Loading...
HomeMy WebLinkAbout2017 CON Countywide Mechanical Systems - Pump Motor Replacement Station 34AGREEMENT BY AND BETWEEN THE CITY OF NATIONAL CITY AND COUNTYWIDE MECHANICAL SYSTEMS, INC. THIS AGREEMENT is entered into on this 27th day of March, 2017, by and between the CITY OF NATIONAL CITY, a municipal corporation (the "CITY"), and COUNTYWIDE MECHANICAL SYSTEMS, INC., a California corporation (the "CONTRACTOR"). RECITALS WHEREAS, the CITY maintains certain electic pumps at Fire Station 34 (located at 343 East 16th Street, National City, California) which pump water into fire hoses ("Pumps") that the CITY Fire Department uses for training purposes. WHEREAS, the existing Pumps can no longer be used for training purposes because of overexposure to water and flooding in the Pumps' underground storage area. WHEREAS, the CITY desires to employ the CONTRACTOR to replace the Pumps and make certain other improvments to the underground storage area described in Exhibit "A". WHEREAS, the CITY has determined that the CONTRACTOR specializes in the installation, service, and ongoing maintenance of commercial HVACR, plumbing, electrical controls, and solar equipment, and is qualified by experience and ability to perform the services desired by the CITY, and the CONTRACTOR is willing to perform such services. NOW, THEREFORE, THE PARTIES HERETO DO MUTUALLY AGREE AS FOLLOWS: 1. ENGAGEMENT OF CONTRACTOR. The CITY agrees to engage the CONTRACTOR to supply all parts and labor to replace the Pumps and make certain other improvments to the underground storage area, described in Exhibit "A", and the CONTRACTOR agrees to perform the services set forth here in accordance with all terms and conditions contained herein. The CONTRACTOR represents that all services shall be performed directly by the CONTRACTOR or under direct supervision of the CONTRACTOR. 2. EFFECTIVE DATE AND LENGTH OF AGREEMENT. This Agreement will become effective on March 27, 2017. The duration of this Agreement is for the period of March 27, 2017 through June 30, 2017. Completion dates or time durations for specific portions of the project are set forth in Exhibit "A". 3. SCOPE OF SERVICES. The CONTRACTOR will replace the Pumps and make certain other improvments to the underground storage area and perform those commercial pump installation and plumbing services, all as set forth in the attached Exhibit "A". The CONTRACTOR shall be responsible for all research and reviews related to the work and shall not rely on personnel of the CITY for such services, except as authorized in advance by the CITY. The CITY may unilaterally, or upon request from the CONTRACTOR, from time to time reduce or increase the Scope of Services to be performed by the CONTRACTOR under this Agreement. Upon doing so, the CITY and the CONTRACTOR agree to meet in good faith and confer for the purpose of negotiating a corresponding reduction or increase in the compensation associated with said change in services. 4. PROJECT COORDINATION AND SUPERVISION. Arturo Gonzalez, Facilities Maintenance Supervisor, hereby is designated as the Project Coordinator for the CITY and will monitor the progress and execution of this Agreement. The CONTRACTOR shall assign a single Project Director to provide supervision and have overall responsibility for the progress and execution of this Agreement for the CONTRACTOR. Mike Hubbard thereby is designated as the Project Director for the CONTRACTOR. 5. COMPENSATION AND PAYMENT. The compensation for the CONTRACTOR shall be based on monthly billings covering actual work performed. Billings shall include labor classifications, respective rates, hours worked and also materials, if any. The total cost for all work described in Exhibit "A" shall not exceed $30,377. The compensation for the CONTRACTOR'S work shall not exceed the rates set forth in Exhibit "A". Monthly invoices will be processed for payment and remitted within thirty (30) days from receipt of invoice, provided that work is accomplished consistent with Exhibit "A", as determined by the CITY. The CONTRACTOR shall maintain all books, documents, papers, employee time sheets, accounting records, and other evidence pertaining to costs incurred, and shall make such materials available at its office at all reasonable times during the term of this Agreement and for three (3) years from the date of final payment under this Agreement, for inspection by the CITY, and for furnishing of copies to the CITY, if requested. 6. ACCEPTABILITY OF WORK. The CITY shall decide any and all questions which may arise as to the quality or acceptability of the services performed and the manner of performance, the acceptable completion of this Agreement, and the amount of compensation due. In the event the CONTRACTOR and the CITY cannot agree to the quality or acceptability of the work, the manner of performance and/or the compensation payable to the CONTRACTOR in this Agreement, the CITY or the CONTRACTOR shall give to the other written notice. Within ten (10) business days, the CONTRACTOR and the CITY shall each prepare a report which supports their position and file the same with the other party. The CITY shall, with reasonable diligence, determine the quality or acceptability of the work, the manner of performance and/or the compensation payable to the CONTRACTOR. 7. DISPOSITION AND OWNERSHIP OF DOCUMENTS. The Memoranda, Reports, Maps, Drawings, Plans, Specifications, and other documents prepared by the CONTRACTOR for this project, whether paper or electronic, shall become the property of the CITY for use with respect to this project, and shall be turned over to the CITY upon completion of the project, or any phase thereof, as contemplated by this Agreement. Contemporaneously with the transfer of documents, the CONTRACTOR hereby assigns to the CITY, and CONTRACTOR thereby expressly waives and disclaims any copyright Service Agreement Page 2 of 10 City of National City and March 27, 2017 Countywide Mechanical Systems, Inc. in, and the right to reproduce, all written material, drawings, plans, specifications, or other work prepared under this Agreement, except upon the CITY'S prior authorization regarding reproduction, which authorization shall not be unreasonably withheld. The CONTRACTOR shall, upon request of the CITY, execute any further document(s) necessary to further effectuate this waiver and disclaimer. The CONTRACTOR agrees that the CITY may use, reuse, alter, reproduce, modify, assign, transfer, or in any other way, medium, or method utilize the CONTRACTOR'S written work product for the CITY'S purposes, and the CONTRACTOR expressly waives and disclaims any residual rights granted to it by Civil Code Sections 980 through 989 relating to intellectual property and artistic works. Any modification or reuse by the CITY of documents, drawings, or specifications prepared by the CONTRACTOR shall relieve the CONTRACTOR from liability under Section 14, but only with respect to the effect of the modification or reuse by the CITY, or for any liability to the CITY should the documents be used by the CITY for some project other than what was expressly agreed upon within the Scope of Services of this project, unless otherwise mutually agreed. 8. INDEPENDENT CONTRACTOR. Both parties hereto in the performance of this Agreement will be acting in an independent capacity and not as agents, employees, partners, or joint venturers with one another. Neither the CONTRACTOR nor the CONTRACTOR'S employees are employees of the CITY, and are not entitled to any of the rights, benefits, or privileges of the CITY'S employees, including but not limited to retirement, medical, unemploy- ment, or workers' compensation insurance. This Agreement contemplates the personal services of the CONTRACTOR and the CONTRACTOR'S employees, and it is recognized by the parties that a substantial inducement to the CITY for entering into this Agreement was, and is, the professional reputation and competence of the CONTRACTOR and its employees. Neither this Agreement nor any interest herein may be assigned by the CONTRACTOR without the prior written consent of the CITY. Nothing herein contained is intended to prevent the CONTRACTOR from employing or hiring as many employees, or SUBCONTRACTORS, as the CONTRACTOR may deem necessary for the proper and efficient performance of this Agreement. All agreements by CONTRACTOR with its SUBCONTRACTOR(S) shall require the SUBCONTRACTOR(S) to adhere to the applicable terms of this Agreement. 9. CONTROL. Neither the CITY nor its officers, agents, or employees shall have any control over the conduct of the CONTRACTOR or any of the CONTRACTOR'S employees, except as herein set forth, and the CONTRACTOR or the CONTRACTOR'S agents, servants, or employees are not in any manner agents, servants, or employees of the CITY, it being understood that the CONTRACTOR its agents, servants, and employees are as to the CITY wholly independent CONTRACTOR, and that the CONTRACTOR'S obligations to the CITY are solely such as are prescribed by this Agreement. 10. COMPLIANCE WITH APPLICABLE LAW. The CONTRACTOR, in the performance of the services to be provided herein, shall comply with all applicable state and federal statutes and regulations, and all applicable ordinances, rules, and regulations of the City of National City, whether now in force or subsequently enacted. The CONTRACTOR and each Service Agreement Page 3 of 10 City of National City and March 27, 2017 Countywide Mechanical Systems, Inc. of its SUBCONTRACTOR(S), shall obtain and maintain a current City of National City business license prior to and during performance of any work pursuant to this Agreement. 11. LICENSES, PERMITS, ETC. The CONTRACTOR represents and covenants that it has all licenses, permits, qualifications, and approvals of whatever nature that are legally required to practice its profession. The CONTRACTOR represents and covenants that the CONTRACTOR shall, at its sole cost and expense, keep in effect at all times during the term of this Agreement, any license, permit, or approval which is legally required for the CONTRACTOR to practice its profession. 12. STANDARD OF CARE. A. The CONTRACTOR, in performing any services under this Agreement, shall perform in a manner consistent with that level of care and skill ordinarily exercised by members of the CONTRACTOR'S trade or profession currently practicing under similar conditions and in similar locations. The CONTRACTOR shall take all special precautions necessary to protect the CONTRACTOR'S employees and members of the public from risk of harm arising out of the nature of the work and/or the conditions of the work site. B. Unless disclosed in writing prior to the date of this Agreement, the CONTRACTOR warrants to the CITY that it is not now, nor has it for the five (5) years preceding, been debarred by a governmental agency or involved in debarment, arbitration or litigation proceedings concerning the CONTRACTOR'S professional performance or the furnishing of materials or services relating thereto. C. The CONTRACTOR is responsible for identifying any unique products, treatments, processes or materials whose availability is critical to the success of the project the CONTRACTOR has been retained to perform, within the time requirements of the CITY, or, when no time is specified, then within a commercially reasonable time. Accordingly, unless the CONTRACTOR has notified the CITY otherwise, the CONTRACTOR warrants that all products, materials, processes or treatments identified in the project documents prepared for the CITY are reasonably commercially available. Any failure by the CONTRACTOR to use due diligence under this sub -paragraph will render the CONTRACTOR liable to the CITY for any increased costs that result from the CITY' S later inability to obtain the specified items or any reasonable substitute within a price range that allows for project completion in the time frame specified or, when not specified, then within a commercially reasonable time. 13. NON-DISCRIMINATION PROVISIONS. The CONTRACTOR shall not discriminate against any employee or applicant for employment because of age, race, color, ancestry, religion, sex, sexual orientation, marital status, national origin, physical handicap, or medical condition. The CONTRACTOR will take positive action to insure that applicants are employed without regard to their age, race, color, ancestry, religion, sex, sexual orientation, marital status, national origin, physical handicap, or medical condition. Such action shall include but not be limited to the following: employment, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff or termination, rates of pay or other forms of compensation, and selection for training, including apprenticeship. The CONTRACTOR agrees to post in conspicuous places available to employees and applicants for employment any notices provided by the CITY setting forth the provisions of this non-discrimination clause. Service Agreement Page 4 of 10 City of National City and March 27, 2017 Countywide Mechanical Systems, Inc. 14. CONFIDENTIAL INFORMATION. The CITY may from time to time communicate to the CONTRACTOR certain confidential information to enable the CONTRACTOR to effectively perform the services to be provided herein. The CONTRACTOR shall treat all such information as confidential and shall not disclose any part thereof without the prior written consent of the CITY. The CONTRACTOR shall limit the use and circulation of such information, even within its own organization, to the extent necessary to perform the services to be provided herein. The foregoing obligation of this Section 14, however, shall not apply to any part of the information that (i) has been disclosed in publicly available sources of information; (ii) is, through no fault of the CONTRACTOR, hereafter disclosed in publicly available sources of information; (iii) is already in the possession of the CONTRACTOR without any obligation of confidentiality; or (iv) has been or is hereafter rightfully disclosed to the CONTRACTOR by a third party, but only to the extent that the use or disclosure thereof has been or is rightfully authorized by that third party. The CONTRACTOR shall not disclose any reports, recommendations, conclusions or other results of the services or the existence of the subject matter of this Agreement without the prior written consent of the CITY. In its performance hereunder, the CONTRACTOR shall comply with all legal obligations it may now or hereafter have respecting the information or other property of any other person, firm or corporation. CONTRACTOR shall be liable to CITY for any damages caused by breach of this condition, pursuant to the provisions of Section 14. 15. INDEMNIFICATION AND HOLD HARMLESS. The CONTRACTOR agrees to defend, indemnify and hold harmless the City of National City, its officers, officials, agents, employees, and volunteers against and from any and all liability, loss, damages to property, injuries to, or death of any person or persons, and all claims, demands, suits, actions, proceedings, reasonable attorneys' fees, and defense costs, of any kind or nature, including workers' compensation claims, of or by anyone whomsoever, resulting from or arising out of the CONTRACTOR'S performance or other obligations under this Agreement; provided, however, that this indemnification and hold harmless shall not include any claims or liability arising from the established sole negligence or willful misconduct of the CITY, its agents, officers, employees or volunteers. CITY will cooperate reasonably in the defense of any action, and CONTRACTOR shall employ competent counsel, reasonably acceptable to the City Attorney. The indemnity, defense, and hold harmless obligations contained herein shall survive the termination of this Agreement for any alleged or actual omission, act, or negligence under this Agreement that occurred during the term of this Agreement. 16. WORKERS' COMPENSATION. The CONTRACTOR shall comply with all of the provisions of the Workers' Compensation Insurance and Safety Acts of the State of California, the applicable provisions of Division 4 and 5 of the California Government Code and all amendments thereto; and all similar State or federal acts or laws applicable; and shall indemnify, and hold harmless the CITY and its officers, employees, and volunteers from and against all claims, demands, payments, suits, actions, proceedings, and judgments of every nature and description, including reasonable attorney's fees and defense costs presented, brought or recovered against the CITY or its officers, employees, or volunteers, for or on account of any liability under any of said acts which may be incurred by reason of any work to be performed by the CONTRACTOR under this Agreement. Service Agreement Page 5 of 10 City of National City and March 27, 2017 Countywide Mechanical Systems, Inc. 17. INSURANCE. The CONTRACTOR, at its sole cost and expense, shall purchase and maintain, and shall require its SUBCONTRACTOR(S), when applicable, to purchase and maintain throughout the term of this Agreement, the following checked insurance policies: A. n If checked, Professional Liability Insurance (errors and omissions) with minimum limits of $1,000,000 per occurrence. B. Automobile Insurance covering all bodily injury and property damage incurred during the performance of this Agreement, with a minimum coverage of $1,000,000 combined single limit per accident. Such automobile insurance shall include owned, non -owned, and hired vehicles ("any auto"). The policy shall name the CITY and its officers, agents, employees, and volunteers as additional insureds, and a separate additional insured endorsement shall be provided. C. Commercial General Liability Insurance, with minimum limits of either $2,000,000 per occurrence and $4,000,000 aggregate, or $1,000,000 per occurrence and $2,000,000 aggregate with a $2,000,000 umbrella policy, covering all bodily injury and property damage arising out of its operations, work, or performance under this Agreement. The policy shall name the CITY and its officers, agents, employees, and volunteers as additional insureds, and a separate additional insured endorsement shall be provided. The general aggregate limit must apply solely to this "project" or "location". The "project" or "location" should be noted with specificity on an endorsement that shall be incorporated into the policy. D. Workers' Compensation Insurance in an amount sufficient to meet statutory requirements covering all of CONTRACTOR'S employees and employers' liability insurance with limits of at least $1,000,000 per accident. In addition, the policy shall be endorsed with a waiver of subrogation in favor of the CITY. Said endorsement shall be provided prior to commencement of work under this Agreement. If CONTRACTOR has no employees subject to the California Workers' Compensation and Labor laws, CONTRACTOR shall execute a Declaration to that effect. Said Declaration shall be provided to CONTRACTOR by CITY. E. The aforesaid policies shall constitute primary insurance as to the CITY, its officers, officials, employees, and volunteers, so that any other policies held by the CITY shall not contribute to any loss under said insurance. Said policies shall provide for thirty (30) days prior written notice to the CITY of cancellation or material change. F. If required insurance coverage is provided on a "claims made" rather than "occurrence" form, the CONTRACTOR shall maintain such insurance coverage for three years after expiration of the term (and any extensions) of this Agreement. In addition, the "retro" date must be on or before the date of this Agreement. G. Insurance shall be written with only California admitted companies that hold a current policy holder's alphabetic and financial size category rating of not less than A:VII according to the current Best's Key Rating Guide, or a company equal financial stability that is approved by the CITY'S Risk Manager. In the event coverage is provided by non -admitted "surplus lines" carriers, they must be included on the most recent California List of Eligible Surplus Lines Insurers (LESLI list) and otherwise meet rating requirements. H. This Agreement shall not take effect until certificate(s) or other sufficient proof that these insurance provisions have been complied with, are filed with and approved by the CITY'S Risk Manager. If the CONTRACTOR does not keep all of such insurance policies in full force and effect at all times during the terms of this Agreement, the CITY may elect to treat Service Agreement Page 6 of 10 City of National City and March 27, 2017 Countywide Mechanical Systems, Inc. the failure to maintain the requisite insurance as a breach of this Agreement and terminate the Agreement as provided herein. I. All deductibles and self -insured retentions in excess of $10,000 must be disclosed to and approved by the CITY. 18. LEGAL FEES. If any party brings a suit or action against the other party arising from any breach of any of the covenants or agreements or any inaccuracies in any of the representations and warranties on the part of the other party arising out of this Agreement, then in that event, the prevailing party in such action or dispute, whether by final judgment or out -of - court settlement, shall be entitled to have and recover of and from the other party all costs and expenses of suit, including attorneys' fees. For purposes of determining who is to be considered the prevailing party, it is stipulated that attorney's fees incurred in the prosecution or defense of the action or suit shall not be considered in determining the amount of the judgment or award. Attorney's fees to the prevailing party if other than the CITY shall, in addition, be limited to the amount of attorney's fees incurred by the CITY in its prosecution or defense of the action, irrespective of the actual amount of attorney's fees incurred by the prevailing party. 19. TERMINATION. A. This Agreement may be terminated with or without cause by the CITY. Termination without cause shall be effective only upon 60-day's written notice to the CONTRACTOR. During said 60-day period the CONTRACTOR shall perform all services in accordance with this Agreement. B. This Agreement may also be terminated immediately by the CITY for cause in the event of a material breach of this Agreement, misrepresentation by the CONTRACTOR in connection with the formation of this Agreement or the performance of services, or the failure to perform services as directed by the CITY. C. Termination with or without cause shall be effected by delivery of written Notice of Termination to the CONTRACTOR as provided for herein. D. In the event of termination, all finished or unfinished Memoranda Reports, Maps, Drawings, Plans, Specifications and other documents prepared by the CONTRACTOR, whether paper or electronic, shall immediately become the property of and be delivered to the CITY, and the CONTRACTOR shall be entitled to receive just and equitable compensation for any work satisfactorily completed on such documents and other materials up to the effective date of the Notice of Termination, not to exceed the amounts payable hereunder, and less any damages caused the CITY by the CONTRACTOR'S breach, if any. Thereafter, ownership of said written material shall vest in the CITY all rights set forth in Section 7. E. The CITY further reserves the right to immediately terminate this Agreement upon: (1) the filing of a petition in bankruptcy affecting the CONTRACTOR; (2) a reorganization of the CON TRACTOR for the benefit of creditors; or (3) a business reorganization, change in business name or change in business status of the CONTRACTOR. 20. NOTICES. All notices or other communications required or permitted hereunder shall be in writing, and shall be personally delivered; or sent by overnight mail (Federal Express or the like); or sent by registered or certified mail, postage prepaid, return receipt requested; or sent by ordinary mail, postage prepaid; or telegraphed or cabled; or delivered or sent by telex, Service Agreement Page 7 of 10 City of National City and March 27, 2017 Countywide Mechanical Systems, Inc. telecopy, facsimile or fax; and shall be deemed received upon the earlier of (i) if personally delivered, the date of delivery to the address of the person to receive such notice, (ii) if sent by overnight mail, the business day following its deposit in such overnight mail facility, (iii) if mailed by registered, certified or ordinary mail, five (5) days (ten (10) days if the address is outside the State of California) after the date of deposit in a post office, mailbox, mail chute, or other like facility regularly maintained by the United States Postal Service, (iv) if given by telegraph or cable, when delivered to the telegraph company with charges prepaid, or (v) if given by telex, telecopy, facsimile or fax, when sent. Any notice, request, demand, direction or other communication delivered or sent as specified above shall be directed to the following persons: To CITY: Arturo Gonzalez Facilities Maintenance Supervisor Engineering and Public Works City of National City 1243 National City Boulevard National City, CA 91950-4397 To CONTRACTOR: Mike Hubbard Service Account Manager Countrywide Mechanical Systems, Inc. 1400 N. Johnson Ave., Suite 114 El Cajon, CA 92020 Notice of change of address shall be given by written notice in the manner specified in this Section. Rejection or other refusal to accept or the inability to deliver because of changed address of which no notice was given shall be deemed to constitute receipt of the notice, demand, request or communication sent. Any notice, request, demand, direction or other communication sent by cable, telex, telecopy, facsimile or fax must be confirmed within forty- eight (48) hours by letter mailed or delivered as specified in this Section. 21. CONFLICT OF INTEREST AND POLITICAL REFORM ACT OBLIGATIONS. During the term of this Agreement, the CONTRACTOR shall not perform services of any kind for any person or entity whose interests conflict in any way with those of the City of National City. The CONTRACTOR also agrees not to specify any product, treatment, process or material for the project in which the CONTRACTOR has a material financial interest, either direct or indirect, without first notifying the CITY of that fact. The CONTRACTOR shall at all times comply with the terms of the Political Reform Act and the National City Conflict of Interest Code. The CONTRACTOR shall immediately disqualify itself and shall not use its official position to influence in any way any matter coming before the CITY in which the CONTRACTOR has a financial interest as defined in Government Code Section 87103. The CONTRACTOR represents that it has no knowledge of any financial interests that would require it to disqualify itself from any matter on which it might perform services for the CITY. ❑ If checked, the CONTRACTOR shall comply with all of the reporting requirements of the Political Reform Act and the National City Conflict of Interest Code. Specifically, the CONTRACTOR shall file a Statement of Economic Interests with the City Service Agreement Page 8 of 10 City of National City and March 27, 2017 Countywide Mechanical Systems, Inc. Clerk of the City of National City in a timely manner on forms which the CONTRACTOR shall obtain from the City Clerk. The CONTRACTOR shall be strictly liable to the CITY for all damages, costs or expenses the CITY may suffer by virtue of any violation of this Paragraph 22 by the CONTRACTOR. 22. PREVAILING WAGES. State prevailing wage rates may apply to work performed under this Agreement. State prevailing wages rates apply to all public works contracts as set forth in California Labor Code, including but not limited to, Sections 1720,1720.2, 1720.3, 1720.4, and 1771. Contractor is solely responsible to determine if State prevailing wage rates apply and, if applicable, pay such rates in accordance with all laws, ordinances, rules, and regulations. 23. MISCELLANEOUS PROVISIONS. A. Computation of Time Periods. If any date or time period provided for in this Agreement is or ends on a Saturday, Sunday or federal, state or legal holiday, then such date shall automatically be extended until 5:00 p.m. Pacific Time of the next day which is not a Saturday, Sunday or federal, state, or legal holiday. B. Counterparts. This Agreement may be executed in multiple counterparts, each of which shall be deemed an original, but all of which, together, shall constitute but one and the same instrument. C. Captions. Any captions to, or headings of, the sections or subsections of this Agreement are solely for the convenience of the parties hereto, are not a part of this Agreement, and shall not be used for the interpretation or determination of the validity of this Agreement or any provision hereof. D. No Obligations to Third Parties. Except as otherwise expressly provided herein, the execution and delivery of this Agreement shall not be deemed to confer any rights upon, or obligate any of the parties hereto, to any person or entity other than the parties hereto. E. Exhibits and Schedules. The Exhibits and Schedules attached hereto are hereby incorporated herein by this reference for all purposes. To the extent any exhibits,schedules, or provisions thereof conflict or are inconsistent with the terms and conditions contained in this Agreement, the terms and conditions of this Agreement shall control. F. Amendment to this Agreement. The terms of this Agreement may not be modified or amended except by an instrument in writing executed by each of the parties hereto. G. Waiver. The waiver or failure to enforce any provision of this Agreement shall not operate as a waiver of any future breach of any such provision or any other provision hereof. H. Applicable Law. This Agreement shall be governed by and construed in accordance with the laws of the State of California. I. Audit. If this Agreement exceeds ten -thousand dollars ($10,000), the parties shall be subject to the examination and audit of the State Auditor for a period of three (3) years after final payment under the Agreement, per Government Code Section 8546.7. J. Entire Agreement. This Agreement supersedes any prior agreements, negotiations and communications, oral or written, and contains the entire agreement between the parties as to the subject matter hereof. No subsequent agreement, representation, or promise made by either party hereto, or by or to an employee, officer, agent or representative of any party hereto shall be of any effect unless it is in writing and executed by the party to be bound thereby. Service Agreement March 27, 2017 Page 9 of 10 City of National City and Countywide Mechanical Systems, Inc. K. Successors and Assigns. This Agreement shall be binding upon and shall inure to the benefit of the successors and assigns of the parties hereto. L. Subcontractors or Subcontractors. The CITY is engaging the services of the CONTRACTOR identified in this Agreement. The CONTRACTOR shall not subcontract any portion of the work, unless such subcontracting was part of the original proposal or is allowed by the CITY in writing. In the event any portion of the work under this Agreement is subcontracted, the subcontractor(s) shall be required to comply with and agree to, for the benefit of and in favor of the CITY, both the insurance provisions in Section 17 and the indemnification and hold harmless provision of Section 15 of this Agreement. M. Construction. The parties acknowledge and agree that (i) each party is of equal bargaining strength, (ii) each party has actively participated in the drafting, preparation and negotiation of this Agreement, (iii) each such party has consulted with or has had the opportunity to consult with its own, independent counsel and such other professional advisors as such party has deemed appropriate, relative to any and all matters contemplated under this Agreement, (iv) each party and such parry's counsel and advisors have reviewed this Agreement, (v) each party has agreed to enter into this Agreement following such review and the rendering of such advice, and (vi) any rule or construction to the effect that ambiguities are to be resolved against the drafting party shall not apply in the interpretation of this Agreement, or any portions hereof, or any amendments hereto. IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the date and year first above written. CITY OF NATIONAL CITY Bq�l� Leslie Deese, City Manager APPROVED AS TO FORM: George H. Eiser, III Interim City Attorney COUNTYWIDE MECHANICAL SYSTEMS, INC. (Signatures of two corporate o,( ers required) By: (Name) RANDALL A. SIGNORE (Print) VP -SERVICE & SPECIAL PROJECTS OPERATIONS (Title) By: (Name) MICHAEL CANCEL (Print) SERVICE OPERATIONS MANAGER (Title) Service Agreement Page 10 of 10 City of National City and March 27, 2017 Countywide Mechanical Systems, Inc. C(uuntuwide �.. - Mechanical Systems, Inc. 3/21/2017 CMS PROPOSAL # 11759R City of National City ATTN: Arturo Gonzalez 619-336-4585 RE: National City Fire Department Station 34 343 E 16th St. National City, CA 91950 PUMP MOTOR REPLACEMENT During a recent visit to your location at Fire Station 34 to quote a motor replacement of the main pump. We are recommending thefollowing: 1. Secure the electrical to this pump for safety. 2. Drain enough water from the system in order to remove the motor, adapter and seal kit. 3. Provide and install the following items: One (1) 60 HP ODP motor, One (1) Adapter, One (1) Seal Kit, One (1) 60 HP ABB Variable Frequency Drive (VFD). 4. Provide and install One Pressure transducer to communicate with the VFD. 5. Rebuild Cla-Valve pressure relief valve. 6.Place the pump in service and calibrate the VFD to run efficiently and provide the trainees with the water pressure they need to properly train. and misc. installation material. 7. Place pump in service. *See Notes 8. Check for Teaks and running order. 9. Commission system. 10. Clean up and check out with facilities. Note: A. Work to be done during normal working hours. B.VFD needs to be installed before pump can be ran. C. Quote to follow if further repairs are needed. Exclusions: A. Permits, engineering drawings, controls and B. Anything not listed in the above scope of work. Material lead time: Motor 2-3 days, VFD 6-8 Weeks. THE COST TO PERFORM THE SCOPE OF WORK ABOVE: $30,377.00 We look forward to working with you on this project and would like to take this opportunity to thank you for choosing Countywide Mechanical Systems for all your service needs. If you have any questions and/or concerns regarding this project or if there is anything else that we may be of service to you for, please feel free to contact us. This proposal is valid for 30 days. Thank you, Mike Hubbard Service Account Manager EXHIBIT A ACCEPTANCE: BY: TITLE: DATE: 1400 N. JOHNSON AVE. SUITE 114, EL CAJON, CA 92020 PHONE (619) 449-9900 FAX (619)449-9907 Lic. 967998 ACORES' CERTIFICATE OF LIABILITY INSURANCE ‘...----- 3/1/2018 DATE(MM/DD/YYYY) 3/23/2017 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Lockton Companies 444 W. 47th Street, Suite 900 Kansas City MO 64112-1906 (816) 960-9000 NCONT AMEACT I�tc r o. Extl: FAX(A/C No): E-MAIL ADDRESS: INSURER(S) AFFORDING COVERAGE INSURER A : Old Republic General Ins Corporation NAIL # 24139 INSURED COUNTYWIDE MECHANICAL SYSTEMS, INC. 1362635 1400 N. JOHNSON AVE., SUITE 114 EL CAJON CA 92020 INSURER B : Houston Casualty Company 42374 INSURER C : INSURER D : INSURER E : INSURER F : CERTIFICATE NUMBER: • THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF (MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY Y N A7DG09221702 3/1/2017 3/1/2018 EACH OCCURRENCE $ 1,000,000 CLAIMS -MADE XOCCUR DAMAGE PREMISESO(EaENTED nrYui ence) $ 300,000 X CONTRACTUAL MED EXP (Any one person) $ 10,000 PERSONAL & ADV INJURY $ 1,000,000 GENII_ AGGREGATE POLICY OTHER: X LIMIT APPLIES ECT X PER: LOC GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMP/OP AGG $ 2,000,000 $ A AUTOMOBILE X X X LIABILITY ANY AUTO OWNED AUTOS ONLY HIRED AUTOS ONLY X SCHEDULED AUTOS NON -OWNED AUTOS ONLY Y N A7CA09221702 3/1/2017 3/1/2018 COMBINED SINGLE LIMIT (Ea accident) $ 1,000,000 BODILY INJURY (Per person) p ) �O�XXXXX BODILY INJURY (Per accident) $ XXXXXXX PROPERTY DAMAGE (Per accident) $ XXX70CX $ XXXX3GOX B x UMBRELLA LIAB EXCESS LIAB X OCCUR CLAIMS -MADE Y N H17XC50421-02 3/1/2017 3/1/2018 EACH OCCURRENCE $ 5,000,000 AGGREGATE $ 5,000,000 DED RETENT ON $ $ XA'XXXXX A A A A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below Y / N N N IA Y A7DW09221702 (AOS) A7CW09221702 (WI ONLY) EXCLUDES PR, U S VI STOP GAP ONLY: ND,OH,WA,WY 3/1/2017 3/1/2017 I 3/1/2018 3/1/2018 X PER STATUTE OTH- ER E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYEE $ 1,000,000 E.L. DISEASE - POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) THIS CERTIFICATE SUPERSEDES ALL PREVIOUSLY ISSUED CERTIFICATES FOR THIS HOLDER, APPLICABLE TO THE CARRIERS L STED AND THE POLICY TERM(S) REFERENCED. RE: AS NEEDED PLUMBING AND HVAC SERVICES. THE CITY OF NATIONAL CITY, ITS ELECTED OFFICIALS, OFFICERS, AGENTS, EMPLOYEES AND VOLUNTEERS ARE ADDITIONAL INSURED ON GENERAL, AUTO AND EXCESS LIABILITY COVERAGE, AS REQUIRED BY WRITTEN CONTRACT. WAIVER OF SUBROGATION IN FAVOR OF THE ADDITIONAL INSURED APPLIES ON WORKERS COMPENSATION COVERAGE, AS REQUIRED BY WRITTEN CONTRACT AND WHERE ALLOWED BY LAW. COVERAGE IS SUBJECT TO THE TERMS AND CONDITIONS OF THE POLICY. MMC'S GENERAL LIABILITY AND WORKERS COMPENSATION POLICIES EACH HAVE A $100,000 DEDUCTIBLE. CERTIFICATE HOLDER CANCELLATION See Attachments 14457058 CITY OF NATIONAL CITY C/O RISK MANAGER 1243 NATIONAL CITY BOULEVARD NATIONAL CITY CA 91950 ACORD 25 (2016/03) SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIV ©1988=ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD POLICY NUMBER: A7DG09221702 COMMERCIAL GENERAL LIABILITY CG20100413 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED --- OWNERS, LESSEES OR CONTRACTORS -- SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Additional Insured Person(s) or Organization(s): ANY PERSONS OR ORGANIZATIONS TO WHOM OR TO WHICH YOU ARE REQUIRED TO PROVIDE ADDITIONAL INSURED STATUS IN A WRITTEN CONTRACT OR WRITTEN AGREEMENT EXECUTED PRIOR TO THE LOSS EXCEPT WHERE SUCH CONTRACT OR AGREEMENT IS PROHIBITED BY LAW. Location(s) Of Covered Operations: VARIOUS AS REQUIRED PER WRITTEN CONTRACT. (Information required to complete this Schedule, if not shown above, will be shown in the Declarations.) A. Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) designated above. However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured wilt not be broader than that which you are required by the contract or agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after: Miscellaneous Attachment: M472461 Master ID: 1362635, Certificate ID: 14457058 1. All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or 2. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. C. With respect to the insurance afforded to these additional insureds, the following is added to Section III - Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. CG20100413 Miscellaneous Attachment: M472461 Master ID: 1362635, Certificate ID: 14457058 POLICY NUMBER: A7DG09221702 COMMERCIAL GENERAL LIABILITY CG 20 37 0413 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Additional Insured Person(s) or Organization(s): ANY PERSONS OR ORGANIZATION TO WHOM OR TO WHICH YOU AR REQUIRED TO PROVIDE ADDITIONAL INSURED STATUS IN A WRITTEN CONTRACT OR WRITTEN AGREEMENT EXECUTED PRIOR TO THE LOSS EXCEPT WHERE SUCH CONTRACT OR AGREEMENT IS PROHIBITED BY LAW. Location And Description of Completed Operations: VARIOUS AS REQUIRED BY WRITTEN CONTRACT. (Information required to complete this Schedule, if not shown above will be shown in the Declarations.) A. Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" caused, in whole or in part, by "your work" at the location designated and described in the Schedule of this endorsement performed for that additional insured and included in the "products -completed operations hazard". However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following is added to Section III - Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. CG20370413 Miscellaneous Attachment: M472462 Master ID: 1362635, Certificate ID: 14457058 30 DAY NOTICE OF CANCELLATION - WRITTEN NOTICE For insurance provided under: - Commercial General Liability - Commercial Automobile Liability - Workers' Compensation/Employers Liability If the insurance carrier cancels or non -renews any of the above policies by written notice to the first Named Insured for any reason other than the nonpayment of premium, the carrier will also mail or deliver a copy of such written notice of cancellation or non - renewal to the Certificate Holder. Notice of cancellation for non-payment of premium will be mailed or delivered at least 10 days prior to the effective date of such cancellation. Miscellaneous Attachment: M463402 Master ID: 1362635, Certificate ID: 14457058 POLICY NUMBER: A7DG09221702 COMMERCIAL GENERAL LIABILITY CG20100413 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED --- OWNERS, LESSEES OR CONTRACTORS -- SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Additional Insured Person(s) or Organization(s): ANY PERSONS OR ORGANIZATIONS TO WHOM OR TO WHICH YOU ARE REQUIRED TO PROVIDE ADDITIONAL INSURED STATUS IN A WRITTEN CONTRACT OR WRITTEN AGREEMENT EXECUTED PRIOR TO THE LOSS EXCEPT WHERE SUCH CONTRACT OR AGREEMENT IS PROHIBITED BY LAW. Location(s) Of Covered Operations: VARIOUS AS REQUIRED PER WRITTEN CONTRACT. (Information required to complete this Schedule, if not shown above, will be shown in the Declarations.) A. Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) designated above. However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after: Miscellaneous Attachment: M472461 Certificate ID: 14457058 1. All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or 2. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. C. With respect to the insurance afforded to these additional insureds, the following is added to Section III - Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. CG20100413 Miscellaneous Attachment: M472461 Certificate ID: 14457058 POLICY NUMBER: A7DG09221702 COMMERCIAL GENERAL LIABILITY CG20370413 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Additional Insured Person(s) or Organization(s): ANY PERSONS OR ORGANIZATION TO WHOM OR TO WHICH YOU AR REQUIRED TO PROVIDE ADDITIONAL INSURED STATUS IN A WRITTEN CONTRACT OR WRITTEN AGREEMENT EXECUTED PRIOR TO THE LOSS EXCEPT WHERE SUCH CONTRACT OR AGREEMENT IS PROHIBITED BY LAW. Location And Description of Completed Operations: VARIOUS AS REQUIRED BY WRITTEN CONTRACT. (Information required to complete this Schedule, if not shown above will be shown in the Declarations.) A. Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" caused, in whole or in part, by "your work" at the location designated and described in the Schedule of this endorsement performed for that additional insured and included in the "products -completed operations hazard". However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following is added to Section III - Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. CG 20 37 04 13 Miscellaneous Attachment: M472462 Certificate ID: 14457058 POLICY NUMBER: A7CA09221702 COMMERCIAL AUTO CA04441013 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM BUSINESS AUTO PHYSICAL DAMAGE COVERAGE FORM GARAGE COVERAGE FORM MOTOR CARRIER COVERAGE FORM TRUCKERS COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated. Named Insured: MMC CORP. Endorsement Effective Date: March 1, 2017 SCHEDULE Name(s) Of Person(s) Or Organization(s): WHERE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT EXECUTED PRIOR TO LOSS (EXCEPT WHERE NOT PERMITTED BY LAW). Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The Transfer Of Rights Of Recovery Against Others To Us condition does not apply to the person(s) or organization(s) shown in the Schedule, but only to the extent that subrogation is waived prior to the "accident" or the "loss" under a contract with that person or organization. CA 04 44 10 13 Miscellaneous Attachment: M472682 Certificate ID: 14457058 POLICY NUMBER: A7DG09221702 COMMERCIAL GENERAL LIABILITY CG 25 03 05/09 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. DESIGNATED CONSTRUCTION PROJECT(S) GENERAL AGGREGATE LIMIT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Designated Construction Project(s): EACH "PROJECT" FOR WHICH YOU HAVE AGREED, IN A WRITTEN CONTRACT WHICH IS IN EFFECT DURING THIS POLICY PERIOD, TO PROVIDE A SEPARATE GENERAL AGGREGATE LIMIT; PROVIDED THAT, THE CONTRACT IS SIGNED AN EXECUTED PRIOR TO ANY LOSS FOR WHICH COVERAGE IS SOUGHT. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. For all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under Section I - Coverage A, and for all medical expenses caused by accidents under Section I - Coverage C, which can be attributed only to ongoing operations at a single designated construction project shown in the Schedule above: 1. A separate Designated Construction Project General Aggregate Limit applies to each designated construction project, and that limit is equal to the amount of the General Aggregate Limit shown in the Declarations. 2. The Designated Construction Project General Aggregate Limit is the most we will pay for the sum of all damages under COVERAGE A, except damages because of "bodily injury" or "property damage" included in the "products -completed operations hazard", and for medical expenses under Coverage C regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 3. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the Designated Construction Project General Aggregate Limit for that designated construction project. Such payments shall not reduce the General Aggregate Limit shown in the Declarations nor shall they reduce any other Designated Construction Project General Aggregate Limit for any other designated construction project shown in the Schedule above. Miscellaneous Attachment: M475822 Certificate ID: 14457058 4. The limits shown in the Declarations for Each Occurrence, Fire Damage and Medical Expense continue to apply. However, instead of being subject to the General Aggregate Limit shown in the Declarations, such limits will be subject to the applicable Designated Construction Project General Aggregate Limit. B. For all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under Section I - Coverage A, and for all medical expenses caused by accidents under Section I - Coverage C, which cannot be attributed only to ongoing operations at a single designated construction project shown in the Schedule above: 1. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the amount available under the General Aggregate Limit or the Products - Completed Operations Aggregate Limit, whichever is applicable; and 2. Such payments shall not reduce any Designated Construction Project General Aggregate Limit. C. When coverage for liability arising out of the "products -completed operations hazard" is provided, any payments for damages because of "bodily injury" or "property damage" included in the "products - completed operations hazard" will reduce the Products -Completed Operations Aggregate Limit, and not reduce the General Aggregate Limit nor the Designated Construction Project General Aggregate Limit. D. If the applicable designated construction project has been abandoned, delayed, or abandoned and then restarted, or if the authorized contracting parties deviate from plans, blueprints, designs, specifications or timetables, the project will still be deemed to be the same construction project. E. The provisions of Section III - Limits Of Insurance not otherwise modified by this endorsement shall continue to apply as stipulated. CG 25 03 05/09 Miscellaneous Attachment: M475822 Certificate ID: 14457058 WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE WC 00 03 13 (Ed. 4-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. SCHEDULE WHERE REQUIRED BY WRITTEN AGREEMENT SIGNED PRIOR TO LOSS. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. Effective Policy # A7DW09221702 (AOS); A7CW09221702 (WI ONLY) Insured: MMC Corp. Insurance Company: Old Republic General Insurance Corporation WC 00 03 13 (Ed. 4-84) Miscellaneous Attachment: M472683 Certificate ID: 14457058 Page 1 of 1 CITY OF NATIONAL CITY Office of the City Clerk 1243 National City Blvd., National City, California 91950-4397 619-336-4228 Michael R. Dalla, CMC - City Clerk April 3, 2017 Mr. Mike Hubbard Countywide Mechanical Systems 1400 N. Johnson Avenue, Suite 114 El Cajon, CA 92020 Dear Mr. Hubbard, On March 27th, 2017, an Agreement was entered into between the City of National City and Countywide Mechanical Systems, Inc. We are enclosing for your records a fully executed original Agreement. Sincerely, Michael R. Dalla, CMC City Clerk Enclosure