access
A. Types of Reports. The Grantee agrees to submit to SANDAG all reports required by laws and
regulations, policies, the Agreement, and any other reports SANDAG may specify.
B. Report Formats. The Grantee agrees that all reports and other documents or information
intended for public availability developed in the course of the Project and required to be
submitted to SANDAG must be prepared and submitted in electronic and or typewritten hard
copy formats as SANDAG may specify. SANDAG reserves the right to specify that records be
submitted in particular formats.
C. Record Retention. During the course of the Project and for three years thereafter from the
date of transmission of the final expenditure report, the Grantee agrees to maintain, intact
and readily accessible, all data, documents, reports, records, contracts, and supporting
materials relating to the Project as SANDAG may require.
D. Access to Records of Grantees and Subgrantees. The Grantee agrees to permit, and
require its subgrantees to permit, SANDAG or its authorized representatives, upon request, to
inspect all Project work, materials, payrolls, and other data, and to audit the books, records,
and accounts of the Grantee and its subgrantees pertaining to the Project.
E. Project Closeout. The Grantee agrees that Project closeout does not alter the reporting and
record retention requirements of this Agreement.
F. Quarterly Reports. Grantee shall submit written quarterly reports to SANDAG detailing the
progress of its work, expenditures incurred, and information regarding whether the Project is
projected to be completed within the limits of the Approved Project Budget, Project
Schedule, and consistent with Board Policy No. 035 and any policy amendments thereto.
11
Grantee shall document the progress and results of work performed under this Agreement to
the satisfaction of SANDAG. This includes progress and final reports, plans, specifications,
estimates, and other evidence of attainment of the Agreement objectives, which are
requested by SANDAG or the ITOC. Grantee may be required to attend meetings of SANDAG
staff and committees, including ITOC, to report on its progress and respond to questions.
G. Data Collection and Communities Served Report. If requested, Grantee shall provide
SANDAG with data regarding how the Project's benefits and burdens were equitably
distributed among socioeconomic populations in the area affected by the Project, and
associated smart growth data.
Section 8. Project Completion, Audit, Settlement, and Closeout
A. Project Completion. Within ninety (90) calendar days following Project completion or
termination by SANDAG, the Grantee agrees to submit a final certification of Project expenses
and final reports, as applicable. All payments made to the Grantee shall be subject to review
for compliance by SANDAG with the requirements of this Agreement and shall be subject to
an audit upon completion of the Project.
B. Project Audit. The Grantee agrees to have performed financial and compliance audits
SANDAG may require consistent with the TransNet Extension Ordinance for TransNet funds.
This Project's MPO ID Number is located in both Recital H, above, and on Attachment A. The
Grantee agrees that Project closeout will not alter the Grantee's audit responsibilities.
C. Project Closeout. Project closeout occurs when SANDAG notifies the Grantee that SANDAG
has closed the Project, and, if applicable, either forwards the final SGIP Funding payment and
liquidates any remaining funds. The Grantee agrees that Project closeout by SANDAG does
not invalidate any continuing requirements imposed by the Agreement or any unmet
requirements set forth in a written notification from SANDAG.
D. Project Use. Grantee was awarded this Agreement based on representations in its grant
application regarding the Project's intended use. If the Project is a capital project, Grantee
hereby commits to continued use of the Project for the purposes stated in its application for a
period of at least five years after completion of construction. SANDAG may require Grantee
to refund SGIP funding provided for the Project in the event Grantee fails to utilize the
Project for its intended purposes as stated in the grant application or for any disallowed costs.
Section 9. Timely Progress and Right of SANDAG to Terminate
A. Grantee shall make diligent and timely progress toward completion of the Project within the
timelines set forth in the Project Schedule (Attachment A), and consistent with SANDAG
Board Policy No. 035 and any policy amendments thereto. If timely progress is not achieved,
SANDAG may, in its sole discretion, review the status of the Project to determine if the
remaining funding should be reallocated to another eligible project, as per SANDAG Board
Policy No. 035. Grantee understands and agrees that any failure to make reasonable progress
on the Project or violation of this Agreement and/or Board Policy No. 035, that endangers
12
substantial performance of the Project shall provide sufficient grounds for SANDAG, in its sole
discretion, to terminate this Agreement.
B. In the event Grantee encounters difficulty in meeting the Project Schedule or anticipates
difficulty in complying with the Project Schedule, the Grantee shall immediately notify the
SANDAG Project Manager in writing, and shall provide pertinent details, including the
reason(s) for the delay in performance and the date by which Grantee expects to complete
performance or delivery. This notification shall be informational in character only and receipt
of it shall not be construed as a waiver by SANDAG of a project delivery schedule or date, or
any rights or remedies provided by this Agreement, including SANDAG Board Policy No. 035
requirements.
C. Upon written notice, the Grantee agrees that SANDAG may suspend or terminate all or any
part of the SGIP Funding to be provided for the Project if the Grantee has violated the terms
of the Agreement, or SANDAG Board Policy No. 035, or if SANDAG determines that the
purposes of the laws or policies authorizing the Project would not be adequately served by
the continuation of SGIP Funding for the Project.
D. In general, termination of SGIP Funding for the Project will not invalidate obligations
properly incurred by the Grantee before the termination date to the extent those obligations
cannot be canceled. If, however, SANDAG determines that the Grantee has willfully misused
SGIP Funding by failing to make adequate progress, or failing to comply with the terms of the
Agreement, SANDAG reserves the right to require the Grantee to refund to SANDAG the
entire amount of SGIP Funding provided for the Project or any lesser amount as SANDAG may
determine.
E. Expiration of any Project time period established in the Project Schedule will not, by itself,
automatically constitute an expiration or termination of the Agreement for the Project,
however, Grantee must request and SANDAG must agree to amend the Agreement in writing
if the Project Schedule will not be met. An amendment to the Project Schedule may be made
at SANDAG`s discretion if Grantee's request is consistent with the provisions of SANDAG
Board Policy No. 035 and if Grantee provides documentation that the Project is delayed due
to factors external to the control of the Grantee.
F. Amendment of Scope. The grant was awarded based on the application submitted by
Grantee with the intention that the awarded funds would be used to implement the Project
as described in the Scope of Work (Included in Attachment A). Any substantive deviation from
the Scope of Work must be approved by SANDAG if SGIP Funds are to be used for such
changes. If Grantee believes substantive changes need to be made to the Project, Grantee will
immediately notify SANDAG in writing. SANDAG will then determine whether the Project is
still consistent with the overall objectives of the SGIP Program, SANDAG Board Policy 035 and
that the changes would not have negatively affected the Project ranking during the
competitive grant evaluation process. SANDAG reserves the right to have SGIP Funding
withheld or refunded due to substantive Project changes.
13
Section 10. Disputes and Venue
A. Choice of Law. This Agreement shall be interpreted in accordance with the laws of the State
of California.
B. Dispute Resolution Process. In the event Grantee has a dispute with SANDAG during the
performance of this Agreement, Grantee shall continue to perform unless SANDAG informs
Grantee in writing to cease performance. The dispute resolution process for disputes arising
under this Agreement shall be as follows:
Grantee shall submit a statement of the grounds for the dispute, including all pertinent dates,
names of persons involved, and supporting documentation, to the SANDAG Project Manager.
The Project Manager and other appropriate SANDAG staff will review the documentation in a
timely manner and reply to Grantee within 20 days. Upon receipt of an adverse decision by
SANDAG, Grantee may submit a request for reconsideration to the SANDAG Executive
Director. The request for reconsideration must be received within 10 days from the postmark
date of SANDAG's reply. The Executive Director will respond to the request for
reconsideration within 10 working days. The decision of the Executive Director will be in
writing.
C. Venue. If any action is brought to interpret or enforce any term of this Agreement, the
action shall be brought in a state or federal court situated in the County of San Diego, State
of California. In the event of any such litigation between the parties, the prevailing party
shall be entitled to recover all reasonable costs incurred, including reasonable attorney's fees,
litigation and collection expenses, witness fees, and court costs as determined by the court.
Section 11. Assignment
The Grantee agrees that Grantee shall not assign, sublet, or transfer (whether by assignment or
novation) this Agreement or any rights under or interest in this Agreement
Section 12. Project Manager
The Grantee has assigned Stephen Manganiello as the Project Manager for the Project. Project
Manager continuity and experience is deemed essential in Grantee's ability to carry out the Project
in accordance with the terms of this Agreement. Grantee shall not change the Project Manager
without notice to SANDAG.
Section 13. Insurance
Grantee shall procure and maintain during the period of performance of this Agreement, and for
12 months following completion, policies of insurance from insurance companies authorized to do
business in the State of California or the equivalent types and amounts of self-insurance, as follows:
A. General Liability. Combined single limit of $1,000,000 per occurrence and $2,000,000 general
aggregate for personal and bodily injury, including death, and broad form property damage.
14
The policy must include an acceptable "Waiver of Transfer Rights of Recovery Against Others
Endorsement." The policy must name SANDAG as an additional insured in the endorsement.
A deductible or retention may be utilized, subject to approval by SANDAG.
B. Automobile Liability. For personal and bodily injury, including death, and property damage in
an amount not less than $1,000,000.
C. Workers' Compensation and Employer's Liability. Policy must comply with the laws of the
State of California. The policy must include an acceptable "Waiver of Right to Recover From
Others Endorsement" naming SANDAG as an additional insured.
D. Other Requirements. Grantee shall furnish satisfactory proof by one or more certificates
(original copies) that it has the foregoing insurance. The insurance shall be provided by an
acceptable insurance provider, as determined by SANDAG, which satisfies the following
minimum requirements:
1. An insurance carrier qualified to do business in California and maintaining an agent for
service of process within the state. Such insurance carrier shall maintain a current A.M.
Best rating classification of "A-" or better, and a financial size of "$10 million to $24
million (Class V) or better," or
2. A Lloyds of London program provided by syndicates of Lloyds of London and other
London insurance carriers, providing all participants are qualified to do business in
California and the policy provides for an agent for service of process in California.
Certificates of insurance shall be filed with SANDAG. These policies shall be primary insurance as to
SANDAG so that any other coverage held by SANDAG shall not contribute to any loss under
Grantee's insurance. Each insurance policy shall contain a clause which provides that the policy may
not be canceled without first giving thirty (30) days advance written notice to SANDAG. For
purposes of this notice requirement, any material change in the policy prior to its expiration shall be
considered a cancellation.
Section 14. Indemnification and Duty to Defend
A. Generally. With regard to any claim, protest, or litigation arising from or related to the
Grantee's performance in connection with or incidental to the Project or this Agreement,
Grantee agrees to defend, indemnify, protect, and hold SANDAG and its agents, officers,
Board members, and employees harmless from and against any and all claims, including, but
not limited to prevailing wages claims against the Project, asserted or liability established
for damages or injuries to any person or property, including injury to the Grantee's or its
subgrantees' employees, agents, or officers, which arise from or are connected with or are
caused or claimed to be caused by the negligent, reckless, or willful acts or omissions of the
Grantee and its subgrantees and their agents, officers, or employees, in performing the
work or services herein, and all expenses of investigating and defending against same,
including attorney fees and costs; provided, however, that the Grantee's duty to indemnify
and hold harmless shall not include any claims or liability arising from the established sole
negligence or willful misconduct of SANDAG, its agents, officers, or employees.
15
B. Intellectual Property. Upon request by SANDAG, the Grantee agrees to indemnify, save,
and hold harmless SANDAG and its officers, agents, and employees acting within the scope
of their official duties against any liability, including costs and expenses, resulting from any
willful or intentional violation by the Grantee of proprietary rights, copyrights, or right of
privacy, arising out of the publication, translation, reproduction, delivery, use, or disposition
of any data furnished under the Project. The Grantee shall not be required to indemnify
SANDAG for any such liability caused solely by the wrongful acts of SANDAG employees or
agents.
Section 15. Relationship of Parties
For purposes of this Agreement, the relationship of the parties is that of independent entities and
not as agents of each other or as joint venturers or partners. The parties shall maintain sole and
exclusive control over their personnel, agents, consultants, and operations. Except as SANDAG may
specify in writing, Grantee shall have no authority, express or implied, to act on behalf of SANDAG
in any capacity whatsoever, as an agent or otherwise. Grantee shall have no authority, express or
implied, to bind SANDAG or its members, agents, or employees, to any obligation whatsoever,
unless expressly provided in this Agreement.
Section 16. Severability and Integration
If any provision of the Agreement is determined invalid, the remainder of that Agreement shall not
be affected if that remainder would continue to conform to the requirements of applicable laws or
regulations. This Agreement represents the entire understanding of SANDAG and Grantee as to
those matters contained in it. No prior oral or written understanding shall be of any force or effect
with respect to those matters covered hereunder. This Agreement may not be modified or altered
except in writing, signed by SANDAG and the Grantee.
Section 17. Notice
Any notice or instrument required to be given or delivered by this Agreement may be given or
delivered by depositing the same in any United States Post Office, registered or certified, postage
prepaid, addressed to:
San Diego Association of Governments
401 B Street, Suite 800
San Diego, CA 92101
Attn: Susan Baldwin
Grantee:
City of National City
1243 National City Boulevard
National City, CA 91950
Attn: Stephen Manganiello
and shall be effective upon receipt thereof.
16
Section 18. Signatures
The individuals executing this Agreement represent and warrant that they have the legal capacity
and authority to do so on behalf of their respective legal entities.
IN WITNESS WHEREOF, the parties have executed this Agreement as of the date written
above.
SAN DIEGO ASSOCIATION CITY OF NATIONAL CITY
OF GOVERNMENTS
GARY L. GALLEGOS
ecutive Director or designee
LESLIE DEESE
City Manager
APPROVED AS TO FORM: APPROVED AS TO FORM
CL G.
City Attorney
17
ATTACHMENT A
SCOPE OF WORK, SCHEDULE, AND APPROVED PROJECT BUDGET
TransNet SMART GROWTH INCENTIVE GRANT PROGRAM SCOPE OF WORK, BUDGET, & SCHEDULE (FY 2013 Cycle)
Project Title: Downtown Westside Community Connections Project
Project Type: Capital
Project location/Omits:
Downtown-Westside Community Connections highlights four streets: Coolidge Avenue between Plaza Boulevard and 14th Street; A Avenue between 8th Street and 14th Street; Plaza Boulevard
between Coolidge Avenue and A Avenue; 14th Street between Coolidge Avenue and A Avenue
Project Description:
The project enhances City right-of-way &encourages smart growth through the following improvements; improve existing bus stops with new benches, shelters, recycling receptacles, public art, and
electronic signs indicating the arrival time of the next bus; install bicycle racks, comer bulbouts, and accessible curb rarnps at intersections with enhanced crosswalks and pedestrian refuges; install
landscaping in center medians and where the curb is being extended; install street lighting with way finding signage, and increase the buffer between pedestrians and vehicles through diagonal on -
street parking on Coolidge Avenue, 14th Street, Plaza Boulevard & where the curb is being extended; install street lighting with wayfinding signage, and increase the buffer between pedestrians and
vehicles through diagonal on -street parking on Coolidge Avenue, 14th Street, and A Avenue. Establish Brick Row Plaza & potential downtown shuttle system.
Task No.
Task Description
Deliverables
Start Date'
Completion Date*
Duration
SANDAG Funds
Matching Funds
TOTAL
1
Baseline Data Collection
Data
NTP Date
12 Months
12 Months
$5,000
$0
$5 000
2
Engineering, Design, Construction Bidding &
Plans & Contract
Docs
2 Months
12 Months
10 Months
$195,000
$100,000
$295,000
3
Construction & Pro'eR Close-out
1
Notice of
Completion
14 Months
24 Months
10 Months
$1,800,000
$1,900,000
$3,700,000
Project Completion
NTP Date
24 Months
24 Months
-._ -.... _.
..
TOTALS
$2,00Q000
$2,000,000
54,000,000
`Start Date and Completion Date are both tracked from NTP Date.
PROJECT REVENUES
Source
FY 2014
FY 2015
FY 2016
TOTAL
SGIP/TransNet
$200,000
$1,800,000
$0
$2,000000
Local (Other)
$100,000
$1,900,000
$0
$2,000,000
TOTALS
$300,000
$3,700,000
So
54,000,000
TransNet MPO ID NO.V10
18
ATTACHMENT B
BOARD POLICY NO. 03 5
COMPETITIVE GRANT PROGRAM PROCEDURES
Applicability and Purpose of Policy
This Policy applies to the following grant programs administered through SANDAG, whether from
TransNet or another source: Smart Growth Incentive Program, Environmental Mitigation Program,
Bike and Pedestrian Program, Senior Mini Grant Program, Job Access Reverse Commute, New
Freedom, and Section 5310 Elderly & Persons with Disabilities Transportation Program.
Nothing in this Policy is intended to supersede federal or state grant rules, regulations, statutes, or
contract documents that conflict with the requirements in this Policy. There are never enough
government grant funds to pay for all of the projects worthy of funding in the San Diego region.
For this reason, SANDAG awards grant funds on a competitive basis that takes the grantees' ability
to perform their proposed project on a timely basis into account. SANDAG intends to hold grantees
accountable to the project schedules they have proposed in order to ensure fairness in the
competitive process and encourage grantees to get their projects implemented quickly so that the
public can benefit from the project deliverables as soon as possible.
Procedures
1. Project Milestone and Completion Deadlines
1.1. When signing a grant agreement for a competitive program funded and/or
administered by SANDAG, grant recipients must agree to the project delivery objectives and
schedules in the agreement. In addition, a grantee's proposal must contain a schedule that
falls within the following deadlines. Failure to meet the deadlines below may result in
revocation of all grant funds not already expended. The final invoice for capital, planning,
or operations grants must be submitted prior to the applicable deadline.
1.1.1. Funding for Capital Projects. If the grant will fund a capital project, the
project must be completed according to the schedule provided in the grant
agreement, but at the latest, any necessary construction contract must be awarded
within two years following execution of the grant agreement, and construction
must be completed within eighteen months following award of the construction
contract. Completion of construction for purposes of this policy shall be when the
prime construction contractor is relieved from its maintenance responsibilities. If no
construction contract award is necessary, the construction project must be complete
within eighteen months following execution of the grant agreement.
1.1.2. Funding for Planning Grants. If the grant will fund planning, the project
must be completed according to the schedule provided in the grant agreement, but
at the latest, any necessary consultant contract must be awarded within one year
19
following execution of the grant agreement, and the planning project must be
complete within two years following award of the consultant contract. Completion
of planning for purposes of this policy shall be when grantee approves the final
planning project deliverable. If no consultant contract award is necessary, the
planning project must be complete within two years of execution of the grant
agreement.
1.1.3 Funding for Operations Grants. If the grant will fund operations, the project
must be completed according to the schedule provided in the grant agreement, but
at the latest, any necessary services contract for operations must be awarded within
one year following execution of the grant agreement, and the operations must
commence within six months following award of the operations contract. If no
services contract for operations is necessary, the operations project must commence
within one year of execution of the grant agreement.
1.1.4 Funding for Equipment or Vehicles Grants. If the grant will fund equipment
or vehicles, the project must be completed according to the schedule provided in the
grant agreement, but at the latest, any necessary purchase contracts for equipment
or vehicles must be awarded within one year following execution of the grant
agreement, and use of the equipment or vehicles for the benefit of the public must
commence within six months following award of the purchase contract.
2. Project Milestone and Completion Deadline Extensions
2.1. Schedules within grant agreements may include project scopes and schedules that
will identify interim milestones in addition to those described in Section 1 of this Policy.
Grant recipients may receive extensions on their project schedules of up to six months for
good cause. Extensions of up to six months aggregate that would not cause the project to
miss a completion deadline in Section 1 may be approved by the SANDAG Executive
Director. Extensions beyond six months aggregate or that would cause the project to miss a
completion deadline in Section 1 must be approved by the Policy Advisory Committee that
has been delegated the necessary authority by the Board. For an extension to be granted
under this Section 2, the following conditions must be met:
2.1.1. For extension requests of up to six months, the grantee must request the
extension in writing to the SANDAG Program Manager at least two weeks prior to
the earliest project schedule milestone deadline for which an extension is being
requested. The Executive Director or designee will determine whether the extension
should be granted. The Executive Director's action will be reported out to the Board
in following month's report of delegated actions.
2.1.2. A grantee seeking an extension must document previous efforts undertaken
to maintain the project schedule, explain the reasons for the delay, explain why the
delay is unavoidable, and demonstrate an ability to succeed in the extended time
frame the grantee proposes.
2.1.3. If the Executive Director denies an extension request under this Section 2,
the grantee may appeal within ten business days of receiving the Executive
Director's response to the responsible Policy Advisory Committee by sending the
appeal to the SANDAG Program Manager.
20
2.1.4. Extension requests that are rejected by the Policy Advisory Committee will
result in termination of the grant agreement and obligation by the grantee to
return to SANDAG any unexpended funds within 30 days. Unexpended funds are
funds for project costs not incurred prior to rejection of the extension request by the
Policy Advisory Committee.
3. Project Delays and Extensions in Excess of Six Months
3.1. Requests for extensions in excess of six months, or that will cause a project to miss a
completion deadline in Section 1 (including those projects that were already granted
extensions by the Executive Director and are again falling behind schedule), will be
considered by the Policy Advisory Committee upon request to the SANDAG Program
Manager.
3.2 A grantee seeking an extension must document previous efforts undertaken to
maintain the project schedule, explain the reasons for the delay, explain why the delay is
unavoidable, and demonstrate an ability to succeed in the extended time frame the grantee
proposes. The grantee must provide the necessary information to SANDAG staff to place in
a report to the Policy Advisory Committee. If sufficient time is available, and the grant
utilized TransNet funds, the request will first be taken to the Independent Taxpayer
Advisory Committee (ITOC) for a recommendation. The grantee should make a
representative available at the meeting to present the information to, and/or answer
questions from, the ITOC and Policy Advisory Committee.
3.3 The Policy Advisory Committee will only grant an extension under this Section 3 for
extenuating circumstances that the grantee could not have reasonably foreseen.
4. Resolution and Execution of the Grant Agreement
4.1 Two weeks prior to the review by the Policy Advisory Committee of the proposed
grants, prospective grantees must submit a resolution from their authorized governing body
that includes the provisions in this Subsection 4.1. Failure to provide a resolution that meets
the requirements in this Subsection 4.1 will result in rejection of the application and the
application will be dropped from consideration with funding going to the next project as
scored by the evaluation committee. In order to assist grantees in meeting this resolution
deadline, when SANDAG issues the call for projects it will allow at least 90 days for grant
application submission.
4.1.1 Grantee governing body commits to providing the amount of matching
funds set forth in the grant application.
4.1.2 Grantee governing body authorizes staff to accept the grant funding and
execute a grant agreement if an award is made by SANDAG.
4.2 Grantee's authorized representative must execute the grant agreement within 45
days from the date SANDAG presents the grant agreement to the prospective grantee for
execution. Failure to meet the requirements in this Subsection 4.2 may result in revocation
of the grant award.
21
5. Increased Availability of Funding Under this Policy
5.1. Grant funds made available as a result of the procedures in this Policy may be
awarded to the next project on the recommended project priority list from the most recent
project selection process, or may be added to the funds available for the next project
funding cycle, at the responsible Policy Advisory Committee's discretion. Any project that
loses funding due to failure to meet the deadlines specified in this Policy may be
resubmitted to compete for funding in a future call for grant applications.
Adopted: January 2010
22
ATTACHMENT C
PROJECT IMPLEMENTATION AND OVERSIGHT REQUIREMENTS
Capital Grants
1. Contact Information: Grantee must provide SANDAG with contact information for the project
manager. Grantee must provide SANDAG with updated contact information in a timely manner if
there are any changes to staff assigned.
2. Design Development Meetings: Grantee must provide SANDAG with advance notice
(preferably within two weeks) and agendas of all design development meetings, and a meeting
summary following the meeting. SANDAG staff may attend any meetings as appropriate.
3. Plan Review: Grantee must submit project design drawings and cost estimates (if available) to
SANDAG for review and comment at 30 percent, 60 percent, 90 percent, and 100 percent. SANDAG
staff may meet with the grantee to comment on submitted plans and ensure substantial
conformance. SANDAG may comment on submitted plans regarding:
• whether they are consistent with the project proposed in the original grant application, and
• consistency with accepted pedestrian/bicycle facility standards.
4. Quarterly Reports: Grantee must submit quarterly reports to SANDAG, detailing
accomplishments in the quarter, anticipated progress next quarter, pending issues and actions
toward resolution, and status of budget and schedule.
5. Performance Monitoring: SANDAG staff may measure performance of the constructed capital
improvements against stated project objectives, and evaluate the overall SGIP. Grantee is expected
to meet with SANDAG staff to identify relevant performance measures and data sources, and
provide available data and feedback regarding the program as appropriate. Grantee will provide
SANDAG with a copy of its records showing its outreach efforts to the racial and economic
population groups in the Project area, including but not limited to disabled, low income and
minority groups, to establish input was sought and utilized from the populations expected to be
affected by the Project.
Planning Grants
1. Contact Information. Grantee must provide SANDAG with contact information for the project
manager. Grantee must provide SANDAG with updated contact information in a timely manner if
there are any changes to staff assigned.
2. Stakeholder and Community Meetings. Grantee must provide SANDAG with advance notice
(preferably within two weeks) and agendas of all stakeholder and community meetings, and a
meeting summary following the meeting. SANDAG staff may attend any meetings as appropriate.
3. Request for Proposals and Consultant Selection. Grantee must submit consultant draft
Request for Proposals to SANDAG staff for review and comment. Consultant proposals must also be
submitted to SANDAG for review and comment prior to consultant selection.
23
4. Quarterly Reports. Grantee must submit quarterly reports to SANDAG, detailing
accomplishments in the quarter, anticipated progress next quarter, pending issues and actions
toward resolution, and status of budget and schedule. The reports will include information
regarding Grantee's outreach efforts to the racial and economic population groups in the Project
area, including but not limited to disabled, low income and minority groups, to establish input was
sought and utilized from the populations expected to be affected by the Project.
24
ATTACHMENT D
QUARTERLY REPORT AND INVOICE FORMS
SMART GROWTH INCENTIVE GRANT PROGRAM
QUARTERLY PROGRESS REPORT
eportitg Perio
ue.Date�
Project Title:
Project Manager Name:
Agency:
Address:
Telephone:
Contract #:
Invoice Date:
Invoice #: Invoice Period: (from) (to)
Task 1 (Fill in each task from Scope of Work)
1. Work Accomplished this Invoice Period
Add description
2. Work Anticipated for Next Invoice Period
Add description
3. Challenges or Problems Experienced and Actions Toward Resolution
Add description
Task 2
1. Work Accomplished this Invoice Period
Add description
2. Work Anticipated for Next Invoice Period
Add description
3. Challenges or Problems Experienced and Actions Toward Resolution
Add description
4. Outreach Efforts
Add description
25
Summary of Progress
Task
Scheduled
Start Date
Scheduled
Completion
Date
Completed
This
Invoice
Period?
(mark x)
Start
Next
Invoice
Period?
(mark x)
Complete
Next
Invoice
Period?
(mark x)
Anticipated
Completion
Date (if not
as
scheduled)*
Task 1
Task 2
Task 3
Action/s requested of SANDAG (check appropriate box/es):
❑ No action requested
❑ Amendment to*:
❑ Scope of Work
Describe:
Justification:
❑ Project Budget
Describe:
Justification:
❑ Project Schedule
Describe:
Justification:
* For any amendment requested, please describe the amendment and provide justification for why
the amendment is needed.
For Project Schedule amendment requests, explain:
• previous efforts to maintain timely progress,
• reasons for the delays and why they were unavoidable, and
• demonstrate how the project will meet the proposed revised deadlines if the schedule
amendment is approved.
It is the Grantee's responsibility to ensure compliance with Board Policy No. 035 (Use it or Lose it)
milestones and grant agreement terms and conditions. Amendment requests are subject to
SANDAG approval
Note that any changes from scheduled start and completion dates are subject to approval by
SANDAG. Please refer to Board Policy No. 35 in your grant agreement regarding milestones that fall
behind schedule, and the actions required for schedule adjustments.
26
To:
From:
TRANSNET SMART GROWTH INCENTIVE PROGRAM INVOICE
SUCHI MUKHERJEE
SANDAG
401 B Street, Suite 800
San Diego, CA 92101-4231
Name
Address
Project Name:
Contract Number:
Grant Invoice Number:
Billing Period: FROM
Invoice Date: DATE
Grant Award: $0.00
Balance Remaining $0.00
TO
TASK
Previous Balance
Current MM/DD/YYYY to MM/DD/YYYY
Total Expenses SANDAG Total Match Spent
Balance
,
' Reimtiuiso
,Matt.
- v a
: 7ota1 ; .
".,Con
fa i osfss
o unamwnwr.
a�-. Cos ,� r:
L .31- x " .-
6 herC sts`
ram,
Th�s'lnvdice
x is -invoice
`This invoke
1, Remaining--
1
Prelim Engineering & Design
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
2
30% Review
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
3
60% Review
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
4
90% Review
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
5
100% Review
$0.00
$0.00
$0.00
6
Advertise for Construction
$0.00
$0.00
$0.00
7
Award Contract
$0.00
$0.00
$0.00
8
Begin construction
$0.00
$0.00
$0.00
9
Construction Task
$0.00
$0.00
$0.00
10
Construction Task
$0.00
$0.00
$0.00
11
Construction Task
$0.00
$0.00
$0.00
12
Construction Task
$0.00
$0.00
$0.00
13
Construction Task
$0.00
$0.00
$0.00
14
Construction Task
$0.00
$0.00
$0.00
15
Construction Task
$0.00
$0.00
$0.00
16
Construction Task
$0.00
$0.00
$0.00
17
Construction Task
$0.00
$0.00
$0.00
18
Construction Task
$0.00
$0.00
$0.00
19
Construction Task
$0.00
$0.00
$0.00
20
Construction Task
$0.00
$0.00
$0.00
21
Construction Task
$0.00
$0.00
$0.00
22
Construction Task
$0.00
$0.00
$0.00
23
Construction Task
$0.00
$0.00
$0.00
24
Construction Complete
$0.00
$0.00
$0.00
25
Project Completion/Closeout
$0.00
$0.00
$0.00
Total
$0.00
$0 00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
Total Current
Total Amount Due
Less 10%
Match
Expenditures:
this Invoice:
Retention:
% Met to Date:
$0.00
$0.00
$0.00
#DIV/01
27
Other Costs (Column G)
Describe Expenses:
Project Budget
,SANDAG'r#Match
"Grant `'�
, .:^-z
Tota -;,
=_
1
Task 1Task
Task 1
$0.00
$0.00
$0.00
Task 3
Task 2
$0.00
$0.00
$0.00
Task 4
Task 3
$0.00
$0.00
$0.00
Task 4
$0.00
$0.00
$0.00
Task 5
$0.00
Task 6
$0.00
Task 7
$0.00
Task 8
$0.00
Task 9
$0.00
Task 10
$0.00
Task 11
$0.00
Task 12
$0.00
Task 13
$0.00
Task 14
$0.00
Task 15
$0.00
Task 16
$0.00
Task 17
$0.00
Task 18
$0.00
Task 19
$0.00
Task 20
$0.00
Task 21
$0.00
Task 22
$0.00
Task 23
$0.00
Task 24
$0.00
I ask 25
$0.00
TOTAL
$0.00
$0.00
$0.00
Required Match % #DIV/01
CERTIFICATION OF GRANTEE
I hereby certify That the above costs were incurred in performance of the work required under the grant and are consistent with the a
supporting documents and expenditures.
Signature Printed Name and Title
28
RESOLUTION NO. 2013 — 09
RESOLUTION OF THE CITY COUNCIL OF THE CITY OF NATIONAL CITY
AUTHORIZING THE FILING OF AN APPLICATION FOR
SMART GROWTH INCENTIVE GRANT PROGRAM FUNDS
THROUGH THE SAN DIEGO ASSOCIATION OF GOVERNMENTS
FOR THE NATIONAL CITY DOWNTOWN-WESTSIDE COMMUNITY
CONNECTIONS PROJECT, ACCEPTING THE TERMS
OF THE GRANT AGREEMENT, AND AUTHORIZING
THE CITY MANAGER TO EXECUTE THE GRANT AGREEMENT
WHEREAS, $9.6 million of TransNet funding for capital and planning smart
growth incentive program projects is available to local jurisdictions and the County of San Diego
from Fiscal Year 2011-2012; and
WHEREAS, the City of National City desires to receive $2,000,000 in Smart
Growth Incentive Grant funds for the National City Downtown-Westside Community
Connections; and
WHEREAS, the City of National City understands that the Smart Growth
Incentive Grant Program funding is fixed at the programmed amount, and therefore project cost
increases that exceed the grant awarded will be the sole responsibility of the City; and
WHEREAS, the City of National City agrees to complete the proposed grant
project within a timely matter and in compliance with Board Policy No.035.
NOW, THEREFORE, BE IT RESOLVED that the City Council of the City of
National City hereby authorizes the submittal of an application to SANDAG Smart Growth
Incentive Grant Program for funding in the amount of $2,000,000 for the National City
Downtown-Westside Community Connections Project.
BE IT FURTHER RESOLVED that, if a grant award is made by SANDAG to fund
the National City Downtown-Westside Community Connections Project, the City Council
commits to providing $2,000,000 of matching funds and/or in -kind contributions.
BE IT FURTHER RESOLVED that the City Council hereby authorizes the City
Manager to accept the grant funds, execute the Grant Agreement with SANDAG with no
exceptions, and complete the National City Downtown-Westside Community Connections
Project.
PASSED and ADOPTED this 15th day of January, 13.
Morrison, Mayor
ATTEST:
Michael R. Dalla, CRty Clerk
PROVED AS TO FORM:
dia Gam- Silva
City Attor
Passed and adopted by the Council of the City of National City, California, on January
15, 2013 by the following vote, to -wit:
Ayes: Councilmembers Cano, Morrison, Natividad, Rios, Sotelo-Solis.
Nays: None.
Absent: None.
Abstain: None.
AUTHENTICATED BY:
RON MORRISON
Mayor of the City of National City, California
City Clerlf of the City of ational City, California
By:
Deputy
I HEREBY CERTIFY that the above and foregoing is a full, true and correct copy of
RESOLUTION NO. 2013-9 of the City of National City, California, passed and adopted
by the Council of said City on January 15, 2013.
City Clerk of the City of National City, California
By:
Deputy
CITY OF NATIONAL CITY, CALIFORNIA
COUNCIL AGENDA STATEMENT
MEETING DATE: January 15, 2013
AGENDA ITEM NO. [if
fEM TITLE:
Resolution of the City Council of the City of National City authorizing the filing of an application for Smart
Growth Incentive Grant Program Funds through the San Diego Association of Governments in the amount of
$2,000,000 for the National City Downtown-Westside Community Connections Project; and if awarded the
grant, committing to $2,200,000 in matching funds, authorizing the City Manager to accept the grant funds,
execute the attached grant agreement with SANDAG with no exceptions, and complete the project
PREPARED BY: Stephen Manganiello DEPARTMENT:
PHONE: 4382 APPROVED BY:
EXPLANATION:
See attached
Engineering
FINANCIAL STATEMENT: APPROVED: ",r/
ACCOUNT NO. APPROVED:
SGIP Grant (proposed) - $2,000,000; Prop 84 Grant (local match) - $2,000,000
SRTS Grant (local match) - $200,000
ENVIRONMENTAL REVIEW:
N/A
ORDINANCE: INTRODUCTION:
FINAL ADOPTION:
Finance
MIS
STAFF RECOMMENDATION:
Adopt Resolution
BOARD / COMMISSION RECOMMENDATION:
N/A
ATTACHMENTS:
1. Explanation
2. Resolution
e•.�scLv��cf;
Explanation
Staff is requesting authorization to file an application for Smart Growth Incentive
Grant Program Funds through the San Diego Association of Governments in the
amount of $2,000,000 for the National City Downtown-Westside Community
Connections Project. Matching funds in the amount of $2,200,000 are available
through a previous Proposition 84 Storm Water Grant for "A" Avenue and Safe
Routes to School Grant for Coolidge Avenue.
The Project includes improvements along the following corridors to provide key
pedestrian connections between Downtown National City and the Westside (Old
Town) Community:
• Coolidge Avenue between Plaza Boulevard and 14th Street
• "A" Avenue between Plaza Boulevard and 14th Street
• Plaza Boulevard between Coolidge Avenue and "A" Avenue
• 14th Street between Coolidge Avenue and "A" Avenue
The goal of the project is to stimulate Smart Growth redevelopment by creating a
contiguous complete street system that connects Downtown National City with
the Westside Community, consistent with the National City General Plan,
Westside Specific Area Plan and National City Bicycle Master Plan.
The project will provide the following enhancements: install corner bulbouts and
handicap accessible curb ramps at intersections; install enhanced crosswalks
and pedestrian refuges; install landscaping in center islands and in areas where
the curb is being extended; install ornamental street lighting, decorative benches
and bike racks along the corridor; provide a "gateway" at Division Street through
public art; enhance existing bus stops with new benches, shelters, trash/recycling
receptacles, and electronic signs indicating the arrival time of the next bus.
Council Resolution is required to file the grant application, and if awarded the
grant, committing to $2,200,000 in matching funds, authorizing the City Manager
to accept the grant funds, execute the attached grant agreement with SANDAG
with no exceptions, and complete the project.
RESOLUTION NO. 2013 —
RESOLUTION OF THE CITY COUNCIL OF THE CITY OF NATIONAL CITY
AUTHORIZING THE FILING OF AN APPLICATION FOR
SMART GROWTH INCENTIVE GRANT PROGRAM FUNDS
THROUGH THE SAN DIEGO ASSOCIATION OF GOVERNMENTS
FOR THE NATIONAL CITY DOWNTOWN-WESTSIDE COMMUNITY
CONNECTIONS PROJECT, ACCEPTING THE TERMS
OF THE GRANT AGREEMENT, AND AUTHORIZING
THE CITY MANAGER TO EXECUTE THE GRANT AGREEMENT
WHEREAS, $9.6 million of TransNet funding for capital and planning smart
growth incentive program projects is available to local jurisdictions and the County of San Diego
from Fiscal Year 2011-2012; and
WHEREAS, the City of National City desires to receive $2,000,000 in Smart
Growth Incentive Grant funds for the National City Downtown-Westside Community
Connections; and
WHEREAS, the City of National City understands that the Smart Growth
Incentive Grant Program funding is fixed at the programmed amount, and therefore project cost
increases that exceed the grant awarded will be the sole responsibility of the City; and
WHEREAS, the City of National City agrees to complete the proposed grant
project within a timely matter and in compliance with Board Policy No.035.
NOW, THEREFORE, BE IT RESOLVED that the City Council of the City of
National City hereby authorizes the submittal of an application to SANDAG Smart Growth
Incentive Grant Program for funding in the amount of $2,000,000 for the National City
Downtown-Westside Community Connections Project.
BE IT FURTHER RESOLVED that, if a grant award is made by SANDAG to fund
the National City Downtown-Westside Community Connections Project, the City Council
commits to providing $2,000,000 of matching funds and/or in -kind contributions.
BE IT FURTHER RESOLVED that the City Council hereby authorizes the City
Manager to accept the grant funds, execute the Grant Agreement with SANDAG with no
exceptions, and complete the National City Downtown-Westside Community Connections
Project.
PASSED and ADOPTED this 15th day of January, 2013.
Ron Morrison, Mayor
ATTEST: APPROVED AS TO FORM:
Michael R. Dalla, City Clerk Claudia Gacitua Silva
City Attorney
PROJECT SUMMARY/ DETAIL DESCRIPTION
Figure 1-1: Project Area
Plaza Boulevard Smart Growth Connector
AnglerlPartn9 * PnpoiMBky[k Rb[I(
O Lantsueingane
LaaRTRn
FYB HYing/bus St*,
Parallel hrhAej
1
FOR INFORMATION ONLY — DO NOT FILL OUT
TRANSNET SMART GROWTH INCENTIVE GRANT PROGRAM
FISCAL YEAR 2011 — 2012 - 2013
GRANT AGREEMENT [AGREEMENT NUMBER] BETWEEN
THE SAN DIEGO ASSOCIATION OF GOVERNMENTS
AND
[INSERT AGENCY/JURISDICTION NAME]
REGARDING [INSERT FULL PROJECT TITLE]
THIS GRANT AGREEMENT [AGREEMENT NUMBER] ("Agreement") is made this [Day] day of
[Month], 2012, by and between the San Diego Association of Governments (hereinafter referred to as
"SANDAG"), 401 B Street, Suite 800, San Diego, California, and the [Grant Recipient and Address]
(hereinafter referred to as "Grantee"). This agreement expires on [Month] [Day], [Year].
The following recitals are a substantive part of this Agreement:
A. In November 2004, the voters of San Diego County approved SANDAG Ordinance 04-01, which
extended the TransNet 'A cent sales and use tax through 2048 (Extension Ordinance).
B. The Extension Ordinance contains provisions to fund the Smart Growth Incentive Program (SGIP),
which funding began on April 1, 2008.
C. The SGIP is commonly referred to, herein, as the "Smart Growth Incentive" grant program (SGIP).
The SANDAG Board of Directors also approved programming of approximately $[insert new
updated amount for the call for project which generated THIS grant award/agreement] million in
TransNet funds [insert new future date when BOD approved action described in this recital] by
Resolution Number [insert Reso number].
D. On [insert updated future date], SANDAG issued a Call for Projects from local jurisdictions in San
Diego County wishing to apply for a portion of the SGIP Funding/ TransNet Funds for use on
capital improvement and planning projects meeting certain criteria.
Both SGIP Funding and TransNet funds were eligible funding sources for the SGIP.
Grantee successfully applied for SGIP Funding for the following project: [Insert Project
Name/Description] (hereinafter referred to as the "Project"). The scope of work, schedule, and
budget for the Project is attached as Attachment A.
G. The purpose of this Agreement is to establish the terms and conditions for SANDAG to provide
Grantee with funding to implement the Project.
-2-
Contracts Staff: Before finalizing this agreement for internal SharePoint routing please
obtain from SANDAG Finance and Planning staff the TransNet MPO ID required to
complete Recital H, below. Thank you.
H. Grantee's Project is funded with [insert dollar values for Extension Ordinance funding, e.g.
$268,000) in Extension Ordinance funds]. TransNet MPO ID
Although SANDAG will be providing financial assistance to Grantee to support the Project,
SANDAG will not be responsible for Project implementation or hold any substantial control of the
Project.
NOW, THEREFORE, it is agreed as follows:
Section 1. Definitions
A. Application. The signed and dated grant application, including any amendment thereto, with all
explanatory, supporting, and supplementary documents filed with SANDAG by or on behalf of the
Grantee and accepted or approved by SANDAG. All of Grantee's application materials, not in
conflict with this Agreement, are hereby incorporated into this Agreement as though fully set forth
herein.
B. Agreement. This Grant Agreement, together with all Attachments hereto, which are hereby
incorporated into this Agreement and contain additional terms and conditions that are binding upon
the parties.
C. Approval, Authorization, Concurrence, Waiver. A written statement (transmitted in typewritten
hard copy or electronically) of a SANDAG official authorized to permit the Grantee to take or omit
an action required by this Agreement, which action may not be taken or omitted without such
written permission. Except to the extent that SANDAG determines otherwise in writing, such
approval, authorization, concurrence, or waiver permitting the performance or omission of a
specific action does not constitute permission to perform or omit other similar actions. An oral
permission or interpretation has no legal force or effect. (See also Notice to Proceed, below at
paragraph I in this Section 1.)
D. Approved Project Budget. The most recent statement of the costs of the Project, the maximum
amount of assistance from SANDAG for which the Grantee is currently eligible, the specific tasks
(including specific contingencies) covered, and the estimated cost of each task, that has been
approved by SANDAG. The Approved Project Budget is attached hereto as a section of
Attachment A.
SGIP Funds and Funding. Funding from the TransNet Extension Ordinance for the Smart Growth
Incentive Program (SGIP).
F. Grantee. The local jurisdiction that is the recipient of SGIP Funding under this Agreement. If the
Grantee enters into agreements with other parties to assist with the implementation of the Project,
each participant in, member of, or party to that agreement is deemed a "subgrantee" and for
purposes of compliance with applicable requirements of the Agreement for its Project will be
treated as a Grantee.
2
-3-
Note to SANDAG Contracts Staff: Please complete Section G. "Maximum
Percentage of SANDAG Participation" only if grantee committed matching
funds in its grant application. If grantee did not commit matching funds in its
application, please delete Section G, and adjust the Section letters, below,
accordingly. If grantee did commit matching funds, please delete Paragraph G,
and complete Paragraph H, below. After selecting either Paragraph G or H,
below, please adjust the remaining Paragraph letters accordingly. Thank you.
Maximum Percentage of SANDAG Participation. Grantee submitted an application and was
evaluated based on its representation that it would provide matching funds for the Project. Grantee
agrees to provide _% of the Approved Project Budget as matching funds from resources other
than the TransNet funds. Therefore, the maximum percentage that SANDAG will pay Grantee for
amounts invoiced under this Agreement is _%, or $_, whichever is the lesser of these two
amounts.
H. Maximum SANDAG Contribution. Grantee submitted an application and was evaluated based on
its representation that it would abide by a budget for the Project, which has been finalized and
attached to this Agreement as the Approved Project Budget (included in Attachment A). Based on
the Approved Project Budget, the maximum amount of SGIP funding SANDAG will pay to Grantee
for amounts invoiced under this Agreement is $_ or _% of the Approved Project Budget,
whichever is the lesser of these two amounts.
Notice. to Proceed means a written notice from SANDAG issued to the Grantee authorizing the
Grantee to proceed with all or a portion of the work described in the scope of work. Grantee shall
not proceed with the work and shall not be eligible to receive payment for work performed prior to
SANDAG's issuance of a Notice to Proceed.
J. Subgrantee. Any contractor or consultant, at any tier, paid directly or indirectly with funds flowing
from this Agreement for the Project.
Term. The Term of this Agreement begins on the date SANDAG issues the Notice to Proceed and
ends on the last date indicated in the Project Schedule, (Attachment A), unless amended
consistent with the terms of this Agreement and SANDAG's Board Policy No. 035, as amended.
3
-4-
Section 2. Project Implementation
A. General. The Grantee agrees to carry out the Project as follows:
1. Project Description. Grantee agrees to perform the work as described in the Project
Description/Scope of Work attached as Attachment A.
Effective Date. The effective date of this Agreement or any amendment hereto is the date
on which this Agreement or an amendment is fully executed. The Grantee agrees to
undertake Project only after receiving a written Notice to Proceed from SANDAG.
3. Grantee's Capacity. The Grantee agrees to maintain or acquire sufficient legal, financial,
technical, and managerial capacity to: (a) plan, manage, and complete the Project and
provide for the use of any Project property; (b) carry out the safety and security aspects of
the Project, and (c) comply with the terms of the Agreement and all applicable laws,
regulations, and policies pertaining to the Project and the Grantee, including but not limited
to the Extension Ordinance.
4. Project Schedule. The Grantee agrees to complete the Project according to the Project
Schedule attached hereto as a section of Attachment A and in compliance with SANDAG
Board Policy No. 035 ("Competitive Grant Program Procedures")), as amended, attached
hereto as Attachment B.
5. Project Implementation and Oversight. Grantee agrees to comply with the Project
Implementation and Oversight Requirements attached hereto as Attachment C and
SANDAG Board Policy No. 035 as amended. Additionally, if Grantee hires a consultant to
carry out professional services, funded under this Agreement, Grantee shall: prepare an
Independent Cost Estimate (ICE) prior to soliciting proposals; publicly advertise for
competing proposals for the work; use cost as an evaluation factor in selecting the
consultant; document a Record of Negotiation (RON) establishing that the amount paid by
Grantee for the consultant services is fair and reasonable; and pass through the relevant
obligations in this Agreement to the consultant. if Grantee hires a contractor to carry out
construction services funded under this Agreement, Grantee shall: prepare an ICE, (e.g., a
construction cost estimate), prior to soliciting bids; publicly advertise for competing bids for
the work; award the work to the lowest responsive and responsible bidder; document a RON
establishing that the amount paid by Grantee for the construction services is fair and
reasonable; and pass through the relevant obligations in this Agreement to the contractor.
6. Changes to Project's Scope of Work. This Agreement was awarded to Grantee based on
the application submitted by Grantee, which contained representations by Grantee regarding
project parameters, project proximity to transit, and other criteria relevant to evaluating and
ranking the Project based on SANDAG SGIP scoring criteria. Any substantive deviation from
Grantee's representations in the Project Justification during project implementation may
require reevaluation or result in loss of funding. If Grantee knows or should know that
substantive changes in the Project Justification have occurred or will occur, Grantee will
immediately notify SANDAG in writing. SANDAG will then determine whether the Project is
4
-5-
still consistent with the overall objectives of the SGIP Program and that the changes would
not have negatively affected the Project ranking during the competitive grant evaluation
process. SANDAG reserves the right to have SGIP Funding withheld from, or refunded to
SANDAG from Grantee due to Grantee's failure to satisfactorily complete the Project or due
to substantive changes to the Project Justification. See Section 9, paragraph F of this
Agreement regarding amendments to the Scope of Work.
Application of Laws Should a federal or state law pre-empt a local law, regulation, or the
TransNet Ordinance, the Grantee must comply with the federal or state law and implementing
regulations. No provision of this Agreement requires the Grantee to observe or enforce compliance
with any provision, perform any other act, or do any other task in contravention of federal, state,
territorial, or local law, regulation, or ordinance. If compliance with any provision of this Agreement
violates or would require the Grantee to violate any law, the Grantee agrees to notify SANDAG
immediately in writing. Should this occur, SANDAG and the Grantee agree that they will make
appropriate arrangements to proceed with or, if necessary, terminate the Project or portions thereof
expeditiously.
C. Notice Regarding Prevailing Wages SANDAG's SGIP Grants are funded with TransNet
revenues consistent with the TransNet Extension Ordinance adopted by the voters in November
2004 (SANDAG Ordinance 04-01). Although SANDAG Ordinance 04-01 does not require payment
of prevailing wages, a recent appellate court case (Asuza Land Partners v. Department of Industrial
Relations 191 Cal. App. 4th 1 [2010]), may require that TransNet-funded public works projects pay
prevailing wages for workers. Before entering into a grant agreement with SANDAG, grantees are
strongly encouraged to seek legal counsel regarding whether the Asuza case will subject the grant
project to prevailing wage laws consistent with Labor Code Section 1720 et seq. This Grant
Agreement requires Grantee's compliance with all federal, state, and local laws and ordinances as
applicable.
Significant Participation by a Subgrantee. Although the Grantee may delegate any or almost all
Project responsibilities to one or more subgrantees, the Grantee agrees that it, rather than any
subgrantee, is ultimately responsible for compliance with all applicable laws, regulations, and this
Agreement.
E. Grantee's Responsibility to Extend Agreement Requirements to Other Entities
1. Entities Affected. If an entity other than the Grantee is expected to fulfill any responsibilities
typically performed by the Grantee, the Grantee agrees to assure that the entity carries out
the Grantee's responsibilities as set forth in this Agreement.
2. Documents Affected. The applicability provisions of laws, regulations, and policies
determine the extent to which those provisions affect an entity (such as a subgrantee)
participating in the Project through the Grantee. Thus, the Grantee agrees to use a written
document to ensure that each entity participating in the Project complies with applicable
laws, regulations, and policies.
3. Required Clauses. The Grantee agrees to use a written document (such as a
subagreement, lease, third -party contract or other) including all appropriate clauses stating
the entity's responsibilities under applicable laws, regulations, or policies.
5
-6-
4. Flowdown. The Grantee agrees to include in each document (subagreement, lease, third -
party contract, or other) any necessary provisions requiring the Project participant (third -
party contractor, subgrantee, or other) to impose applicable laws, Agreement requirements
and directives on its subgrantees, lessees, third -party contractors, and other Project
participants at the lowest tier necessary.
F. No SANDAG Obligations to Third -Parties. In connection with the Project, the Grantee agrees
that SANDAG shall not be subject to any obligations or liabilities to any subgrantee, lessee, third -
party contractor, or other person or entity that is not a party to the Agreement for the Project.
Notwithstanding that SANDAG may have concurred in or approved any solicitation, subagreement,
lease, or third -party contract at any tier, SANDAG has no obligations or liabilities to any entity other
than the Grantee, including any subgrantee, lessee, or third -party contractor at any tier.
G. Changes in Project Performance. The Grantee agrees to notify SANDAG immediately, in writing,
of any change in local law, conditions (including its legal, financial, or technical capacity), or any
other event that may adversely affect the Grantee's ability to perform the Project in accordance
with the terms of the Agreement and as required by SANDAG Board Policy No. 035 (Competitive
Grant Program Procedures). The Grantee also agrees to notify SANDAG immediately, in writing, of
any current or prospective major dispute, breach, default, or litigation that may adversely affect
SANDAG's interests in the Project; and agrees to inform SANDAG, also in writing, before naming
SANDAG as a party to litigation for any reason, in any forum. At a minimum, the Grantee agrees to
send each notice to SANDAG required by this subsection to SANDAG's Office of General Counsel.
Grantee further agrees to comply with the procedures set forth in SANDAG Board Policy No. 035
attached hereto as Attachment B if it anticipates a delay in performance.
H. Standard of Care. The Grantee expressly warrants that the work to be performed pursuant to this
Agreement shall be performed in accordance with the applicable standard of care. Where approval
by SANDAG, its Executive Director, or other representative of SANDAG is indicated in the Scope
of Work, it is understood to be conceptual approval only and does not relieve the Grantee of
responsibility for complying with all laws, codes, industry standards, and liability for damages
caused by negligent acts, errors, omissions, noncompliance with industry standards, or the willful
misconduct of the Grantee or its subgrantees.
Anti -Discrimination Laws. SANDAG implements its programs without regard to income level,
disability, race, color, and national origin in compliance with the Americans with Disabilities Act and
Title VI of the Civil Rights Act. Grantee shall prohibit discrimination on these grounds, and utilize a
process for addressing complaints of discrimination. Furthermore, Grantee shall make the
procedures for filing a complaint available to members of the public upon request and will notify
SANDAG immediately if a complaint is lodged that relates to the project or program funded by this
grant.
Section 3. Ethics
A. Grantee Code of Conduct/Standards of Conduct. The Grantee agrees to maintain a written
code of conduct or standards of conduct that shall govern the actions of its officers, employees,
council or board members, or agents engaged in the award or administration of subagreements,
leases, or third -party contracts supported with SGIP Funding. The Grantee agrees that its code of
6
-7-
conduct or standards of conduct shall specify that its officers, employees, board members, or
agents may neither solicit nor accept gratuities, favors, or anything of monetary value from any
present or potential subgrantee, lessee, or third -party contractor at any tier or agent thereof. Such a
conflict would arise when an employee, officer, council or board member, or agent, including any
member of his or her immediate family, partner, or organization that employs, or intends to employ,
any of the parties listed herein has a financial interest in the entity selected for award. The Grantee
may set de minimis rules where the financial interest is not substantial, or the gift is an unsolicited
item of nominal intrinsic value. The Grantee agrees that its code of conduct or standards of conduct
shall also prohibit its officers, employees, board members, or agents from using their respective
positions in a manner that presents a real or apparent personal or organizational conflict of interest
or personal gain. As permitted by state or local law or regulations, the Grantee agrees that its code
of conduct or standards of conduct shall include penalties, sanctions, or other disciplinary actions
for violations by its officers, employees, board members, or their agents, or its third -party
contractors or subgrantees or their agents.
1. Personal Conflicts of Interest. The Grantee agrees that its code of conduct or standards of
conduct shall prohibit the Grantee's employees, officers, council or board members, or
agents from participating in the selection, award, or administration of any third -party contract
or subagreement supported by SGIP Funding if a real or apparent conflict of interest would
be involved. Such a conflict would arise when an employee, officer, board member, or agent,
including any member of his or her immediate family, partner, or organization that employs,
or intends to employ, any of the parties listed herein has a financial interest in the firm
selected for award.
2. Organizational Conflicts of Interest. The Grantee agrees that its code of conduct or
standards of conduct shall include procedures for identifying and preventing real and
apparent organizational conflicts of interest. An organizational conflict of interest exists when
the nature of the work to be performed under a proposed third -party contract or
subagreement may, without some restrictions on future activities, result in an unfair
competitive advantage to the third -party contractor or subgrantee or impair its objectivity in
performing the contract work.
B. SANDAG Code of Conduct. SANDAG has established policies concerning potential conflicts of
interest. These policies apply to Grantee. For all awards by SANDAG, any practices which might
result in unlawful activity are prohibited including, but not limited to, rebates, kickbacks, or other
unlawful considerations. SANDAG staff are specifically prohibited from participating in the selection
process when those staff have a close personal relationship, family relationship, or past (within the
last 12 months), present, or potential business or employment relationship with a person or
business entity seeking a contract with SANDAG. It is unlawful for any contract to be made by
SANDAG if any individual board member or staff has a prohibited financial interest in the contract.
Staff are also prohibited from soliciting or accepting gratuities from any organization seeking
funding from SANDAG. SANDAG's officers, employees, agents, and board members shall not
solicit or accept gifts, gratuities, favors, or anything of monetary value from consultants, potential
consultants, or parties to subagreements. By signing this Agreement, Grantee affirms that it has no
knowledge of an ethical violation by SANDAG staff or Grantee. If Grantee has any reason to
believe a conflict of interest exists with regard to the Agreement or the Project, it should notify the
SANDAG Office of General Counsel immediately.
7
-8-
C. Bonus or Commission. The Grantee affirms that it has not paid, and agrees not to pay, any
bonus or commission to obtain approval of its SGIP Funding application for the Project.
False or Fraudulent Statements or Claims. The Grantee acknowledges and agrees that by executing
the Agreement for the Project, the Grantee certifies or affirms the truthfulness and accuracy of each
statement it has made, it makes, or it may make in connection with the Project, including, but not limited
to, the Grantee's grant application, progress reports and invoices.
Section 4. Approved Project Budget
Except to the extent that SANDAG determines otherwise in writing, the Grantee agrees as follows: The
Grantee and SANDAG have agreed to a Project budget that is designated the "Approved Project Budget."
The Grantee will incur obligations and make disbursements of Project funds only as authorized by the
Approved Project Budget. An amendment to the Approved Project Budget requires the issuance of a
formal amendment to the Agreement, except that re -allocation of funds among budget items or fiscal
years that does not increase the total amount of the SGIP Funding awarded for the Project may be made
by SANDAG's Project Manager consistent with applicable laws, regulations, and policies. Prior written
SANDAG Project Manager approval is required for transfers of funds between Approved Project Budget
line items.
Section 5. Payments
A. Funding Commitment. The Grantee agrees that SANDAG's maximum commitment for Project
Costs will not exceed the Maximum SANDAG Contribution of $_. SANDAG's responsibility to
the County of San Diego to make payments under this Agreement is limited to the amounts listed in
the Approved Project Budget for the Project. Within 30 days of notification to the Grantee that
specific amounts are owed to, or withheld by, SANDAG, whether for excess payments of SGIP
Funding, Grantee's failure to comply with the Agreement, SANDAG Board Policy No. 035
(Attachment B) and any policy amendments thereto, disallowed costs, or funds recovered from
third -parties or elsewhere, the Grantee agrees to remit the owed amounts to SANDAG, including
applicable interest, penalties, and administrative charges.
Payment by SANDAG. Grantee is required to submit invoices no more often and no less
frequently than quarterly. Invoices must be accompanied by a quarterly report (Attachment D).
SANDAG will make payments for eligible amounts to Grantee within 30 days following receipt of
Grantee's invoice(s) if Grantee has complied with the requirements of the Agreement, including
quarterly reporting requirements, has satisfied SANDAG that the SGIP Funding requested is
needed for Project purposes in that requisition period, and is making adequate progress toward
Project completion consistent with SANDAG Board Policy No. 035 and any policy amendments
thereto. After the Grantee has demonstrated satisfactory compliance with the preceding
requirements, SANDAG will reimburse the Grantee's apparent allowable costs incurred consistent
with the Approved Project Budget for the Project.
C. Eligible Costs. The Grantee agrees that Project costs eligible for SGIP Funding must comply with
all the following requirements. Except to the extent that SANDAG determines otherwise, in writing,
to be eligible for reimbursement, Project costs, must be:
8
-9-
1. Consistent with the Project Scope of Work, the Approved Project Budget, and other
provisions of the Agreement,
2. Necessary in order to accomplish the Project,
3. Reasonable for the goods or services purchased,
4. Actual net costs to the Grantee (i.e., the price paid minus any refunds, rebates, or other
items of value received by the Grantee that have the effect of reducing the cost actually
incurred, excluding program income),
5. Incurred for work performed, only on a reimbursement, not advance basis, after both the
Effective Date of the Agreement and following Grantee's receipt of a Notice to Proceed from
SANDAG,
6. Satisfactorily documented with supporting documentation which is to be submitted with each
invoice,
7. Treated consistently in accordance with generally accepted accounting principles and
procedures for the Grantee and any third -party contractors and subgrantees, (see Section 6
Accounting Records), and
8. Eligible for SGIP Funding as part of the SGIP Program Claim Eligible Costs.
9. Expended allowable direct and indirect costs. Indirect costs will be reimbursed only if the
Grantee has an approved indirect cost allocation plan and prior written approval has been
obtained by SANDAG. The Grantee shall annually submit to SANDAG, prior to
reimbursement of indirect costs, an approved indirect cost allocation plan in accordance with
Office of Management and Budget (OMB), Circular A-87 Cost Principles for State, Local,
And Indian Tribal Governments, which can be viewed at
http://www.whitehouse.gov/omb/circulars. Indirect Costs are only allowable with either: (1)
an approved indirect cost rate from a Federal Cognizant agency (or its designee) or an
independent certified accounting firm; or (2) the applicant's proposed method for allocating
indirect costs must be submitted in accordance with applicable OMB guidelines and
approved by SANDAG. If the Grantee does not have an acceptable approved indirect cost
allocation plan, then indirect costs are not eligible for reimbursement.
10. Project generated revenue realized by the Grantee shall be utilized in support of the Project.
Project generated revenue and expenditures, if any, shall be reported at the end of the
Agreement period.
11. In the event the Grantee receives payment from SANDAG, for which reimbursement is later
deemed ineligible and disallowed by SANDAG, the Grantee shall promptly refund the
disallowed amount to SANDAG on request, or SANDAG may offset the amount disallowed
from any payment due to or to become due to the Grantee under this Agreement.
TransNet Project Eligibility
9
-10-
TransNet SGIP Funds may be expended for capital projects such as pedestrian improvements,
bicycle and transit facilities, and other innovative smart growth supporting infrastructure, as well as
planning projects such as updates to land use plans to qualify for "potential" smart growth
opportunity area as "existing/planned," and other planning activities that facilitate smart growth.
Excluded Costs
In determining the amount of SGIP Funding SANDAG will provide for the Project, SANDAG
will exclude:
a. Any Project cost incurred by the Grantee before either the date SANDAG issues a
Notice to Proceed to Grantee or the Effective Date of the Agreement or any
Amendment thereto;
b. Any cost that is not included in the latest Approved Project Budget;
c. Any cost for Project property or services received in connection with a subagreement,
lease, third -party contract, or other arrangement that is required to be, but has not
been, concurred in or approved in writing by SANDAG;
d. Any cost ineligible for SANDAG participation as provided by applicable laws,
regulations, or policies.
2. The Grantee understands and agrees that payment to the Grantee for any Project cost does
not constitute SANDAG's final decision about whether that cost is allowable and eligible for
payment under the Project and does not constitute a waiver of any violation by the Grantee
of the terms of the Agreement for the Project, and/or Board Policy No. 035. The Grantee
acknowledges that SANDAG will not make a final determination about the allowability and
eligibility of any cost until the final payment has been made on the Project or the results of
an audit of the Project requested by SANDAG or its Independent Taxpayers' Oversight
Committee (ITOC) has been completed, whichever occurs latest. If SANDAG determines
that the Grantee is not entitled to receive any portion of the SGIP Funding requested or paid,
SANDAG will notify the Grantee in writing, stating its reasons. The Grantee agrees that
Project closeout will not alter the Grantee's responsibility to return any funds due SANDAG
as a result of later refunds, corrections, performance deficiencies, or other similar actions;
nor will Project closeout alter SANDAG's right to disallow costs and recover funds provided
for the Project on the basis of a later audit or other review.
F. Maximum SANDAG Participation. Upon receipt of an invoice from Grantee documenting
Grantee's incurred and eligible expenses, SANDAG agrees to pay its Maximum
Percentage/Amount of SANDAG Participation based on the invoiced amount.
Note to SANDAG Contracts Staff: If grantee did not commit matching funds In the
grant application, please delete Section H. "Matching Funds" from the agreement,
and re -letter following sections accordingly. Thank you.
G. Matching Funds Grantee has proposed matching funds for the project and therefore agrees as
follows:
10
-11-
1. Duty to Obtain Matching Funds The Grantee agrees to provide sufficient funds or approved
in -kind resources, together with the TransNet Ordinance Assistance awarded, that will assure
payment of the actual cost of each Project activity covered by the Agreement for the Project.
The amount of matching funds and percentage(s) of matching funds and/or in -kind
contributions Grantee shall provide are set forth in the Approved Project Budget. The Grantee
agrees to complete all proceedings necessary to provide its share of the Project costs at or
before the time the matching funds are needed for the Project. Each of Grantee's invoices
must include its pro-rata matching fund contribution as reflected in the Approved Project
Budget, along with supporting, descriptive and/or explanatory documentation for the matching
funds provided.
2. Prompt Payment of Matching The Grantee agrees to provide the minimum proportionate
amount of the matching funds upon submittal of reimbursement for each invoice and
cumulatively over the life of the project as it incurs Projects costs. If the minimum match is not
provided with each invoice submittal or cumulatively over the life of the project, the identical
amount to make up the difference may be withheld as retention for each invoice until the
minimum match cumulatively over the life of the project is satisfactorily provided. The retention
withholding would be released upon the minimum match provided, in accordance with the
invoice payment terms as stated in this Agreement.
3. Reduction of Matching Funds The Grantee agrees that no reduction of the amount of
matching funds may be made unless, at the same time, a reduction of the proportional amount
of TransNet Ordinance Assistance provided is made to SANDAG in order to maintain
Maximum Percentage(s) of SANDAG participants. No refunds of matching funds will be made.
Section 6. Accounting Records
In compliance with applicable laws, regulations, and policies, the Grantee agrees as follows:
A. Project Accounts. The Grantee agrees to establish and maintain for the Project either a separate
set of accounts or separate accounts within the framework of an established accounting system
that can be identified with the Project. The Grantee also agrees to maintain documentation of all
checks, payrolls, invoices, contracts, vouchers, orders, or other accounting documents related in
whole or in part to the Project so that they may be clearly identified, readily accessible, and
available to SANDAG upon request and, to the extent feasible, kept separate from documents not
related to the Project.
11
-12-
Documentation of Project Costs and Program Income. Except to the extent that SANDAG
determines otherwise, in writing, the Grantee agrees to maintain all documentation of costs
charged to the Project, including any approved services or property contributed by the Grantee or
others, with properly executed payrolls, time records, invoices, contracts, or vouchers describing in
detail the nature and propriety of the charges, including adequate records to support the costs the
Grantee has incurred underlying any payment in which SANDAG has agreed to participate.
Section 7. Reporting, Record Retention, and Access
A. Types of Reports. The Grantee agrees to submit to SANDAG all reports required by laws and
regulations, policies, the Agreement, and any other reports SANDAG may specify.
B. Report Formats. The Grantee agrees that all reports and other documents or information intended
for public availability developed in the course of the Project and required to be submitted to
SANDAG must be prepared and submitted in electronic and or typewritten hard copy formats as
SANDAG may specify. SANDAG reserves the right to specify that records be submitted in
particular formats.
C. Record Retention. During the course of the Project and for three years thereafter from the date of
transmission of the final expenditure report, the Grantee agrees to maintain, intact and readily
accessible, all data, documents, reports, records, contracts, and supporting materials relating to the
Project as SANDAG may require.
Access to Records of Grantees and Subgrantees. The Grantee agrees to permit, and require its
subgrantees to permit, SANDAG or its authorized representatives, upon request, to inspect all
Project work, materials, payrolls, and other data, and to audit the books, records, and accounts of
the Grantee and its subgrantees pertaining to the Project.
E. Project Closeout. The Grantee agrees that Project closeout does not alter the reporting and
record retention requirements of this Agreement.
Quarterly Reports. Grantee shall submit written quarterly reports to SANDAG detailing the
progress of its work, expenditures incurred, and information regarding whether the Project is
projected to be completed within the limits of the Approved Project Budget, Project Schedule, and
consistent with Board Policy No. 035 and any policy amendments thereto. Grantee shall document
the progress and results of work performed under this Agreement to the satisfaction of SANDAL.
This includes progress and final reports, plans, specifications, estimates, and other evidence of
attainment of the Agreement objectives, which are requested by SANDAG or the ITOC. Grantee
may be required to attend meetings of SANDAG staff and committees, including ITOC, to report on
its progress and respond to questions.
Data Collection and Communities Served Report. If requested, Grantee shall provide SANDAG
with data regarding how the Project's benefits and burdens were equitably distributed among socio
and economic populations in the area affected by the Project, and associated smart growth data.
12
-13-
Section 8. Project Completion, Audit, Settlement, and Closeout
A. Project Completion, Within ninety (90) calendar days following Project completion or termination
by SANDAG, the Grantee agrees to submit a final certification of Project expenses and final
reports, as applicable. All payments made to the Grantee shall be subject to review for compliance
by SANDAG with the requirements of this Agreement and shall be subject to an audit upon
completion of the Project.
B. Project Audit. The Grantee agrees to have performed financial and compliance audits SANDAG
may require consistent with the TransNet Extension Ordinance for TransNet funds. This Project's
MPO ID Number is located in both Recital H, above, and on Attachment A. The Grantee agrees
that Project closeout will not alter the Grantee's audit responsibilities.
Project Closeout. Project closeout occurs when SANDAG notifies the Grantee that SANDAG has
closed the Project, and, if applicable, either forwards the final SGIP Funding payment and
liquidates any remaining funds. The Grantee agrees that Project closeout by SANDAG does not
invalidate any continuing requirements imposed by the Agreement or any unmet requirements set
forth in a written notification from SANDAG.
D. Project Use. Grantee was awarded this Agreement based on representations in its grant
application regarding the Project's intended use. If the Project is a capital project, Grantee hereby
commits to continued use of the Project for the purposes stated in its application for a period of at
least five years after completion of construction. SANDAG may require Grantee to refund SGIP
funding provided for the Project in the event Grantee fails to utilize the Project for its intended
purposes as stated in the grant application or for any disallowed costs.
Section 9. Timely Progress and Right of SANDAG to Terminate
A. Grantee shall make diligent and timely progress toward completion of the Project within the
timelines set forth in the Project Schedule (Attachment A), and consistent with SANDAG Board
Policy No. 035 and any policy amendments thereto. If timely progress is not achieved, SANDAG
may, in its sole discretion, review the status of the Project to determine if the remaining funding
should be reallocated to another eligible project, as per SANDAG Board Policy No. 035. Grantee
understands and agrees that any failure to make reasonable progress on the Project or violation of
this Agreement and/or Board Policy NO. 035, that endangers substantial performance of the
Project shall provide sufficient grounds for SANDAG, in its sole discretion, to terminate this
Agreement.
B. In the event Grantee encounters difficulty in meeting the Project Schedule or anticipates difficulty in
complying with the Project Schedule, the Grantee shall immediately notify the SANDAG Project
Manager in writing, and shall provide pertinent details, including the reason(s) for the delay in
performance and the date by which Grantee expects to complete performance or delivery. This
notification shall be informational in character only and receipt of it shall not be construed as a
waiver by SANDAG of a project delivery schedule or date, or any rights or remedies provided by
this Agreement, including SANDAG Board Policy No. 035 requirements.
C. Upon written notice, the Grantee agrees that SANDAG may suspend or terminate all or any part of
the SGIP Funding to be provided for the Project if the Grantee has violated the terms of the
13
-14-
Agreement, or SANDAG Board Policy No. 035, or if SANDAG determines that the purposes of the
laws or policies authorizing the Project would not be adequately served by the continuation of SGIP
Funding for the Project.
D. In general, termination of SGIP Funding for the Project will not invalidate obligations properly
incurred by the Grantee before the termination date to the extent those obligations cannot be
canceled. If, however, SANDAG determines that the Grantee has willfully misused SGIP Funding
by failing to make adequate progress, or failing to comply with the terms of the Agreement,
SANDAG reserves the right to require the Grantee to refund to SANDAG the entire amount of
SGIP Funding provided for the Project or any lesser amount as SANDAG may determine.
E. Expiration of any Project time period established in the Project Schedule will not, by itself,
automatically constitute an expiration or termination of the Agreement for the Project, however,
Grantee must request and SANDAG must agree to amend the Agreement in writing if the Project
Schedule will not be met. An amendment to the Project Schedule may be made at SANDAG's
discretion if Grantee's request is consistent with the provisions of SANDAG Board Policy No. 035.
Amendment of Scope. The grant was awarded based on the application submitted by Grantee with
the intention that the awarded funds would be used to implement the Project as described in the
Scope of Work (Included in Attachment A). Any substantive deviation from the Scope of Work must
be approved by SANDAG if SGIP Funds are to be used for such changes. If Grantee believes
substantive changes need to be made to the Project, Grantee will immediately notify SANDAG in
writing. SANDAG will then determine whether the Project is still consistent with the overall
objectives of the SGIP Program, SANDAG Board Policy 035 and that the changes would not have
negatively affected the Project ranking during the competitive grant evaluation process. SANDAG
reserves the right to have SGIP Funding withheld or refunded due to substantive Project changes.
Section 10. Disputes and Venue
Choice of Law. This Agreement shall be interpreted in accordance with the laws of the State of
California.
Dispute Resolution Process. In the event Grantee has a dispute with SANDAG during the
performance of this Agreement, Grantee shall continue to perform unless SANDAG informs
Grantee in writing to cease performance. The dispute resolution process for disputes arising under
this Agreement shall be as follows:
1 Grantee shall submit a statement of the grounds for the dispute, including all pertinent
dates, names of persons involved, and supporting documentation, to SANDAG's Project
Manager. The Project Manager and other appropriate SANDAG staff will review the
documentation in a timely manner and reply to Grantee within 20 days. Upon receipt of an
adverse decision by SANDAG, Grantee may submit a request for reconsideration to
SANDAG's Executive Director. The request for reconsideration must be received within 10
days from the postmark date of SANDAG's reply. The Executive Director will respond to the
request for reconsideration within 10 working days. The decision of the Executive Director
will be in writing.
14
-15-
2 If Grantee is dissatisfied with the results following exhaustion of the above dispute
resolution procedures, Grantee shall make a written request to SANDAG for appeal to the
SANDAG Regional Planning Committee. SANDAG shall respond to a request for mediation
within thirty (30) calendar days. The decision of the Regional Planning Committee shall be
final.
C. Venue. If any action is brought to interpret or enforce any term of this Agreement, the action shall
be brought in a state or federal court situated in the County of San Diego, State of California. In the
event of any such litigation between the parties, the prevailing party shall be entitled to recover all
reasonable costs incurred, including reasonable attorney's fees, litigation and collection expenses,
witness fees, and court costs as determined by the court.
Section 11. Assignment
The Grantee agrees that Grantee shall not assign, sublet, or transfer (whether by assignment or novation)
this Agreement or any rights under or interest in this Agreement
Section 12. Project Manager
The Grantee has assigned [INSERT PROJECT MANAGER NAME] as the Project Manager for the
Project. Project Manager continuity and experience is deemed essential in Grantee's ability to carry out
the Project in accordance with the terms of this Agreement. Grantee shall not change the Project
Manager without notice to SANDAG.
Section 13. Insurance
Grantee shall procure and maintain during the period of performance of this Agreement, and for 12
months following completion, policies of insurance from insurance companies authorized to do business
in the State of California or the equivalent types and amounts of self-insurance, as follows:
A. General Liability. Combined single limit of $1,000,000 per occurrence and $2,000,000 general
aggregate for personal and bodily injury, including death, and broad form property damage. The
policy must include an acceptable 'Waiver of Transfer Rights of Recovery Against Others
Endorsement." The policy must name SANDAG as an additional insured in the endorsement. A
deductible or retention may be utilized, subject to approval by SANDAG.
Automobile Liability. For personal and bodily injury, including death, and property damage in an
amount not less than $1,000,000.
C. Workers' Compensation and Employer's Liability. Policy must comply with the laws of the State of
California. The policy must include an acceptable "Waiver of Right to Recover From Others
Endorsement" naming SANDAG as an additional insured.
D. Other Requirements. Grantee shall furnish satisfactory proof by one or more certificates (original
copies) that it has the foregoing insurance. The insurance shall be provided by an acceptable
15
-16-
insurance provider, as determined by SANDAG, which satisfies the following minimum
requirements:
1. An insurance carrier qualified to do business in California and maintaining an agent for
service of process within the state. Such insurance carrier shall maintain a current A.M. Best
rating classification of "A-" or better, and a financial size of "$10 million to $24 million (Class
V) or better," or
1. A Lloyds of London program provided by syndicates of Lloyds of London and other London
insurance carriers, providing all participants are qualified to do business in California and the
policy provides for an agent for service of process in California.
2. Certificates of insurance shall be filed with SANDAG. These policies shall be primary
insurance as to SANDAG so that any other coverage held by SANDAG shall not contribute
to any loss under Grantee's insurance. Each insurance policy shall contain a clause which
provides that the policy may not be canceled without first giving thirty (30) days advance
written notice to SANDAG. For purposes of this notice requirement, any material change in
the policy prior to its expiration shall be considered a cancellation.
Section 14. Indemnification and Duty to Defend
A. Generally. With regard to any claim, protest, or litigation arising from or related to the Grantee's
performance in connection with or incidental to the Project or this Agreement, Grantee agrees to
defend, indemnify, protect, and hold SANDAG and its agents, officers, Board members, and
employees harmless from and against any and all claims, including, but not limited to prevailing
wages claims against the Project, asserted or liability established for damages or injuries to any
person or property, including injury to the Grantee's or its subgrantees' employees, agents, or
officers, which arise from or are connected with or are caused or claimed to be caused by the
negligent, reckless, or willful acts or omissions of the Grantee and its subgrantees and their
agents, officers, or employees, in performing the work or services herein, and all expenses of
investigating and defending against same, including attorney fees and costs; provided, however,
that the Grantee's duty to indemnify and hold harmless shall not include any claims or liability
arising from the established sole negligence or willful misconduct of SANDAG, its agents, officers,
or employees.
B. Intellectual Property. Upon request by SANDAG, the Grantee agrees to indemnify, save, and
hold harmless SANDAG and its officers, agents, and employees acting within the scope of their
official duties against any liability, including costs and expenses, resulting from any willful or
intentional violation by the Grantee of proprietary rights, copyrights, or right of privacy, arising out
of the publication, translation, reproduction, delivery, use, or disposition of any data furnished
under the Project. The Grantee shall not be required to indemnify SANDAG for any such liability
caused solely by the wrongful acts of SANDAG employees or agents.
16
-17-
Section 15. Relationship of Parties
For purposes of this Agreement, the relationship of the parties is that of independent entities and not as
agents of each other or as joint venturers or partners. The parties shall maintain sole and exclusive
control over their personnel, agents, consultants, and operations. Except as SANDAG may specify in
writing, Grantee shall have no authority, express or implied, to act on behalf of SANDAG in any capacity
whatsoever, as an agent or otherwise. Grantee shall have no authority, express or implied, to bind
SANDAG or its members, agents, or employees, to any obligation whatsoever, unless expressly provided
in this Agreement.
Section 16. Severability and Integration
If any provision of the Agreement is determined invalid, the remainder of that Agreement shall not be
affected if that remainder would continue to conform to the requirements of applicable laws or regulations.
This Agreement represents the entire understanding of SANDAG and Grantee as to those matters
contained in it. No prior oral or written understanding shall be of any force or effect with respect to those
matters covered hereunder. This Agreement may not be modified or altered except in writing, signed by
SANDAG and the Grantee.
Section 17. Notice
Any notice or instrument required to be given or delivered by this Agreement may be given or delivered
by depositing the same in any United States Post Office, registered or certified, postage prepaid,
addressed to:
San Diego Association of Governments
401 B Street, Suite 800
San Diego, CA 92101
Attn: Heather Cooper
Grantee:
City of National City
1243 National City Boulevard
National City, CA 91950
Attn: Stephen Manganiello
and shall be effective upon receipt thereof.
Contracts Staff: After receiving this original agreement back from the Grantee and before
routing the original agreement for final SANDAG "wet" signatures, please confirm with SANDAG
Finance and Planning staff that the applicable RTIP has been approved. Thank you.
Section 18. Signatures
The individuals executing this Agreement represent and warrant that they have the legal capacity and
authority to do so on behalf of their respective legal entities.
17
-18-
IN WITNESS WHEREOF, the parties have executed this Agreement as of the date written above.
SAN DIEGO ASSOCIATION CITY OF NATIONAL CITY
OF GOVERNMENTS
GARY L. GALLEGOS
Executive Director
[Full Name]
[Title]
APPROVED AS TO FORM: APPROVED AS TO FORM
Associate General Counsel
[Full Name]
[Title]
18
-19-
ATTACHMENT A
SCOPE OF WORK, SCHEDULE, AND APPROVED PROJECT BUDGET
Project Location
(SPECIFIC PROJECT LOCATION INCLUDING JURISDICTION, COMMUNITY, NEIGHBORHOOD, CORRIDORS, AND INTERSECTIONS)
Project Description
[PROJECT TYPE (DESIGN AND/OR CONSTRUCTION, MASTER PLAN, ETC.), TYPES OF IMPROVEMENTS/RECOMMENDATIONS,
PROJECT GOALS]
(INSERT SCOPE, SCHEDULE AND APPROVED PROJECT BUDGET)
TransNet MPO ID NO.
19
ATTACHMENT B
BOARD POLICY NO. 035
COMPETITIVE GRANT PROGRAM PROCEDURES
Applicability and Purpose of Policy
This Policy applies to the following grant programs administered through SANDAG, whether from
TransNet or another source: Smart Growth Incentive Program, Environmental Mitigation Program, Bike
and Pedestrian Program, Senior Mini Grant Program, Job Access Reverse Commute, New Freedom, and
Section 5310 Elderly & Persons with Disabilities Transportation Program.
Nothing in this Policy is intended to supersede federal or state grant rules, regulations, statutes, or
contract documents that conflict with the requirements in this Policy. There are never enough government
grant funds to pay for all of the projects worthy of funding in the San Diego region. For this reason,
SANDAG awards grant funds on a competitive basis that takes the grantees' ability to perform their
proposed project on a timely basis into account. SANDAG intends to hold grantees accountable to the
project schedules they have proposed in order to ensure fairness in the competitive process and
encourage grantees to get their projects implemented quickly so that the public can benefit from the
project deliverables as soon as possible.
Procedures
1. Project Milestone and Completion Deadlines
1.1. When signing a grant agreement for a competitive program funded and/or administered
by SANDAG, grant recipients must agree to the project delivery objectives and schedules in the
agreement. In addition, a grantee's proposal must contain a schedule that falls within the
following deadlines. Failure to meet the deadlines below may result in revocation of all grant
funds not already expended. The final invoice for capital, planning, or operations grants must be
submitted prior to the applicable deadline.
1.1.1. Funding for Capital Projects. If the grant will fund a capital project, the project
must be completed according to the schedule provided in the grant agreement, but at the
latest, any necessary construction contract must be awarded within two years following
execution of the grant agreement, and construction must be completed within eighteen
months following award of the construction contract. Completion of construction for
purposes of this policy shall be when the prime construction contractor is relieved from its
maintenance responsibilities. If no construction contract award is necessary, the
construction project must be complete within eighteen months following execution of the
grant agreement.
1.1.2. Funding for Planning Grants. If the grant will fund planning, the project must be
completed according to the schedule provided in the grant agreement, but at the latest,
any necessary consultant contract must be awarded within one year following execution
20
-21-
of the grant agreement, and the planning project must be complete within two years
following award of the consultant contract. Completion of planning for purposes of this
policy shall be when grantee approves the final planning project deliverable. If no
consultant contract award is necessary, the planning project must be complete within two
years of execution of the grant agreement.
1.1.3 Funding for Operations Grants. If the grant will fund operations, the project must
be completed according to the schedule provided in the grant agreement, but at the
latest, any necessary services contract for operations must be awarded within one year
following execution of the grant agreement, and the operations must commence within
six months following award of the operations contract. If no services contract for
operations is necessary, the operations project must commence within one year of
execution of the grant agreement.
1.1.4 Funding for Equipment or Vehicles Grants. If the grant will fund equipment or
vehicles, the project must be completed according to the schedule provided in the grant
agreement, but at the latest, any necessary purchase contracts for equipment or vehicles
must be awarded within one year following execution of the grant agreement, and use of
the equipment or vehicles for the benefit of the public must commence within six months
following award of the purchase contract.
2. Project Milestone and Completion Deadline Extensions
2.1. Schedules within grant agreements may include project scopes and schedules that will
identify interim milestones in addition to those described in Section 1 of this Policy. Grant
recipients may receive extensions on their project schedules of up to six months for good cause.
Extensions of up to six months aggregate that would not cause the project to miss a completion
deadline in Section 1 may be approved by the SANDAG Executive Director. Extensions beyond
six months aggregate or that would cause the project to miss a completion deadline in Section 1
must be approved by the Policy Advisory Committee that has been delegated the necessary
authority by the Board. For an extension to be granted under this Section 2, the following
conditions must be met:
2.1.1. For extension requests of up to six months, the grantee must request the
extension in writing to the SANDAG Program Manager at least two weeks prior to the
earliest project schedule milestone deadline for which an extension is being requested.
The Executive Director or designee will determine whether the extension should be
granted. The Executive Director's action will be reported out to the Board in following
month's report of delegated actions.
2.1.2. A grantee seeking an extension must document previous efforts undertaken to
maintain the project schedule, explain the reasons for the delay, explain why the delay is
unavoidable, and demonstrate an ability to succeed in the extended time frame the
grantee proposes.
2.1.3. If the Executive Director denies an extension request under this Section 2, the
grantee may appeal within ten business days of receiving the Executive Director's
response to the responsible Policy Advisory Committee by sending the appeal to the
SANDAG Program Manager.
21
22-
2.1.4. Extension requests that are rejected by the Policy Advisory Committee will result
in termination of the grant agreement and obligation by the grantee to return to SANDAG
any unexpended funds within 30 days. Unexpended funds are funds for project costs not
incurred prior to rejection of the extension request by the Policy Advisory Committee.
3. Project Delays and Extensions in Excess of Six Months
3.1. Requests for extensions in excess of six months, or that will cause a project to miss a
completion deadline in Section 1 (including those projects that were already granted extensions
by the Executive Director and are again falling behind schedule), will be considered by the Policy
Advisory Committee upon request to the SANDAG Program Manager.
3.2 A grantee seeking an extension must document previous efforts undertaken to maintain
the project schedule, explain the reasons for the delay, explain why the delay is unavoidable, and
demonstrate an ability to succeed in the extended time frame the grantee proposes. The grantee
must provide the necessary information to SANDAG staff to place in a report to the Policy
Advisory Committee. If sufficient time is available, and the grant utilized TransNet funds, the
request will first be taken to the Independent Taxpayer Advisory Committee (ITOC) for a
recommendation. The grantee should make a representative available at the meeting to present
the information to, and/or answer questions from, the ITOC and Policy Advisory Committee.
3.3 The Policy Advisory Committee will only grant an extension under this Section 3 for
extenuating circumstances that the grantee could not have reasonably foreseen.
4. Resolution and Execution of the Grant Agreement
4.1 Two weeks prior to the review by the Policy Advisory Committee of the proposed grants,
prospective grantees must submit a resolution from their authorized governing body that includes
the provisions in this Subsection 4.1. Failure to provide a resolution that meets the requirements
in this Subsection 4.1 will result in rejection of the application and the application will be dropped
from consideration with funding going to the next project as scored by the evaluation committee.
In order to assist grantees in meeting this resolution deadline, when SANDAG issues the call for
projects it will allow at least 90 days for grant application submission.
4.1.1 Grantee governing body commits to providing the amount of matching funds set
forth in the grant application.
4.1.2 Grantee governing body authorizes staff to accept the grant funding and execute
a grant agreement if an award is made by SANDAG.
4.2 Grantee's authorized representative must execute the grant agreement within 45 days
from the date SANDAG presents the grant agreement to the prospective grantee for execution.
Failure to meet the requirements in this Subsection 4.2 may result in revocation of the grant
award.
5. Increased Availability of Funding Under this Policy
5.1. Grant funds made available as a result of the procedures in this Policy may be awarded
to the next project on the recommended project priority list from the most recent project selection
process, or may be added to the funds available for the next project funding cycle, at the
responsible Policy Advisory Committee's discretion. Any project that loses funding due to failure
22
-23-
to meet the deadlines specified in this Policy may be resubmitted to compete for funding in a
future call for grant applications.
Adopted: January 2010
23
-24-
ATTACHMENT C
PROJECT IMPLEMENTATION AND OVERSIGHT REQUIREMENTS
Capital Grants
1. Contact Information: Grantee must provide SANDAG with contact information for the project
manager. Grantee must provide SANDAG with updated contact information in a timely manner if there
are any changes to staff assigned.
2. Design Development Meetings: Grantee must provide SANDAG with advance notice (preferably
within two weeks) and agendas of all design development meetings, and a meeting summary following
the meeting. SANDAG staff may attend any meetings as appropriate.
3. Plan Review: Grantee must submit project design drawings and cost estimates (if available) to
SANDAG for review and comment at 30 percent, 60 percent, 90 percent, and 100 percent. SANDAG staff
may meet with the grantee to comment on submitted plans and assure substantial conformance.
SANDAG may comment on submitted plans regarding:
• whether they are consistent with the project proposed in the original grant application, and
• consistency with accepted pedestrian/bicycle facility standards.
4. Quarterly Reports: Grantee must submit quarterly reports to SANDAG, detailing accomplishments in
the quarter, anticipated progress next quarter, pending issues and actions toward resolution, and status
of budget and schedule.
5. Performance Monitoring: SANDAG staff may measure performance of the constructed capital
improvements against stated project objectives, and evaluate the overall SGIP. Grantee is expected to
meet with SANDAG staff to identify relevant performance measures and data sources, and provide
available data and feedback regarding the program as appropriate.
Planning Grants
1. Contact Information. Grantee must provide SANDAG with contact information for the project
manager. Grantee must provide SANDAG with updated contact information in a timely manner if there
are any changes to staff assigned.
2. Stakeholder and Community Meetings. Grantee must provide SANDAG with advance notice
(preferably within two weeks) and agendas of all stakeholder and community meetings, and a meeting
summary following the meeting. SANDAG staff may attend any meetings as appropriate.
3. Request for Proposals and Consultant Selection. Grantee must submit consultant draft Request for
Proposals to SANDAG staff for review and comment. Consultant proposals must also be submitted to
SANDAG for review and comment prior to consultant selection.
4. Quarterly Reports. Grantee must submit quarterly reports to SANDAG, detailing accomplishments in
the quarter, anticipated progress next quarter, pending issues and actions toward resolution, and status
of budget and schedule.
24
-25-
ATTACHMENT D
QUARTERLY REPORT AND INVOICE FORMS
SMART GROWTH INCENTIVE GRANT PROGRAM
QUARTERLY PROGRESS REPORT
Reporting Period
Due Date
Project Title:
Project Manager Name:
Agency:
Address:
Telephone:
Contract #:
Invoice Date:
Invoice #: Invoice Period: (from) (to)
Task 1 (Fill in each task from Scope of Work)
1. Work Accomplished this Invoice Period
Add description
2. Work Anticipated for Next Invoice Period
Add description
3. Challenges or Problems Experienced and Actions Toward Resolution
Add description
Task 2
1. Work Accomplished this Invoice Period
Add description
2. Work Anticipated for Next Invoice Period
Add description
3. Challenges or Problems Experienced and Actions Toward Resolution
Add description
25
-26-
Summary of Progress
Task
Scheduled
Start Date
Scheduled
Completion
Date
Completed
This Invoice
Period?
(mark x)
Start Next
Invoice
Period?
(mark x)
Complete
Next
Invoice
Period?
(mark x)
Anticipated
Completion
Date (if not
as
scheduled)
Task 1
Task 2
Task 3
Action/s requested of SANDAG (check appropriate box/es):
❑ No action requested
❑ Amendment to*:
❑ Scope of Work
Describe:
Justification:
❑ Project Budget
Describe:
Justification:
❑ Project Schedule
Describe:
Justification:
* For any amendment requested, please describe the amendment and provide justification for why the
amendment is needed.
For Project Schedule amendment requests, explain:
• previous efforts to maintain timely progress,
• reasons for the delays and why they were unavoidable, and
• demonstrate how the project will meet the proposed revised deadlines if the schedule
amendment is approved.
It is the Grantee's responsibility to ensure compliance with Board Policy No. 035 (Use it or Lose it)
milestones and grant agreement terms and conditions. Amendment requests are subject to SANDAG
approval
Note that any changes from scheduled start and completion dates are subject to approval by SANDAG.
Please refer to Board Policy No. 35 in your grant agreement regarding milestones that fall behind
schedule, and the actions required for schedule adjustments.
26
-27-
Invoice Part 1 of 2
To:
From:
Heather Cooper
SANDAG
401 8 Street. Suite 800
San Diego, CA 92101.4231
Name
Smart Growth Incentive Program Invoice Templet(
Project Name:
Contract Numher:
Grant Invoice Number:
Billing Period' FROM
Invoice Date: DATE
Grant Award:
Balance Remaining $0.00
TO
TASK
Previous Balance
Current MMIDDIYYYY to MMIDD%YYY
Twat Expenses SANDAG Total Match Spent
Balance
r'4
-Reinbureed`._"'
,e
2'n-
._
_ 5tatt�osb ';:
COrlsuftantt or
=z
'Other C0
*.`
Thia Invoice
=
,.
Thie Ervolce-
� ...,.�
- Tixa M3oict_
i
tiematirirlq,
IBcm7(adT-.z.-
CosY3'=r �
1
Insert Task 1 Description
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
2
$0.00
$0.00
8000
$0.00
80- 00
$0.00
$0.00
$0.00
3
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
4
$0.OD
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
5
$0.00
$0.00
$0.00
6
$0.00
$0.00
$0.00
7
$0.00
$0.00
$0.00
8
$0.00
$0.00
$0.00
9
$0.00
$0.00
$0.00
10
$0.00
$0.00
$0.00
11
$0.00
$0.00
$0.00
12
$0.00
$0.00
$0.00
13
$0.00
$0.00
$0.00
14
$0.00
$0.00
$0.00
15
$0.00
$0.00
$0.00
16
$0.00
$D.00
$0.00
17
$0.00
$0.00
$0.00
18
$0.00
$D.00
$0.00
19
$0.00
$0.00
$0.00
20
$0.00
$0.00
$0.00
21
$0.00
30.00
$0.00
22
$0.00
$0.00
$0.00
23
$0.00
$0.00
$0.00
24
$0.00
$000
$0.00
25
$0.00
$0.00
$0.00
Total
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
Total Current Expenditures: $0.00
Total Amount Due this Invoice $0.00
Less 10% Retention: $0.00
Match % Met to Date: 0%
Invoice Part 1 of 2
Other Costs jColumn G)
Describe Expenses:
Project Budget
SANDAL ''''
fiat ."
Match -
Tdtah
Task 1
Task 2
Task 1
$0.00
$0.00
$0.00
Task 3
Task 2
$0.00
$0.00
$0.00
Task 4
Task 3
$0.00
$0.00
$0.00
Task 4
$0.00
$0.00
$0.00
Task 5
$0.00
$0.00
$0.00
Task 6
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
80.00
$0.00
$0.00
$0.00
$0. 00
$0.00
$0.00
$0.00
$0.00
80.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
Sono
$o.00
$o.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0. 00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0. D0
$0.00
$0.00
$0.00
$0.00
TOTAL
$0.00
$0 00
$0.00
Required Match % 0.00%
CERTIFICATION OF GRANTEE
I hereby certify that the above costs are eligible costs incurred in performance of the work required under the grant and are consistent with the amounts evidenced by the attached supporting
documentation and expenditures.
Signature
Printed Name and Title
Date
SANDAG
401 8 Street, Suite 800
San Diego, CA 92101- 4231
(679) 699-1900
Fax (679) 699-1905
www.sandag.org
MEMBER AGENCIES
Cities of
Carlsbad
Chula Vista
Coronado
Del Mar
El Cajon
Encinitas
Escondido
imperial Beach
La Mesa
Lemon Grove
National City
Oceanside
Poway
San Diego
San Marcos
Santee
Solana Beach
Vista
and
County of San Diego
ADVISORY MEMBERS
Imperial County
California Department
of Transportation
Metropolitan
Transit System
North County
Transit District
United States
Department of Defense
San Diego
Unified Port District
San Diego County
Water Authority
Southern California
Tribal Chairmen's Association
Mexico
August 26, 2013
Stephen Manganiello
City Engineer
City of National City
1243 National City Boulevard
National City, CA 91950
Dear Mr. Manganiello:
RECEIVED
ENGINEERING DEPT.
ZD13 AUG 28 A 11: 5u
File Number 5004283
SUBJECT: Notice to Proceed for Smart Growth Incentive Program (SGIP)
Grant Agreement No. 5004283 for Downtown — Westside
Community Connections Project
This letter will serve as your Notice to Proceed, effective August 26, 2013, for
the subject grant agreement. A copy of the fully -executed, original signature
grant agreement is included for your records.
Please note that these funds have not yet been programmed into SANDAG's
Regional Transportation Improvement Program (RTIP) and are thus contingent
upon approval by the SANDAG Board of Directors of the RTIP amendment,
expected for some time in early September. SANDAG will not be able to pay
any invoices relating to this grant agreement prior to the RTIP amendment
being processed.
Ms. Susan Baldwin of this office has been assigned the management
responsibility for the SGIP grant program. All questions and administrative
matters should be directed to Ms. Baldwin at the above address, by email at
Susan.Baldwin@sandag.org, or at (619) 699-1943.
We look forward to working with you in the development of this project.
Sincerely,
(S
JENNY R. RUSSO
Contracts and Procurement Analyst
J R/